The URL can be used to link to this page

R2018-182 2018-09-24 RESOLUTION NO. R2018-182 A Resolution of the City Council of the City of Pearland, Texas, awarding a contract for the purchase of Joint and Crack Sealing Services to Main Lane Industries, Ltd., in an amount not to exceed $108,200.00, for the period of October 1, 2018 through September 30, 2019. BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF PEARLAND, TEXAS: Section 1. That the City obtained unit supply bids for the supply of Joint and Crack Sealing Services, and such bids have been evaluated. . Section 2. That the City Council hereby awards a bid to Main Lane Industries, Ltd., in the unit price amounts reflected in Exhibit"A" attached hereto. Section 3. The City Manager or his designee is hereby authorized to execute a unit supply contract for Joint and Crack Sealing Services. PASSED, APPROVED and ADOPTED this the 24th day of September, A.D., 2018. TOM REID MAYOR ATTEST: '' L.* " YSEC- TARY APPROVED AS TO FORM: DARRIN M. COKER CITY ATTORNEY Exhibit A 1. 'RKKEJGINEERS September 13, 2018 Ms. Andrea Brinkley Assistant Director of Public Works City of Pearland 3501 East Orange Street Pearland,Texas 77581 Re: Letter of Recommendation for 2018 Joint and Crack Sealing Project COP Bid No. 0818-59 ARKK Job No. 18-038 Dear Ms. Brinkley: On September 6, 2018 the City of Pearland received two (2) bids for the above referenced project. This project involves furnishing and placing hot poured joint and crack sealant for various concrete pavement streets and asphalt pavement streets, as selected by City staff, within the City of Pearland, as well as all labor, equipment, materials, and incidentals required . for the project. The following is a summary of our bid evaluation. Two (2) construction firms participated in the bidding process. The bids were checked for mathematical errors and/or bid irregularities. The total bids for the project are as follows: Bidder Total Bid Main Lane Industries, Ltd. $108,200.00 SCR Civil Construction, LLC $139,960.00 A copy of the bid tabulation is attached to this letter. It is our understanding the City's available budget for this project is $140,000.00. Main Lane Industries has performed these type of maintenance contracts for other cities and municipalities. In addition, ARKK Engineers is currently working with Main Lane Industries on a street maintenance project for the City of Bellaire, and the project is close to completion. Main Lane Industries appears to be a responsible firm that is capable of performing the specified work in a satisfactory manner. For these reasons, we recommend that the City of Pearland award the 2018 Joint and Crack Sealing Project to Main Lane Industries, Ltd. for a total amount of$108,200.00. 7322 Southwest Fwy Suite 1040 • Houston,TX 77074 • (713)-400-ARKK•www.arkkengineers.com• TX PE Firm No.13872 If you have any questions, please contact me. Sincerely, ARKK ENGINEERS, LLC John Rudloff, P.E. Senior Project Manager/Principal 7322 Southwest Fwy Suite 1040 • Houston,TX 77074 •(713)-400-ARKK•www.arkkengineers.com• TX PE Firm No.13872 • ARKK Job No.18-038 2018 Joint and Crack Sealing Project City of Pearland LOW BIDDER- ITEM IDDER ITEM ITEM DESCRIPTION UNIT QUAN. Main Lane Industries SCR Civil Construction,LLC NO. BASE BID ITEMS: Sealing of concrete pavement expansion joints as identified by the City(hot poured rubber-asphalt compound), 1 including cleaning and preparation,complete in place,the sum of: L.F. 4400 $4.25 $ 18,700.00 $5.90 $ 25,960.00 Sealing of concrete pavement control joints,construction joints and/or cracks as identified by the City(hot poured 2 rubber-asphalt compound),including cleaning and preparation,complete in place,the sum of: L.F. '22000 $3.25 $ 71,500.00 $3.00 $ 66,000.00 Sealing of asphalt pavement cracks as identified by the City(hot poured rubber-asphalt compound),including cleaning 3 and preparation,complete in place,the sum of: L.F. 30000 $0.60 $ 18,000.00_ $1.60 $ 48,000.00 TOTAL BASE BID ITEMS: $ 108,200.00 $ 139,960.00 • • • • • • • • • • • • Bid Date:09/6/2018 Page 1 OF 1 Project Manual R2018-182 for: 2018 Joint and Crack Sealing Project Pc oi L �y _, -v, ,, V . ,,0 '' , '('' A "'1 . 'I' ' . V.'. , n , ww `. v I TEX AS • 0818-59 �tititititttttk BidO. . M�P,cE OF .....ti r*= p� �: *r August 2018 P0.2DOUGLAS W.BRADFORD 4 .� 115517 e % Prepared B .r P Y: 74-1'i 1/o ris 9• �:4 1� I ARKKENGINEERS L/!7/018 ARKK Engineers, LLC 7322 Southwest Freeway, Suite 1040 Houston,TX 77074 TX PE Firm No. 13872 (713)-400-2755 office (713)-400-2754 fax Project Manual for: 2018 Joint and Crack Sealing Project Bid No. : 0818-59 August 2018 Prepared By: AR K ENGINEERS ARKK Engineers, LLC 7322 Southwest Freeway, Suite 1040 Houston, TX 77074 TX PE Firm No. 13872 (713)-400-2755 office (713)- 400-2754 fax CITY OF PEARLAND ADDENDUM Section 00900 ADDENDUM NO. 1 Date: August 31, 2018 ,�,�•�1'%ut11k PROJECT: 2018 Joint and Crack Sealing Project ZrAS.9F 7.V ttt �•co. tel.- 's*tttt BID NO.: 0818-59 * 7�,,,,,,,, ; *, V DOUGLAS W.BRADFORD BID DATE: Sepetember 6, 2018 at 2:00 PM O»•'v' W. Bradford, P.E. j ? 115517 •• "�.• FROM: Douglas B o , rtt? ''•�!c......'��"� Project Manager titlts� 11 ~~ ARKK Engineers, LLC I // 7322 Southwest Fwy, Ste. 1040, Houston, TX 77074 g1311201 S To: Prospective Bidders and Interested Parties This addendum forms a part of the bidding documents and will be incorporated into the Contract Documents, as applicable. Insofar as the original Contract Documents, Specifications, and Drawings are inconsistent, this Addendum shall govern. Please acknowledge receipt of this Addendum on the Bid Proposal form, Section 00300 submitted to the City of Pearland. FAILURE TO ACKNOWLEDGE RECEIPT OF ADDENDA ON THE BID PROPOSAL FORM MAY BE CAUSE FOR DISQUALIFICATION. CONTRACT DOCUMENTS: 1. Attached is the non-mandatory Pre-Bid sign in sheet for the Project. SPECIFICATIONS: No changes. CONSTRUCTION DRAWINGS: 1. See attached Overall City Map showing priority areas for concrete streets only. This map is being provided for informational purposes only. DESIGN CLARIFICATIONS: 1. Mobilization and traffic control as needed to facilitate the joint and crack sealing operations will not be paid for separately, but the cost thereof shall be included in the unit price bid items as shown in the bid proposal. 2. Contractor will be responsible for distributing door hanger notifications to residents on a given street a minimum of 48 hours prior to starting work on that street. The door hanger notification shall be included as a project submittal for review and approval. 2-22-12 00900- 1 of 2 CITY OF PEARLAND ADDENDUM 3. The preliminary cost estimate for this project is approximately$100,000.00. END OF ADDENDUM NO. 1 Dou_- .s W. Brad, P Project Manager j 2-22-12 00900-2 of 2 yoA , 1.44' PRE-BID CONFERENCE a 2018 Joint and Crack Sealing Project �®� Bid No.: 0818-59 s ; all lid, E K . August 30, 2018 10:00 a.m., City Hall Annex esr. ,too. Name (Print) Company Phone Number Email t tA TC\n.► C C 2 P. ani --°i aqt-t„)- j,v\ e c tko.4- 4..,c1-h_.50d 2 rrc.,i, L`btl 4i]y. IQ to lir 201,1e,2— (L,' 4 lCLLG -t:. rt/ /? '. y6 J f/ ° ICA-le .5-1-'1-,Z 1-)4t,r.lic---7-Sc.";A,elS if)'S G'27 3S-6.7 j`d----ey6)/V- dA-, fC.vesAx,f RI✓P•"' e--1 5t2vi(rS-0e �Rtc— "VAN - ml?)?JL 4 /A49,;(5.-mit -A_ '")13—'097--1JLf) (bc.-9Aa�r=C iE/14c_.9.CA t_..C- iJ4liq Cavk j () 0P 2 1 (e6;( tg-10 ✓ aybi::‘1.0 C PO:trtit l(, TV r- -SA -4 (off 4-4/6 6--4/›.),e,,,, s 7/ -lUv- �.r.5---- 7,46.i sjii#6 /,C cvp mss- ,)pvS 6,--a-J.CL,-- 4-12.4x /'�Jj s 3-'109-2 Fr-c- l rc --c Alfu6f^twS- M P-055 (Zoyc---15 SCR C;..: t C'o„s4-.'''''' LLL —z_' l 3L" °-.?"- l"-'6:5 Cs) 5c4- << ..:s1/4-v--)<-t-, , cc-, Construction ...,,, ,_ ini _..4 l ,311::°1(a'S:1F-4: - -- b.:44.4':-. i 44 ___4 ...., . .,41 t==. .--* —4 -*, 1 *VIA* ,11,••••,, ; 'Iir•0..---'--- 4'sit -4"', ''''"HouTrIN ITI....4 1-11 ,1 I ...,....4„,,,,, ,v -*'•,1 ',•••:. .*••,-•' . •/,,r;It I I,0_:,..."--,t. --ii j, ....._ w - .=,...,.... ,,,.....,1 ) C-4 4 .. 1,:, g....' -4.4 r-tr- 1 —1, './ 4 ',1 ,,,--1.-+ ---4----' ', ,•-- ' '',.. -0.0.-.4-0-0,0,000-0 =r*,r—--tr—:.›.. 8 ......._ - ......... -- _ ....... _ __ . — p 9 ,, .., / , .....„..,„ _. ' imossiiiimaxass ___ / g r''' 35 -... • ----1 1%,,,„•- tittoP..''... q : 0" ...". . r , --.. t I* 1 1 roill'arn sassR onal Park , ,.. 4r .r 4 it Si* IX L..-- , I . Cr , , , 0 > , t , •Pj _ 1 __ qt „-' ,- , I 1 -.141(,- p 3 11. ,.., *mid Posob..9 ......,..0. ........ , / ' --, cf i .....,..* .., -. -1 ' , 0 ix — 'RD 1 , P2 ,. 1 . „,. .; . , (--/ ,...• „..„ ..,c .„.. .. ...... - /...._#. ._, i ) . 1_,..4.40,7„....___„„. , ,,„ .1.,.• \ ,i.- \ i ,i , -4 ........ ''''''.77t7.7 r""'-"SW. I'--------------- .288 x, „,!,.. .-160 „......-i„.............„ .. , ,,, ( 1, if I '-',....iak C RE E IC OKA v...---'-' 1 - CIRI/Roii ‘230, ,,,cim 4_.....zt _____ , S• 1. X i, P1 . OP ! if fe*,hrl\I aPt 4, - t ... P7 ,...... ,I ,311c.4... it. 1.II: 7 ' t(t* ••% #-. r 1 X w , ' L--,.......- •". t - ,it _ __-__ • , ) 4. 4:1 \., '--•-•.4. , ' • / t . — -SETA DWAY S3 f.1--.....------. ''its _ k _____ _ rik .." E WALNU, AIN: ._: imp.i.,Er.:1 e ' ' .... „,, - ,.I If R D . ' 414 moo C LI' 4 IC .,.. 9.T.,, ... , ,....„. ...... . _ , it . ,... , 0 -nip",e..-;``ta I . i I 0 ,. I (t.--4-*Ss,' •X) ''>- .04iir 9—- S. , - 4f P8 , , ,,. ...;:t • .. • . ' P6 , .„,, i, _ n s ,.. ', •-z. 1 Ig ., ,-1,400,,A RD; > ,i Q. lit, c .,,,, ..0.................. .., t., •N,,,,„„,,,,, - • --:,-411k,\Ss1/4 ot ., ...... „ .. . . N N ' Sie 0 \ • e' . , ,,,-":7„,pil -,. - f, - ..... . \ ,, 0 N\ 1 '''''-t ' - N $ -A t =4-• \\ ,, — qw - , r ? \mosiiiiimmll iiii .7- 4kr• t --: '---- _,I rtAll".F Y...011.08c.R 611 1-14' CO rt. • , 0- , • - , • t ,... Illr'• 0 ,., . x ,s,,,....P-• 110;1 . I Ill 1 i 7-4 ,\444,0„..- cc I L.,,,..! i 1 - ........ i 1 # , , ill fioe-,:mr .'! „„ . -,.. Q. =•,,,, i « 1 0 1 . , i t / )i, , .-- — --- 4b/j1*-- , . i 3 5 "1***4***411.—.4 • i .10:7„ , 4 City of Pearland 2018 Joint and Crack Sealing Project TABLE OF CONTENTS SECTION TITLE DIVISION 0—BIDDING AND CONTRACT DOCUMENTS 00100 Invitation to Bid 00200 Instructions to Bidders 00300 Bid Proposal 00500 Standard Form of Agreement 00500A Title VI Nondiscrimination Assurances 00500B House Bill 89 Verification 00610 Performance Bond 00611 Payment Bond 00612 One-Year Maintenance Bond 00615 Partial Waiver of Lien 00700 General Conditions of Agreement 00800 Special Conditions of Agreement 00811 Wage Scale for Engineering Construction 00900 Addendum Template DIVISION 1 —GENERAL REQUIREMENTS 01100 Summary of Work 01140 Contractor's Use of Premises 01200 Measurement and Payment Procedures 01290 Change Order Procedures 01310 Coordination and Meetings 01350 Submittals 01420 Referenced Standards 01430 Contractor's Quality Control 01562 Waste Material Disposal 01600 Material and Equipment 01770 Contract Closeout DIVISION 2—SITE WORK 02781 Cleaning and Sealing Pavement Joints and Cracks APPENDIX List of Streets Identified for Sealing ARKK Job No. 18-038 TC-I CITY OF PEARLAND INVITATION TO BID Section 00100 INVITATION TO BID CITY OF PEARLAND, TEXAS Lowest Responsible Bidder Sealed Electronic Bids will be accepted for the following project, in the City's E-bid System. Electronic bids shall be submitted through the City's web site at: https://pearland.ionwave.net/Login.aspx. All interested Bidders are required to register as a "supplier" on the City's E-bid System at the above web address and clicking on "Supplier Registration". Registration provides automatic access to any changes to the Plans, Specifications or Bid time and date. However, submission of an E-bid requires completing a short registration questionnaire found on this web site. When prompted to add or remove commodity codes registrants must add the codes listed below: * Building Construction Services,New(Includes Maintenance and Repair Services) * Construction Services, General (Includes Maintenance and Repair Services) * Construction Services, Heavy(Includes Maintenance and Repair Services) * Construction Services, Trade (New Construction) For more information regarding registration instructions, see INSTRUCTIONS TO BIDDERS, Section 00200, included in the project bid documents viewable on the web site. Questions regarding electronic bidding should be directed to City Purchasing Officer at ebids@a,pearlandtx.gov. All Bids submitted electronically will remain confidential until the opening date and time when they will be opened and read into the public record. Bids, shall be submitted on the form provided in the E-bid System and submitted electronically through this system to the City Purchasing Officer, City of Pearland, City Hall Annex located at 3523 Liberty Drive, Pearland, Texas 77581. Electronic bids will be accepted until 2:00 p.m., Thursday, September 6, 2018. All Bids shall reference the following project information in the appropriate locations in provided electronic format. All properly submitted bids shall be publicly "opened" and read aloud into the public record following the closing of the acceptance period for the construction of: 2018 Joint and Crack Sealing Project City of Pearland, Texas BID NO.: 0818-59 A non-mandatory pre-bid conference will be held at the City of Pearland City Hall Annex at 3523 Liberty Drive, Pearland, Texas 77581 at 10:00 a.m. on Thursday, August 30, 2018. This project involves furnishing and placing hot poured joint and crack sealant for various concrete pavement streets and asphalt pavement streets within the City of Pearland, as well as all labor, equipment, materials, and incidentals required for the project. 07-2017 00100- 1 of 3 CITY OF PEARLAND INVITATION TO BID Upon award of a contract, the successful Bidder will be required to utilize the City's web based project management software, "Pro-Trak" for the administration of the construction project, including but not limited to, all transmittals and material submittals, RFI's, RFC's, Change Orders, Applications for Payment and all project communications with the City, its Construction Manager and Engineer. This system has certain hardware, internet access and operation requirements that form the basis for all project communications, documentation and records for the project. For more information, see INSTRUCTIONS TO BIDDERS, Section 00200. Electronic Bid Documents: including Contract Documents, Plans and Technical Specifications are available for download on the City's Website at: https://pearland.ionwave.net/Login.aspx upon registration. The documents are NOT viewable without registration. These same documents are also available at the following locations. Amtek Plan Room (713) 956-0100 4001 Sherwood Houston, TX 77092 The Associated General Contractors of America, Inc. (713) 334-7100 2400 Augusta, Suite 350 Houston, TX 77057 Virtual Builders Exchange (832) 613-0201 7035 W. Tidwell Building J, Suite 112 Houston, TX 77092 McGrawHill Construction—Dodge Reports 1-800-393-6343 No plan fees or deposits are required for plans and bid documents obtained through the City's E- bid System. BIDDERS MUST REGISTER AS A SUPPLIER ON THE CITY'S E-BID SYSTEM IN ORDER TO SUBMIT A BID EVEN IF BID DOCUMENTS ARE OBTAINED VIA ONE OF THE PLAN HOUSES. Bidders accept sole responsibility for downloading all of the required documents, plans, specifications bid forms and addenda required for bidding. No bid may be withdrawn or terminated for a period of ninety (90) days subsequent to the bid opening date without the consent of the City of Pearland. Unless otherwise expressly provided herein, all references to"day(s)" shall mean calendar day(s). Bid Security and Bonds: Bid Security in the form of Cashier's Check, Certified Check, or Bid Bond payable to the City of Pearland in the amount of 5% of the total base bid price must accompany each proposal. Bidders submitting bids electronically through the E-bid System shall scan and up-load a copy of the sealed Bid Bond as an attachment to their bid. Original documents for Bid Security shall be requested by the City from the lowest two bidders and delivered to the City's Purchasing Officer within 48 business hours of the Bid Opening. Bid Security shall be delivered to: Office of City Purchasing, Finance Department, City Hall Annex, 3523 Liberty Drive, Pearland, Texas 77581. 07-2017 00100-2 of 3 CITY OF PEARLAND INVITATION TO BID The successful Bidder must furnish Performance and Payment Bonds as required by Chapter 2253 of the Texas Government Code or other applicable law, as amended, upon the form included in the Contract Documents, in the amount of one hundred percent (100%) of the contract price, such bonds to be executed by a corporate surety duly authorized to do business in the State of Texas, and named in the current list of"Treasury Department Circular No. 570", naming the City of Pearland, Texas as Obligee. Additionally, the successful bidder shall be required to provide a one year Maintenance Bond for the improvements installed as part of this work, as provided in the Special Conditions of Agreement. Equal Opportunity: All responsible bidders will receive consideration for award of contract without regard to race, color,religion, sex, or national origin. Nondiscrimination: The City, in accordance with Title VI of the Civil Rights Act of 1964, 78 Stat. 252, 42 U.S.C. 2000d to 2000d-4 and Title 49, Code of Federal Regulations, Department of Transportation, Subtitle A, Office of the Secretary, Part 21, Nondiscrimination in Federally- Assisted programs of the Department of Transportation issued pursuant to such Act, hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, or national origin in consideration for an award. DBE/SBE Goal: The Disadvantaged Business Enterprise (DBE) goal for this project is 0%. The Small Business Enterprise (SBE) goal for this project is 0%. DBEs and SBEs selected must be TxDOT approved. Race neutral participation is encouraged and can be achieved through various supplier and subcontracting opportunities. Selection Criteria: The Contract is to be awarded on the basis of Lowest Responsible Bidder. In identifying this criteria the City will consider: 1) lowest total bid price for all work listed and specifically requested, including but not limited to: Base Bid, Extra Work items and selected Alternates. The City of Pearland reserves the right to award a contract based on any combination of the above considered to be in its best interests or to reject any or all bids. A bid that has been "opened" may not be changed for the purposes of correcting an error in the bid price. Young Lorfing, TRMC City Secretary, City of Pearland First Publication date August 22, 2018 Second Publication date August 29, 2018 07-2017 00100-3 of 3 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS Section 00200 INSTRUCTIONS TO BIDDERS 1. Defined Terms 1.1 The term "Owner" hereinafter is defined as the City of Pearland and is used interchangeably with the term"the City". Both terms are synonymous and refer to the City. 1.2 The term "Bidder"means one who submits a Bid Proposal directly to Owner, as distinct from a sub-bidder, who submits a bid to a Bidder. The term "Successful Bidder" means the lowest responsible Bidder to whom the Owner(on the basis of Owner's evaluation as hereinafter provided) makes an award. The term "Bid Documents" includes the Invitation to Bidders, Instructions to Bidders, the Bid Proposal, and the proposed Contract Documents (including all Addenda issued prior to receipts of bids). 1.3 The term"E-bid System" refers to the City's electronic bidding system. This is a web- based system that provides all Bid Documents electronically to potential Bidders and forms the pathway for interested Bidders to submit bids in response to advertisement and invitation. The term "e-bid" and/ or "electronic bid" means the Bidders' electronic response submitted on the electronic Bid Proposal to the Owner by way of the E-bid System. The terms "electronic bid" or "e-bid" are used inter-changeably to describe the above bid process to submit an authorized bid to the City in response to an Invitation to Bidders. 1.4 The term "Pro-Trak" means the City's web-based contract administration and construction records management system used by involved parties to administer the project. This system serves as the web accessed centralized information distribution hub for communications and document management, pay application processing and record retention for all project documentation. Operational instructions for this system will be issued to the successful Bidder at the pre-Construction Meeting. 1.5 All other definitions set out in the Contract Documents are applicable to terms used in the Bidding Documents. 1.6 Unless otherwise expressly provided herein, all references to "day(s)" shall mean consecutive calendar day(s). 2. Registration for E-bid System 2.1 The Owner's E-bid System is accessible via the City's web site at https://pearland.ionwave.net/Login.aspx. Bid documents can be viewed by simply selecting a specific project from the BID OPPORTUNITIES list and clicking on that project AFTER registration as a Supplier. Potential Bidders MUST REGISTER as a "Supplier" by clicking on the Supplier Registration button and completing the registration form. When prompted to add or remove commodity codes registrants must add the codes listed below: * Building Construction Services,New(Includes Maintenance and Repair Services) * Construction Services, General (Includes Maintenance and Repair Services) * Construction Services, Heavy(Includes Maintenance and Repair Services) * Construction Services, Trade(New Construction) 07-2017 00200- 1 of 8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS Select the appropriate Time Zone for the Bidder's location and whether that location observes Daylight Savings time. Complete the registration information providing all required contact information and establish password security for the E-bid System. Once complete, "suppliers" will receive emails notifying of bid opportunities. Downloading anv project bid data will automatically place the bidder's contact information on the list of plan holders list and the E-bid System will automatically send any and all updates, changes or addenda associated with that project. 2.2 The electronic Bid Proposal can only be submitted through this system. The form can be printed for Bidder's use, but the Bid Proposal MUST be submitted on the electronic form within the E-bid System. 2.3 Questions regarding use of the E-bid System may be directed by email to: ebids@pearlandtx.gov. 3. Copies of Bidding Documents 3.1 Complete sets of "electronic" Bidding Documents are available for download to registered Bidders at No Cost from the City's E-bid System at: https://pearland.ionwave.net/Login.aspx. Interested Bidders must register as a"Supplier"on this site in order to receive the Bid Documents, and all Addenda or other notifications of changes, including communications from the Owner or Engineer. All Bid Documents are available to download and print. 3.2 The Bidder accepts sole responsibility for ensuring that he obtains a full set of these documents by completing the registration and executing a full and complete download of the project documents. Downloading of Bid Documents automatically ensures receipt of any and all subsequent communications from the City or its Engineer. 3.2 Copies of Bidding Documents are available or may be viewed at any of the Plan Houses listed in the Invitation to Bidders. It is recommended that all interested Bidders,whether bidding directly to the Owner or Sub-bidders bidding to a Bidder, register as a Supplier and download the project Bid Documents. 3.3 Complete sets of Bidding Documents must be used in preparing Bid Proposals; neither Owner nor Engineer assumes any responsibility for errors or misinterpretations resulting from the use of incomplete sets of Bidding Documents including,but not limited to all Addenda issued prior to bid. 3.4 Owner and Engineer, in making copies of Bidding Documents available on the above terms, do so only for the purpose of obtaining Bid Proposals on the Work, and do not confer a license or grant for any other use. 4. Qualifications of Bidders 4.1 In determining to whom to award a contract, the City of Pearland may consider, in addition to the other selection criteria identified in section 16 of these Instructions to Bidders, the following Qualifications of Bidder, and each Bidder must be prepared to submit within two (2) days of Owner's request any or all of such Qualifications requested: 1) A brief narrative of previous experience of the Bidder with projects of a similar nature and scope; including a list of 5 representative projects completed by the Bidder of a similar nature 07-2017 00200-2of8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS and scope to the work covered by this proposed Contract. The references for the projects provided must include the cost of the project, Owner's name, Engineer or prime contact and telephone number; 2) A list, including owner name and project location, of on-going projects and contracts for construction of projects of the Bidder which are not yet substantially complete; 3) A list of proposed subcontractors and suppliers for the project being bid and the total value of work awarded to subcontractors as shown on the Subcontractors List Bid Form; 4)A list of name,address and telephone number of references for projects completed by Bidder; and 5)A Financial Statement of Bidder,consisting of the balance sheet and annual income statement of Bidder for the Bidder's last fiscal year end preceding the submission of the Bid Proposal, which has been audited or examined by an independent certified public accountant. The Financial Statement of Bidder shall be used to determine a Bidder's net working capital, which is defined as current assets less current liabilities. A Bidder's net working capital shall be considered evidence of the Bidder's ability to provide sufficient financial management of the project being bid. The Bidder's Financial Statement shall be clearly and conspicuously marked as "confidential", and shall be deemed and treated as confidential and excepted from the Public Information disclosure requirements of Texas Government Code Section 552.001 et seq., as such information, if released, would give advantage to a competitor or bidder, and/or would cause substantial competitive harm to Bidder. 5. Examination of Contract Documents and Site 5.1 It is the responsibility of each Bidder before submitting a Bid Proposal, to (a) examine the Bidding Documents thoroughly, (b) visit the site to become familiar with local conditions that may affect cost,progress,performance or furnishing of the Work, (c)consider federal, state and local laws and regulations that may affect cost, progress, performance or furnishing of the Work, (d)study and carefully correlate Bidder's observations with the Contract Documents, and (e) notify Engineer of all conflicts, errors, omissions or discrepancies in the Contract Documents,(f)to recognize and plan for use of the City's"Pro-Trak"software to administer the construction process and perform the work of the project. 5.2 Any reports of explorations and tests of conditions at the site which have been utilized by the Engineer in preparation of the Contract Documents will be made available to Bidders for review,but such reports are not part of the Contract Documents. Bidder may not and should not rely upon the accuracy of the data contained in such reports, interpretations or opinions contained therein, or the completeness thereof, for the purposes of bidding or construction. 5.3 Information and data reflected in the Contract Documents with respect to underground utilities, equipment or other underground facilities at or contiguous to the site is based upon information and data furnished to Owner and Engineer by owners of such underground facilities or others, and Owner does not assume responsibility for the accuracy or completeness thereof. 5.4 Before submitting a Bid Proposal, each Bidder will, at Bidder's own expense, make or obtain any additional examinations,investigations,explorations,tests and studies and obtain any additional information and data which pertain to the physical conditions (surface, subsurface and underground facilities) at or contiguous to the site or otherwise which may affect cost, 07-2017 00200-3 of 8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS progress, performance or furnishing of the Work and which Bidder deems necessary to determine its Bid Proposal prices for performing and furnishing the Work in accordance with the Contract Time, Contract Price and other terms and conditions of the Contract Documents. 5.5 On request in advance, Owner will provide each prospective Bidder access to the site to conduct such explorations and tests as each prospective Bidder deems necessary for submission of a Bid Proposal. Prospective Bidders shall fill all holes, clean up and restore the site to its former condition upon completion of such explorations. 5.6 The lands upon which the Work is to be performed, rights-of-way and easements for access thereto and other lands designated for use by Contractor in performing the Work are identified in the Contract Documents. All additional lands, access thereto or contractual arrangements for use by the Contractor required for temporary construction facilities or storage of materials and equipment are to be provided by Contractor. Easements for permanent structures or permanent changes in existing structures are to be obtained and paid for by Owner unless otherwise provided in the Contract Documents. 5.7 The submission of a Bid Proposal will constitute an incontrovertible representation by Bidder that Bidder has complied with every requirement of this Article 4, that without exception the Bid Proposal is premised upon performing and furnishing all of the Work required by the Contract Documents and such means, methods, techniques, sequences or procedures of construction as may be indicated in, required by or reasonably inferred from the Contract Documents, and that the Contract Documents are sufficient in scope and detail to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. 6. Interpretations and Addenda 6.1 All questions about the meaning or intent of the Contract Documents are to be directed to Engineer. Interpretations or clarifications considered necessary by Engineer in response to such questions will be issued by Addenda delivered or transmitted by electronic means to all registered Bidders in the City's E-bid System. Questions received less than five (5) days prior to the date for opening of Bid Proposals may not be answered. Only questions answered by formal written Addenda will be binding. Oral and other interpretations or clarifications will be without legal effect. 6.2 Addenda may also be issued to modify the Bidding Documents as deemed advisable by Owner or Engineer. Addenda will automatically be made available to all registered Bidders that have downloaded Bid Documents from the City's E-bid System. 7. Bid Security 7.1 Each Bid Proposal must be accompanied by bid security made payable to Owner in an amount of five percent (5%) of the Bidder's maximum Bid Proposal price, in the form of a certified check, cashier's check or a Bid Bond("Bid Security"). 7.2 Bidders submitting bids through the E-bid System shall scan and up-load a copy of their Bid Security(sealed Bid Bond,Certified Check or Cashier's Check) as an attachment to their electronic bid. Original documents for Bid Security shall be requested by the City from the lowest two bidders and delivered to the City's Purchasing Officer within 48 business hours of 07-2017 00200-4 of 8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS the Bid Opening. Bid Security shall be delivered to: Office of City Purchasing, City Hall Annex, 3523 Liberty Drive, Pearland, Texas 77581. 7.3 The Bid Security of the Successful Bidder will be retained until such time as Bidder has executed the Standard Form of Agreement,and furnished the required Performance and Payment Bonds, whereupon the Bid Security of both bidders will be returned. If the Successful Bidder fails to execute and deliver the Standard Form of Agreement and furnish the required performance and payment bonds within ten (10) days after the Notice of Award, Owner may annul the Notice of Award and shall be entitled to make a claim against the Bid Security. The Bid Security of other Bidders will be retained until the Contract is awarded and the Standard Form of Agreement becomes effective, or all bids are rejected, whereupon Bid Security furnished by all such Bidders will be returned. 8. Contract Time 8.1 The number of days in which the Work is to be Substantially Completed, as set forth in the Bid Proposal form and the Standard Form of Agreement, subject to such extension of time as may be due under the terms and conditions of the Contract Documents ("Contract Time"). All references to "time"or"days" shall be interpreted as consecutive calendar days. 9. Liquidated Damages and Early Completion Bonus 9.1 Provisions for liquidated damages and early completion bonus,if any,are set forth in the Standard Form of Agreement. 10 Substitute or"Or-Equal" Items 10.1 The Contract, if awarded, will be on the basis of the selected materials and equipment described in the Plans or specified in the Specifications without consideration of possible substitute or "or-equal" items. Whenever it is indicated in the Plans or specified in the Specifications that a substitute or"or-equal" item of material or equipment may be furnished or used by the Contractor if acceptable to Engineer, application for such acceptance will not be considered by Engineer until after the Agreement becomes effective. All "or-equal" references shall be interpreted to mean "or approved equal". The procedure for submission of any such application by Contractor and consideration by Engineer is set forth in the Contract Documents. 11. Bid Form 11.1 The Bid Proposal form (Section 00300 — Bid Proposal) is included with the Bidding Documents when downloaded. This Document must be printed and signed, as required below, and then uploaded as an Attachment to the Bid. All E-bids must be submitted on the City's official E-bid System Bid Proposal document. All blanks on the Bid Proposal form must be completed or filled in. The Bidder shall bid all Alternates, if any. Incomplete Bid Proposals may be cause for rejection. 11.2 Bid Proposals by corporations must be executed in the corporate name by the president or a vice-president(or other corporate officer accompanied be evidence of authority to sign)and the corporate seal must be affixed and attested by the secretary or an assistant secretary. The 07-2017 00200-5 of 8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS corporate address and state of incorporation must be shown below the signature. Once executed the document is to be uploaded as an attachment to the Bid. 11.3 Bid Proposals by partnerships must be executed in the partnership name and signed by a general partner, whose title must appear under the signature, and if a corporate general partner, executed as required above for corporations and the official address of the partnership must be shown below the signature. All names must be typed or printed below the signature. Once executed the document is to be uploaded as an attachment to the Bid. 11.4 The Bidder shall acknowledge receipt of all Addenda (the number of which must be filled in on the Bid Proposal form). 11.6 The address and telephone number for communications regarding the Bid Proposal must be shown on the Bid Proposal form. 12. Submission of Bid Proposals 12.1 The place, date and/or time designated for opening Bid Proposals may be changed in accordance with applicable laws, codes and ordinances. Any such changes to the Bid Schedule shall be made by Addenda. 12.2 Electronic Bids shall be submitted per the requirements, instructions, terms and conditions as stated in the registration and submittal instructions of the City's E-bid System electronic bidding software. All Bidders utilizing this system MUST register as a potential supplier, (Bidder). E-Bids are submitted directly via the City's Web based system located at https://pearland.ionwave.net/Lo gin.aspx. Bid Proposals submitted after the bid date and time will be rejected. 13. Modification and Withdrawal of Bid Proposals 13.1 Prior to submission, E-bid Bid Proposals may be modified or withdrawn without prejudice. 13.2 Once submitted, Bid Proposals may only be modified by an appropriate document duly executed (in the manner that a Bid Proposal must be executed) and delivered to Office of City Purchasing, City Hall Annex, 3523 Liberty Drive, Pearland, Texas 77581 and submitted any time prior to the opening of Bid Proposals. 13.3 A Bidder may not modify or withdraw its Bid Proposal by facsimile or verbal means. A withdrawn Bid Proposal may be resubmitted prior to the designated time for opening Bid Proposals. No bid may be withdrawn or terminated for a period of ninety(90) days subsequent to the bid opening date without the consent of the City of Pearland. 13.4 If, within twenty-four(24)hours after Bid Proposals are opened, any Bidder files a duly signed, written notice with Owner and promptly thereafter demonstrates to the reasonable satisfaction of Owner that there was a material mistake in the preparation of its Bid Proposal, that Bidder may request to withdraw its Bid Proposal and the bid security may be returned or,at the discretion of the Owner, Owner may make a claim against the bid security. Thereafter, that 07-2017 00200-6 of 8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS Bidder will be disqualified from further bidding on the Project to be provided under the Contract Documents. 14. Opening of Bid Proposals 14.1 Bid Proposals will be opened and(unless obviously non-responsive)read aloud publicly. An abstract of the amounts of the base Bid Proposals and major alternates (if any)will be made available to Bidders after the opening of Bid Proposals. Bid Proposals, in their entirety, shall be open for public inspection after the contract is awarded, with the exception of any trade secrets or confidential information contained therein, provided Bidder has expressly identified any specific information contained therein as being trade secrets or confidential information. 15. Bid Proposals to Remain Subject to Acceptance 15.1 All Bid Proposals will remain subject to acceptance for ninety(90) days after the day of the Bid Proposal opening, but Owner may, in its sole discretion, release any Bid Proposal and return the bid security prior to that date. 16. Award of Contract 16.1 Owner reserves the right to reject any and all Bid Proposals, to waive any and all informalities not involving price, time or changes in the Work and to negotiate contract terms with the Successful Bidder. Owner may reject a bid as non-responsive if: 1) Bidder fails to provide required Bid Security; 2) Bidder improperly or illegibly completes or fails to complete all information required by the Bidding Documents; 3) Bidder fails to sign the Bid Proposal or improperly signs the Bid Proposal; 4) Bidder qualifies its Bid Proposal; 5) Bidder tardily or otherwise improperly submits its Bid Proposal; 6) Bidder fails to submit the Qualifications of Bidder as required under section 4 of these Instructions to Bidders; or 7) Bid Proposal is otherwise non-responsive. Contracts are awarded on the basis of one of the following criteria: A)provision of the "Best Value"or B) Lowest Responsible Bidder 16.2 Best Value. In determining the best value for the Owner, and in determining to whom to award a contract, Owner may consider: 1) purchase price; 2) reputation of the Bidder and Bidder's goods or services;3)quality of Bidder's goods or services;4)extent to which the goods or services meet the Owner's needs; 5) Bidder's past relationship with the Owner; 6)impact on the ability of Owner to comply with laws and rules relating to contracting with historically underutilized businesses and nonprofit organizations employing persons with disabilities; 7) total long-term cost to Owner to acquire Bidder's goods or services; 8) the Qualifications of Bidder; and 9) any other relevant criteria specifically listed in the Bidding Documents. A contract to be awarded to the Bidder offering the Best Value may be let on either a lump sum basis or a unit cost basis dependent on the Bid Proposal format. 16.3 Lowest Responsible Bidder. In determining Lowest Responsible Bidder, Owner will consider: Lowest Total Bid price for all work including Base Bid, Extra Work and Alternates, if any, and any other cost criteria. Additional evaluation criteria may include: the Qualifications of the Bidders, whether or not the Bid Proposals comply with the prescribed requirements, and such alternates,unit prices and other data, as may be requested in the Bid Proposal form or prior 07-2017 00200-7of8 CITY OF PEARLAND INSTRUCTIONS TO BIDDERS to the Notice of Award. Discrepancies in the multiplication of units of Work and unit prices will be resolved in favor of the unit prices. Discrepancies between the indicated sum of any column of figures and the correct sum thereof will be resolved in favor of the correct sum. A contract to be awarded to the Lowest Responsible Bidder may be let on either a lump sum basis or a unit cost basis dependent on the Bid Proposal format. Acceptance of any and all bids may be conditioned on compliance with the requirement for attendance of the mandatory pre-bid meeting. 16.4 In either case, Owner may conduct such investigations as Owner deems necessary to assist in the evaluation of any Bid Proposal and to establish the responsibility,qualifications and financial ability of Bidders, proposed Subcontractors, suppliers and other persons and organizations to perform and furnish the Work in accordance with the Contract Documents, to Owner's satisfaction, within the Contract Time. 16.5 Each Bidder agrees to waive any claim it has or may have against the Owner, the Professional/Engineer, and their respective employees, arising out of or in connection with the administration, evaluation, or recommendation of any bid. 17. Contract Security 17.1 When the Successful Bidder delivers the executed Standard Form of Agreement to Owner, it must be accompanied by the Performance, Payment, Maintenance and Surface Correction Bonds required by the Contract Documents. Bonds may be on the forms provided herein or an equal form containing no substantive changes, as determined by Owner. 18. Signing of Agreement 18.1 When Owner gives a Notice of Award to the Successful Bidder, it will be accompanied by the required number of unsigned counterparts of the Standard Form of Agreement, and the required Performance and Payment Bond forms. Within ten (10) days thereafter Contractor shall sign and deliver the required number of counterparts of the Standard Form of Agreement to Owner with the required Bonds. Within ten (10) days thereafter, Owner shall deliver one fully signed counterpart to Contractor. There shall be no contract or agreement between Owner and the Successful Bidder until proper execution and attestation of the Standard Form of Agreement by authorized representatives of the Owner. 19. Pre-bid Conference 19.1 A pre-bid conference will be held as indicated in the Invitation to Bid. 20. Retainage 20.1 Provisions concerning retainage are set forth in the Contract Documents. END OF SECTION 07-2017 00200-8 of 8 CITY OF PEARLAND BID PROPOSAL Section 00300 BID PROPOSAL Part A Date: 9/6/2018 Bid of Main Lane Industries, Ltd. , an . . $ . a partnership consisting of mc2 civil,Inc.&Main Lane Management LLC , for the construction of: 2018 Joint and Crack Sealing Project City of Pearland, Texas BID NO.: 0818-59 (Submitted in Electronic format) To: The Honorable Mayor and City Council of Pearland City of Pearland 3519 Liberty Drive Pearland, Texas 77581 Pursuant to the published Invitation to Bidders, and Instructions to Bidders, the undersigned Bidder hereby proposes to perform all the work and furnish all necessary superintendence, labor, machinery, equipment, tools and materials, and whatever else may be necessary to complete all the work described in or reasonably inferable from the Contract Documents for the construction of the 2018 Joint and Crack Sealing Project with all related appurtenances, complete, tested, and operational, in accordance with the Plans and Specifications prepared by the Engineer, ARKK Engineers LLC, 713-400-2755, Douglas Bradford, P.E., for the unit prices or applicable prices set forth in Exhibit"A", the electronic bid form as contained in the City's E-bid system, which, once fully executed and submitted shall constitute a legal and executable proposal from the Bidder. It is understood that, in the event any changes are ordered on any part of the Work, the applicable unit prices bid shall apply as additions to or deductions from the total prices for the parts of the Work so changed. The Bid Security required under the Instructions to Bidders is included and has been uploaded as an attachment within the E-bid system and, that a fully executed, signed and sealed hard copy has been delivered to the Office of City Purchasing, Finance Department, City Hall Annex, 3523 Liberty Drive, Pearland, Texas 77581. The Bidder agrees to submit to the Owner the Qualifications of Bidder, including the Financial Statement of Bidder, as required by the Instructions to Bidders if requested to do so as a condition of the Bid review. The Bidder binds himself, upon acceptance of his proposal, to execute the Standard Form of Agreement and furnish an acceptable Performance and Payment Bond and One-Year Maintenance Bond, each in the amount of one hundred percent (100%) of the total Contract Price, according to the forms included in the Contract Documents, for performing and completing the said work within the time stated and for the prices stated in Part B of this proposal along with all required insurance in the required amounts. Bidder's Initial's/14- 07-2017 nitial's07-2017 00300- I of 2 CITY OF PEARLAND BID PROPOSAL The undersigned Bidder agrees to commence work within 10 days of the date of a written Notice to Proceed. It is understood that the Work is to be Substantially Complete within sixty (60) days after the date of the Notice to Proceed. Time for Substantial Completion shall begin on the date established by the Notice to Proceed. The Contractor will pay liquidated damages in the amount(s) specified in Document 00500 — Standard Form of Agreement, in the event the Work is not Substantially Complete within the Contract Time. The undersigned agrees that the amounts bid in this Bid Proposal will not be withdrawn or modified for ninety (90) days following date of Bid Proposal opening, or such longer period as may be agreed to in writing by the City of Pearland and Bidder. It is understood that in the event the Successful Bidder fails to enter into the Standard Form of Agreement and/or to furnish an acceptable Performance and Payment Bond and One-Year Maintenance Bond, each in the amount of one hundred (100) percent of the Contract Price, along with all required insurance in the stated amounts within ten (10) days of the Notice of Award, the Successful Bidder will forfeit the Bid Security as provided in the Instructions to Bidders. Unless otherwise expressly provided herein, all references to "day(s)" shall mean calendar day(s). The Bidder acknowledges that the following Addenda have been received. The modifications to the Bidding Documents noted therein have been considered and all costs thereto are included in the Bid Proposal prices. Addendum No.: 1 Date: 8/31/2018 Addendum No.: Date: Addendum No.: Date: Addendum No.: Date: Bidder hereby represents that the only person or parties interested in this offer as principals are those named. Bidder has not directly or indirectly entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding. Firm Name: Main Lane industries. Ltd. By: Anthony Colombo Title: President Address: 14 15 Luth, oaf.Suite 100_ Houston.Texas 77039 Ph. e No: 13)8.,- ATTEST: 318•-ATTEST: Anthony C•to (Seal, if Bidder is a Corporation) (Typed or •tint:, I •- ).- Vr Signature Date: 9/6,2018 END OF SECTION Bidder's Initial's: At 07-2017 00300-2 of 2 EXHIBIT'A'-BID FORM (Bid Form must be submitted electronically) Project Name:2018 Joint and Crack Sealing Project Bid No: 0818-59 Quantity UOM Description Spec Reference Unit Price Total PKI-10 1 Base Bid Base Bid Items Sealing of concrete pavement expansion joints as identified by the City(hot poured rubber-asphalt compound),including cleaning and preparation,complete in place, 4'25 5 �10 700 00 PKLN 1 1 Base Bid 4,400 IF the sum of: 02781 5 Sealing of concrete pavement control joints,construction joints and/or cracks as identified by the City(hot poured rubber-asphalt compound),Including cleaning 3.25 71,500.00 PKLN 1 2 Base Bid 22,000 LF and preparation,complete in place,the sum of: 02781 5 $ Sealing of asphalt pavement cracks as identified by the City(hot poured rubber- asphalt compound),including cleaning and preparation,complete in place,the sum 0.60 18,000.00 PKLN 1 3 Base Bid 30,000 IF of: 02781 S $ TOTAL BASE BID ITEMS: $108,200.00 Bid Form Page 1 of 1 CITY OF PEARLAND STANDARD FORM OF AGREEMENT Section 00500 STANDARD FORM OF AGREEMENT THIS AGREEMENT is by and between City of Pearland(hereinafter called OWNER or City) and Main Lane Industries, Ltd. (hereinafter called CONTRACTOR). OWNER and CONTRACTOR,in consideration of the mutual covenants hereinafter set forth, agree as follows: Article 1. WORK CONTRACTOR shall complete all work as specified or indicated in or reasonably inferable from the Contract Documents(hereinafter the"Work"). The Work is generally described as follows: 2018 Joint and Crack Sealing Project City of Pearland, Texas BID NO.: 0818-59 Article 2. ENGINEER The Work has been designed by Douglas Bradford,P.E.with ARKK Engineers,LLC located at 7322 Southwest Fwy., Suite 1040, Houston, TX 77074 who is hereinafter called ENGINEER and who is to assume all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract Documents in connection with completion of the Work in accordance with the Contract Documents. Article 3. CONTRACT TIME 3.1 The Work will be Substantially Complete (as defined in Article 1 of the General Conditions) within sixty (60) days (including weekends and holidays) from the date when the Contract Time commences to run as provided in paragraph 5.01 of the General Conditions (as revised in the Special Conditions if applicable), and completed and ready for Final Payment within seventy five (75) days from the date when the Contract Time commences to run. No work will be allowed on Sundays. 3.2 Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1 above,plus any extensions thereof allowed in accordance with Article 5 of the General Conditions. OWNER and CONTRACTOR also recognize the delays, expense, and difficulties involved in proving in a legal or arbitration preceding the actual loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay(but not as a penalty) CONTRACTOR shall pay OWNER three hundred dollars ($300.00) for each day that expires after the time specified in paragraph 3.1 for Substantial Completion until the Work is substantially complete. After Substantial Completion, if CONTRACTOR shall neglect, refuse or fail to complete the remaining Work 4-2015 00500- 1 of 7 CITY OF PEARLAND STANDARD FORM OF AGREEMENT within the time set out in the Certificate of Substantial Completion or any proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER three hundred dollars ($300.00) for each day that expires after the time specified in the Certificate of Substantial Completion for completion and readiness for Final Payment. 3.3 Inspection Time. Working hours for the Pearland Inspection personnel are from 7:30 a.m. to 4:30 p.m., Monday through Friday, excluding City approved holidays. The Contractor shall notify the OWNER of any required inspection overtime work at least 48 hours in advance and shall pay the overtime wages for the required City inspections. Article 4. CONTRACT PRICE 4.1 OWNER shall pay CONTRACTOR for completion of the Work in strict accordance with the Contract Documents in current funds $108,200.00 (the"Contract Price"). The Contract Price includes the Base Bid as shown in Document 00300 — Bid Proposal. Article 5. PAYMENT PROCEDURES CONTRACTOR shall submit Applications for Payment in accordance with Section 6.0 "Measurement and Payment" of the General Conditions. Application for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1 Progress Payments. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR's Application for Payment as recommended by ENGINEER as provided below. All progress payments will be on the basis of the progress of the Work and actual quantity of Work completed, in accordance with Article 6 "Measurement and Payment" of the General Conditions. 5.1.1 Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage or actual quantity of Work complete, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with the General Conditions. The OWNER shall make payment within 30 days of receipt of application for payment by the ENGINEER. 5.1.2 Each progress payment shall be less retainage as specified in Paragraph 6.06 of the General Conditions, and further less all previous payments and all further sums that may be retained by the OWNER under the terms of this Agreement. It is understood,however,that in case the whole work be near to completion and some unexpected and unusual delay occurs due to no fault or neglect on the part of the CONTRACTOR, the OWNER may upon written recommendation of the ENGINEER pay a reasonable and equitable portion of the retained percentage to the CONTRACTOR, or the CONTRACTOR at the OWNER's option,may be relieved of the obligation to fully complete the Work and, thereupon, the CONTRACTOR shall receive payment of the 4-2015 00500-2 of 7 CITY OFPEARLAND STANDARD FORM OF AGREEMENT balance due him under the contract subject only to the conditions stated under "Final Payment." 5.2 Final Payment. Upon final completion and acceptance of the Work in accordance with paragraph 6.09 of the General Conditions, OWNER shall pay the remainder of the Contract Price as recommended by ENGINEER as provided in said paragraph 6.09. Article 6. INTEREST Interest on any overdue payment from OWNER to CONTRACTOR shall be paid in accordance with the provisions of Chapter 2251.025 of the Texas Government Code, as amended. Article 7. CONTRACTOR'S REPRESENTATIONS In order to induce OWNER to enter into this Agreement CONTRACTOR makes the following representations: 7.1 CONTRACTOR has familiarized himself with the nature and extent of the Contract Documents, Work, site, locality, and all local conditions and Laws and Regulations that in any manner may affect cost,progress,performance,or furnishing of the Work. 7.2 CONTRACTOR has studied carefully all available surveys, assessments, reports of explorations, investigations, and tests of subsurface conditions and drawings of physical conditions of the site. Such technical reports and drawings are not Contract Documents, and Owner makes no representations or warranties as to the accuracy of such documents or information, or to whether or not they are complete, comprehensive, or all-inclusive. 7.3 CONTRACTOR has obtained and carefully studied (or assumes responsibility for obtaining and carefully studying) all such examinations,investigations,explorations, tests, reports, and studies (in addition to or to supplement those referred to in paragraphs 7.2 above) which pertain to the subsurface or physical conditions at or contiguous to the site or otherwise may affect the cost, progress, performance or furnishing of the Work, and CONTRACTOR assumes the risk of such subsurface and physical conditions, and shall furnish the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents; and no additional examinations, investigations, explorations, tests, reports, and studies or similar information or data are or will be required by CONTRACTOR for such purposes. 7.4 CONTRACTOR has reviewed and checked all information and data shown or indicated on the Contract documents with respect to existing underground facilities at or contiguous to the site and assumes responsibility for the accurate location of said underground facilities. No additional examinations, investigations, explorations, tests, reports, studies or similar information or data in respect of said underground facilities are or will be required by CONTRACTOR in order to perform 4-2015 00500-3 of 7 CITY OF PEARLAND STANDARD FORM OF AGREEMENT and finish the Work at the Contract Price,within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. 7.5 CONTRACTOR has correlated the results of all such observations, examinations, investigations, explorations, tests, reports, and studies with the terms and conditions of the Contract Documents. 7.6 CONTRACTOR has given ENGINEER written notice of all conflicts, errors or discrepancies in the Contract Documents of which Contractor knew or should have known, and CONTRACTOR shall perform the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents, including any written resolution of any such conflict, error or discrepancy by ENGINEER. In the event of a conflict that was not brought to the OWNER's or ENGINEER's attention prior to the bid, the CONTRACTOR is assumed to have bid the most expensive alternative. Article 8. CONTRACT DOCUMENTS The Contract Documents, which comprise the entire agreement between OWNER and CONTRACTOR concerning the Work, consist of the following, each of which are incorporated herein by reference: 8.1 Standard Form of Agreement(Section 00500). 8.2 Performance, Payment, and/or Maintenance Bonds (Sections 00610, 00611, and 00612). 8.3 General Conditions of Agreement (Section 00700), including Attachment No. 1 Workers' Compensation Insurance Coverage,Attachment No.2 Agreement for Final Payment and Contractor's Sworn Release, and Attachment No. 3 Owner's Insurance Requirements of Contractor. 8.4 Special Conditions of Agreement(Section 00800). 8.5 Instructions to Bidders and CONTRACTOR's Bid Proposal, including any Addenda referenced therein. 8.6 Technical Specifications for the Work. 8.7 The following, which may be delivered or issued after this Agreement becomes effective: Any Change Orders or other documents amending, modifying, or supplementing the Contract Documents in accordance with the General Conditions. There are no Contract Documents other than those listed above in this Article 8. The Contract Documents may only be amended, modified or supplemented as provided in the General Conditions. 4-2015 00500-4 of 7 CITY OF PEARLAND STANDARD FORM OF AGREEMENT Article 9. MISCELLANEOUS 9.1 Terms used in this Agreement which are defined in Section 1, "Definitions and Interpretations" of the General Conditions will have the meanings indicated in the General Conditions. 9.2 No assignment by a party hereto of any rights under or interests in the Contract Documents will be binding on another party hereto without the written consent of the party sought to be bound; and specifically but without limitation moneys that may become due and moneys that are due may not be assigned without such consent (except to the extent that the effect of this restriction may be limited by law), and unless specifically stated to the contrary in any written consent to an assignment, no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3 OWNER and CONTRACTOR each binds itself,its partners, successors, assigns and legal representative to the other party hereto, its partners, successors, assigns and legal representatives in respect of all covenants, agreements and obligations contained in the Contract Documents. 9.4 CONTRACTOR agrees to warranty the Work for a period of one (1) year from Substantial Completion against defects in materials and workmanship. CONTRACTOR agrees to repair or replace any defective work within this warranty period immediately unless such repairs require long lead time materials and equipment in which case CONTRACTOR shall provide an agreeable schedule for repairs at no additional cost to OWNER. 9.5 The Work will be completed according to the Contract Documents and in accordance with codes, ordinances, and construction standards of the City of Pearland, and all applicable laws, codes and regulations of governmental authorities. 9.6 In the event any notice period required under the Contract Documents is found to be shorter than any minimum period prescribed by applicable law, the notice period required shall be construed to be the minimum period prescribed by applicable law. 9.7 This Contract and the Contract Documents, insofar as they relate in any part or in any way to the Work undertaken therein, constitute the entire agreement between the parties hereto, and it is expressly understood and agreed that there are no agreements or promises by and between said parties, except as aforesaid, and that any additions thereto or changes shall be in writing. 9.8 The provisions of this Contract shall be applied and interpreted in a manner consistent with each other so as to carry out the purposes and the intent of the parties, but if for any reason any provision is unenforceable or invalid, such provisions shall be deemed severed from this Contract and the remaining provisions shall be carried out with the same force and effect as if the severed provision had not been part of this Contract. 4-2015 00500-5 of 7 CITY OF PEARLAND STANDARD FORM OF AGREEMENT 9.9 The headings of the paragraphs are included solely for the convenience of reference and if there is any conflict between the headings and the text of this Contract, the Contract text shall control. 9.10 The waiver of any breach hereof shall not constitute a waiver of any subsequent breach of the same or any other provision hereof. Failure by the OWNER in any instance to insist upon observance or performance by CONTRACTOR shall not be deemed a waiver by CONTRACTOR of any such observance or performance. No waiver will be binding upon OWNER unless in writing and then will be for the particular instance only. Payment of any sum by OWNER to CONTRACTOR with knowledge of any breach or default will not be deemed a waiver of such breach or default or any other breach or default. 9.11 The CONTRACTOR acknowledges that the OWNER(through its employee handbook) considers the following to be misconduct that is grounds for termination of an employee of the OWNER: Any fraud, forgery, misappropriation of funds, receiving payment for services not performed or for hours not worked, mishandling or untruthful reporting of money transactions, destruction of assets, embezzlement, accepting materials of value from vendors, or consultants, and/or collecting reimbursement of expenses made for the benefit of the OWNER. The CONTRACTOR agrees that it will not, directly or indirectly; cause an employee of the OWNER to engage in such misconduct. 9.12 The CONTRACTOR agrees to comply with Appendix A (attached) of the City of Pearland's Title VI Nondiscrimination Plan Assurances. 4-2015 00500-6 of 7 CITY OF PEARLAND STANDARD FORM OF AGREEMENT IN WITNESS WHEREOF, OWNER and CONTRACTOR have signed this Agreement in duplicate. One counterpart each has been delivered to OWNER and one to CONTRACTOR. This Agreement will be effective upon execution and attestati• by aut • •ed representatives of the City of Pearland and upon the following date: 4 / , 20_ OWNER: CON hiR: CITY OF RL 1 Fr 1 By: t'`_' kis de A. By: 1 Title: ��n � Title: A Ory Cp�,pnri,1p0, Pt'esiderL Date: /°—//',2) Date: 1140 I 1 I'6 (Corporate Seal) ATTEST ATTEST Address for giving notices Phone: Fax: Agent for service of process: END OF SECTION 4-2015 00500-7 of 7 Title VI Nondiscrimination Assurances APPENDIX A During the performance of this contract, the contractor, for itself, its assignees and successors in interest (hereinafter referred to as the "contractor") agrees as follows: (1) Compliance with Regulations: The contractor shall comply with the Regulations relative to nondiscrimination in Federally-Assisted programs of the Department of Transportation (hereinafter, "DOT') Title 49, Code of Federal Regulations, Part 21, as they may be amended from time to time, (hereinafter referred to as the Regulations), which are herein incorporated by reference and made a part of this contract. (2) Nondiscrimination: The contractor, with regard to the work performed by it during the contract, shall not discriminate on the grounds of race, color, or national origin in the selection and retention of subcontractors, including procurements of materials and leases of equipment. The contractor shall not participate either directly or indirectly in the discrimination prohibited by Section 21.5 of the Regulations, including employment practices when the contract covers a program set forth in Appendix B of the Regulations. (3) Solicitations for Subcontracts, including Procurements of Materials and Equipment: In all solicitations either by competitive bidding or negotiation made by the contractor for work to be performed under a subcontract, including procurements of materials or leases of equipment, each potential subcontractor or supplier shall be notified by the contractor of the contractor's obligations under this contract and the Regulations relative to nondiscrimination on the grounds of race, color, or national origin. (4) Information and Reports: The contractor shall provide all information and reports required by the Regulations or directives issued pursuant thereto, and shall permit access to its books, records, accounts, other sources of information, and its facilities as may be determined by the Sub-Recipient or the Federal Highway Administration to be pertinent to ascertain compliance with such Regulations, orders and instructions. Where any information required of a contractor is in the exclusive possession of another who fails or refuses to furnish this information the contractor shall so certify to the Sub-Recipient, or the Federal Highway Administration as appropriate, and shall set forth what efforts it has made to obtain the information. (5) Sanctions for Noncompliance: In the event of the contractor's noncompliance with the nondiscrimination provisions of this contract, the Sub-Recipient shall impose such contract sanctions as it or the Federal Highway Administration may determine to be appropriate, including, but not limited to: (a) withholding of payments to the contractor under the contract until the contractor complies, and/or (b) cancellation, termination or suspension of the contract, in whole or in part. (6) Incorporation of Provisions:The contractor shall include the provisions of paragraphs (1) through (6) in every subcontract, including procurements of materials and leases of equipment, unless exempt by the Regulations, or directives issued pursuant thereto. The contractor shall take such action with respect to any subcontract or procurement as the Sub-Recipient or the Federal Highway Administration may direct as a means of enforcing such provisions including sanctions for non-compliance. Provided, however, that, in the event a contractor becomes involved in, or is threatened with, litigation with a subcontractor or supplier as a result of such direction, the contractor may request the Sub-Recipient to enter into such litigation to protect the interests of the Sub-Recipient, and, in addition, the contractor may request the United States to enter into such litigation to protect the interests of the United States. House Bill 89 Verification Anthony Colombo (Person name), the undersigned representative (hereafter referred to as "Representative") of Main Lane Industries, Ltd. (company or business name, hereafter referred to as "Business Entity"), being an adult over the age of eighteen (18) years of age, after being duly sworn by the undersigned notary, do hereby depose and affirm the following: 1 . That Representative is authorized to execute this verification on behalf of Business Entity; 2. That Business Entity does not boycott Israel and will not boycott Israel during the term of any contract that will be entered into between Business Entity and the City of Pearland; and 3. That Representative understands that the term "boycott Israel" is defined by Texas Government Code Section 2270.001 to mean refusing to deal with, terminating business activities with, or otherwise taking any action that is intended to penalize, inflict economic harm on, or limit commercial relations specifically Ny.it1i .rael or w' a .person or entity doing business in Israel or in an Israeli-controlled -rrito' b/' do: • clude an action made for ordinary business purposes. f SIGNATURE OF REPRESENTATIVE SUBSCRIBED AND SWORN TO BEFORE ME, the undersigned authority, on this 6 day of September , 2018 . ,:,.V pL/ci ALEXANDRA EVANS :Notary Public, State of Texas Notary Public ='• c? Comm. Expires 05-04-2022 7 t. 2;>‘‘ Notary ID 131555155 CITY OF PEARL/GNI) PERFORMANCE BOND Section 00610 PERFORMANCE BOND Bond No 35BCSHZ1657 STATE OF TEXAS COUNTY OF BRAZORIA § KNOW ALL MEN BY THESE PRESENTS: That Main Lane Industries Ltd, of the City of Houston, County of Hams, and State of Texas, as principal, and Hartford Fire Insurance Company authorized under the laws of the State of Texas to act as surety on bonds for principals, are held and firmly bound unto City of Pearland as Obligee (Owner), in the penal sum of S 108.200.00 for the payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators, executors, successors, and assigns, jointly and severally, by these presents: WHEREAS,the Principal has entered into a certain written contract with the Owner,effective as of the day of 20 , (the "Contract") to commence and completc the construction of certain improvements described as follows: 2018 Joint and Crack Sealing Project City of Pearland,Texas BID NO.: 0818-59 which Contract,including the Contract Documents as defined therein,is hereby referred to and made a pan hereof as fully and to the same extent as if copied at length herein. NOW THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall faithfully perform said Contract Work and shall in all respects duly and faithfully observe and perform all and singular the covenants, conditions, and agreements in and by said Contract agreed and covenanted by the Principal to be observed and performed, and according to the true intent and meaning of said Contract and Contract Documents, then this obligation shall be void; otherwise to remain in full force and effect', PROVIDED, HOWEVER,that this bond is executed pursuant to the provisions of Chapter 2253 of the Texas Government Code as amended and all liabilities on this bond shall be detemiined in accordance with the provisions of said Statute to the same extent as if it were copied at length herein Surety, for value received, stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the Work performed thereunder, or the plans, specifications, or drawings accompanying the same, shall m any way affect its obligation on this bond, and it does hereby waive notice of any such change, extension of time, alteration or addition to the terms of the Contract,or to the Work to be performed thereunder, 1212007 00610- 1 n12 CITY OF PEARLAND PERFORMANCE BOND IN WITNESS WHEREOF,the said Principal and Surety have signed and sealed this instrionent this 28th day of September lo 18 Principal- S er, Main Lane ndu: .., td. Hartford Fire Insurance Company 111 By, Titte J\ I°Min PreSt'• '11*- Title: Susan L. Small, Attorney-In-Fact Address Address: 14115 Luthe Rd., Suite 100 One Hartford Plaza,T-4 Houston,TX 77039 Hartford, CT 06115 Telephone, (713)896-3141 Telephone, (248)822-6456 Fax (713)896-3142 Fax• (248)822-6450 NOTICE: THE ADDRESS OF THE SURETY COMPANY TO WHICH ANY NOTICE OF CLAIM SHOULD BE SENT MAY BE OBTAINED FROM THE TEXAS DEPARTMENT OF INSURANCE BY CALLING ITS TOLL-FREE TELEPHONE NUMBER; 1-80-252-3439, END OF SECTION 124'2007 4)06:042 or 2 CITY OF PEARLAND PAYMENT BOND Section 0061,1 PA YMEN1' BOND Bond No. 35BCSHZ1657 STATE OF TEXAS COUNTY OF BRAZORIA § KNOW ALL MEN BY THESE PRESENTS: ThatMgi in Lane Industries, Ltd. of the City of Houston, County of 'Harris, and State of Texas, as principal, and Hartford Fire Insurance Company authorized under the laws of the State of Texas to act as surety on bonds for principals, are held and firmly bound unto City of Pearland as Obligee (Owner), in the penal sum of$ I08.200,00 for the payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators, executors, successors, and assigns, jointly and severally, by these presents: WHEREAS,the Principal has entered into a certain written contract with the Owner,effective as cif the day of , 20 (the "Contract") to commerce and complete the construction of certain improvements described as follows. 2018 Joint and Crack Sealing Project City of Pea rhi rid,Texas BID NO,: 0818-59 which Contract, including the Contract Documents as defined therein,is hereby referred to and made a part hereof as fully and to the same extent as if copied at length herein, NOW THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall pay all claimants supplying labor or material to him or a subcontractor in the prosecution of the Work provided for in said Contract,then,this obligation shall be void;othetwise to remain in full force and effect, PROVIDED, HOWEVER, that this bond is executed pursuant to the provisions of Chapter 2253 of the Texas Government Code as amended and all liabilities on this bond shall be determined in accordance with the provisions of said Statute to the same extent as if it were copied at length herein Surety, for value received, stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the Work performed thereunder, or the plans, specifications, or drawings accompanying the sarre, shall in any way affect its obligation on this bond, and it does hereby waive notice of any such change,extension of rime, alteration or addition to the terms of the Contract,or to the Work to be performed thereunder. 07/7.006 0061i - I (.4'2 CITY OF PE4RL4ND PAYMENT BOND IN WITNESS WHEREOF,the said Principal and Surety have signed and sealed this instrument this 28th day of September 1018 Principal: Surety: Main Lane I • es ' d. Hartford Fire Insurance Company - • le By: B Title: ktiknomt icyr400tPr?sA Let- Title; SusanL. Small,Attorney-m-fact Address Address; 14115 Luthe Rd., Suite 100 One Hartford Plaza, T-4 Houston, TX 77039 Hartford,CT 06115 Telephone: (713)896-3141 Telephone,J248)822-6456 Fax: (713)896-3142 Fax, (248)822-6450 NOTICE: THE ADDRESS OF THE SURETY COMPANY TO WHICH ANY NOTICE OF CLAIM SHOULD BE SENT MAY BE OBTAINED FROM THE TEXAS DEPARTMENT OF INSURANCE BY CALLING ITS TOLL-FREE TELEPHONE NUMBER; 1-800-252-3439. END OF SECTION 07-2n% 00611 -201'2 CITY OF PEA NI) ONE-YEAR MAINTENANCE BOND Section 00612 ONE-YEAR MAINTENANCE BOND Bond No. 35BCSHZ1657 STATE OF TEXAS COUNTY OF BRAZORIA § KNOW ALL MEN BY THESE PRESENTS: That Mani Lane Itidustries, Ltd. of the City of Houston, County of Harris, and State of Texas, as principal, and Hartford Fire Insurance Company authorized under the laws of the State of Texas to act as surety on bonds for principals, are held and firmly bound unto City of Pearland as Obligee (Owner), in the penal sum of S 108,200,00 for the payment whereof, the said Principal and Surety bind themselves, and their heirs, administrators, executors, successors, and assigns, jointly and severally, by these presents WHEREAS, the Principal has entered into a certain written contract with the Owner,effective as of the day of , 20 (the "Contract") to commence and complete the construction of certain improvements described as follows; 2018 Joint and Crack Sealing Project City of Pearland,Texas BID NO.: 0818-59 which Contract is hereby referred to and made a part hereof as fully and to the same extent as if copied at length herein. NOW THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, that if the said Principal shall faithfully correct all such work not in accordance with the Contract Documents discovered within the one-year period from the date of substantial completion, then this obligation shall be void; otherwise to remain in full force and effect; PROVIDED, HOWEVER., that this bond is executed pursuant to the provisions of Chapter 2253 of the Texas Government Code as amended and all liabilities on this bond shall be determined in accordance with the provisions of said Statute to the same extent as if it were copied at length herein. Surec:y, for value received, stipulates and agrees that no change, extension of time, alteration or addition to the terms of the contract, or to the work performed thereunder, or the plans, specificaiious, or drawings accompanying the same, shall in any way affect its obligation on this bond, and it does hereby waive notice of any such change,extension of time,alteration or addition to the terms of the contract, or to the work to be performed thereunder, 07,2006 iiO4).2• 1 of C/fl'aF PeARLAND ONE-YEAR MAINTENANCE BOND IN WITNESS WHEREOF,the said Principal and Surety have signed and sealed this instrument this 28th day of September , 20 18 Principal. i Surety: Main Lan ; strie ;1111111 Hartford Fire Insurance Company 'Alert . By: Title: i 4t.1 . t co, ,,,r , .., 4— Title: Susan L Small, Attorney-In-Fact _ Address. Address: _ igus Luthe Rd., Suite 100 One Hartford Plaza, T-4 ::: _ _- -: — Houston, TX 77039 Hartford,CT 06115 , . Telephone: (713)896-3141 Telephone- (248)822-6456 Fax: (713)896-3142 Fax' NOTICE: THE ADDRESS OF THE SURETY COMPANY TO WHICH ANY NOTICE OF CLAIM SHOULD BE SENT MAY BE OBTAINED FROM THE TEXAS DEPARTMENT OF INSURANCE BY CALLING ITS TOLL-FREE TELEPHONE NUMBER; 1400-252-3439. END OF SECTION ovviy, 006 12.2 of2 • Direct Inquiries/Claims to: THE HARTFORD POWER OF ATTORNEYBOND,T-12 HartfOne Hartford od Connecticut 06155 Bond.ClaimsCathehartford.com call:888-2663488 or fax:860-757-5835 KNOW ALL PERSONS BY THESE PRESENTS THAT: Agency Name: VTC INSURANCE GROUP Agency Code: 35-351225 1-1 Hartford Fire Insurance Company,a corporation duly organized under the laws of the State of Connecticut [-1 Hartford Casualty Insurance Company,a corporation duly organized under the laws of the State of Indiana ET Hartford Accident and Indemnity Company,a corporation duly organized under the laws of the State of Connecticut 1-1 Hartford Underwriters Insurance Company,a corporation duly organized under the laws of the State of Connecticut Twin City Fire Insurance Company,a corporation duly organized under the laws of the State of Indiana 11 Hartford Insurance Company of Illinois,a corporation duly organized under the laws of the State of Illinois 1-1Hartford Insurance Company of the Midwest,a corporation duly organized under the laws of the State of Indiana n Hartford Insurance Company of the Southeast,a corporation duly organized under the laws of the State of Florida having their home office in Hartford, Connecticut, (hereinafter collectively referred to as the"Companies")do hereby make, constitute and appoint, up to the amount of Unlimited : Susan L. Small of Farmington Hills MI, Jeffrey A. Chandler, Alan P. Chandler, Ian J. Donald, Wendy L. Hingson, Kathleen M. Irelan, Meagan L. Kress, Robert Trobec of TROY, Michigan their true and lawful Attorney(s)-in-Fact, each in their separate capacity if more than one is named above,to sign its name as surety(ies) only as delineated above by E, and to execute, seal and acknowledge any and all bonds, undertakings, contracts and other written instruments in the nature thereof,on behalf of the Companies in their business of guaranteeing the fidelity of persons,guaranteeing the performance of contracts and executing or guaranteeing bonds and undertakings required or permitted in any actions or proceedings allowed by law. In Witness Whereof,and as authorized by a Resolution of the Board of Directors of the Companies on May 6,2015 the Companies have caused these presents to be signed by its Senior Vice President and its corporate seals to be hereto affixed, duly attested by its Assistant Secretary. Further, pursuant to Resolution of the Board of Directors of the Companies,the Companies hereby unambiguously affirm that they are and will be bound by any mechanically applied signatures applied to this Power of Attorney. � , �r'SiW �� PJ`• ,+ttr .yJ � r:v,4� ,/.waWs� ,� '�f� of .rte_ c F 4 ��eRne.rr<'.i ►04 f +'ue--rtt sc'• • '�w'F \\\♦ ,..;4.1.11.1., � I ` 4 ••nNi► 1079 i! tDTi /X,v [713? "1/ John Gray,Assistant Secretary M.Ross Fisher,Senior Vice President STATE OF CONNECTICUT ss. Hartford COUNTY OF HARTFORD On this 5th day of January,2018,before me personally came M. Ross Fisher,to me known,who being by me duly sworn,did depose and say: that he resides in the County of Hartford, State of Connecticut; that he is the Senior Vice President of the Companies, the corporations described in and which executed the above instrument; that he knows the seals of the said corporations; that the seals affixed to the said instrument are such corporate seals;that they were so affixed by authority of the Boards of Directors of said corporations and that he signed his name thereto by like authority. NT.M4 y� 777 . A Ild Kathleen T.Maynard Notary Public CERTIFICATE My Commission Expires July 31,2021 I,the undersigned,Assistant Vice President of the Companies, DO HEREBY CERTIFY that the above and foregoing is a true and correct copy of the Power of Attorney executed by said Companies,which is still in full force effective as of §eptember 28th,2018 Signed and sealed at the City of Hartford. fry 14w4 d eww, • s'n ..4 f} • + r ?*d .w 1�1� •• > • � 121 o=4o' ;t-1 6,1.1 :;:if 4.40 9 7, N. ? I9T9 Kevin Heckman,Assistant Vice President POA 2018 IMPORTANT NOTICE AVISO IMPORTANTE To obtain information or make a complaint: Para obtener informacion o para someter una queja. You may contact your agent. Puede comunicarse con su agente. You may call Hartford Insurance Group at the toll free telephone number for information or to Usted puede Hamar al numero de telefono make a complaint at:, gratis de The Hartford Insurance Group para indormacion o para someter una queja al 1-800-392-7805 1-800-392-7805 You may also write to The Hartford: Usted tambien puede escribir a The Hartford. The Hartford Hartford Financial Products The Hartford 2 Park Avenue, 5th Floor Hartford Financial Products New York, New York 10016 2 Park Avenue, 5th Floor 1-212-277-0400 New York, New York 10016 1-212-277-0400 You may contact the Texas Department of Insurance to obtain information on companies, Puede comunicarse con el Departamento de coverages, rights or complaints at: Seguros de Texas para obtener informacion acerca de companies, coberturas, derechos o quejas al: 1-800-252-3439 1-800-252-3439 You may write the Texas Department of Puede escribir al Departamento de Seguros de Insurance Texas P.O. Box 149104 P.O. Box 149104 Austin, TX 78714-9104 Austin, TX 78714-9104 Fax Number(512)475-1771 Fax Number(512) 475-1771 Web: http://www.tdi.state,tx.us Web: http://www.tdi.state.tx.us E-mail: ConsumerProtection@tdi.state.tx.us E-mail: ConsumerProtection@tdi.state.tx.us PREMIUM OR CLAIMS DISPUTES: Should DISPUTAS SOBRE PRIMAS 0 RECLAMOS: you have a dispute concerning your Si tiene una disputa concerniente a su premium or about a claim you should prima o a un reclamo, debe comunicarse contact the agent first. If the dispute is not con su agente primero. Si no se resuelve la resolved, you may contact the Texas disputa, puede entonces comunicarse con Department of Insurance. el departamento (TDI). ATTACH THIS NOTICE TO YOUR POLICY: UNA ESTE AVISO A SU POLIZA: Este aviso This notice is for your information only and es solo para proposlto de informacion y no does not become a part or condition of the se convierte en parte o condicion del attached document. documento adjunto. F-4275-1,JTX4275-1 • HR 42 H006 00 0807 CITY OF PEARLAND PARTIAL WAIVER OF LIEN Section 00615 PARTIAL WAIVER OF LIEN AND PAYMENT AFFIDAVIT The undersigned contracted with City of Pearland to furnish in connection with certain improvements to real property located in the City of Pearland, TX and owned by the City of Pearland which improvements are described as follows: In consideration of Pay Estimate No. in the amount of$ the undersigned, on oath, states that all persons and firms who supplied labor and materials to the undersigned in connection with said Project will be fully paid within 30 days of the date of this document by the undersigned for such work through In consideration of the payment herewith made, the undersigned does fully and finally release and hold harmless the City of Pearland and its surety, if any, through the above date from any and all claims, liens, or right to claim or lien, arising out of this Project under any applicable bond, law or statue. It is understood that this affidavit is submitted to induce payment of the above sum and for use by the City of Pearland in assuring the Owner and others that all liens and claims relating to the said Project furnished by the undersigned are paid. Signature Printed Name&Title Company Name State of County of Subscribed and sworn to, before me, this day of , 20 My Commission Expires: Notary Public 5-12-12 AC CERTIFICATE CERTIFICATE OF LIABILITY INSURANCE DATE(MM/DD/YYYY) 10/4/2018 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED,the policy(ies)must be endorsed. If SUBROGATION IS WAIVED,subject to the terms and conditions of the policy,certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER CONTACT Jackie Wilson VTC Insurance GroupPHONE CA/C.No.EM►: (248)828-3377 (NC, No):(248)828-3741 Troy Office E-MAIL ADDRESS:jWilson@vtcins.com 1175 W. Long Lake Ste. 200 INSURER(S)AFFORDING COVERAGE NAIC# Troy MI 48098-4960 INsuRERA:Travelers Indemnity Company of CT 25682 INSURED INSURERB:Travelers Prop. Cas.Co. Of America 25674 Main Lane Industries, Ltd. INsuRERc:Texas Mutual Insurance Company 22945 14115 Luthe Rd INSURERD:Travelers Lloyds Insurance Co. 41262 Suite 100 INsuRERE:Endurance American Ins Company 10641 Houston TX 77039 INSURERF: COVERAGES CERTIFICATE NUMBER:2018-2019 REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR ADDL SUBR POLICY EFF POLICY EXP LTR TYPE OF INSURANCE INSD WVD POLICY NUMBER (MM/DD/YYYY) (MM/DD/YYYY) LIMITS X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 A CLAIMS-MADE X OCCUR DAMAGE TO RENTED 300,000 PREMISES(Ea occurrence) $ x XCU Included X Y CO1E958445 1/21/2018 1/21/2019 MED EXP(Any one person) $ 10,000 PERSONAL 8 ADV INJURY _ $ 1,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE $ 2,000,000 X POLICY X TER X LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER: Employee Benefits $ 1,000,000 AUTOMOBILE LIABILITY EO MBIINNEEDtSINGLE LIMIT $ 1,000,000 I X ANY AUTO BODILY INJURY(Per person) $ ALL AUTOSAUTOS OWNED SCHEDULED X y 8101E958445 1/21/2018 1/21/2019 BODILY INJURY(Per accident) $ X HIRED AUTOS X NON-OWNED PROPERTY DAMAGE AUTOS (Per accident) $ Underinsured motorist $ 1,000,000 X UMBRELLA LIAB X OCCUR EACH OCCURRENCE _ $ 2,000,000 A EXCESS LIAR CLAIMS-MADE AGGREGATE $ 2,000,000 DED X RETENTION$ 10,000 CUP1E958445 1/21/2018 1/21/2019 $ WORKERS COMPENSATION X PER STATUTE EERH- AND EMPLOYERS'LIABIUTY ,,/N R ANY PROPRIETOR/PARTNER/EXECUTIVE E.L.EACH ACCIDENT $ 1,000,000 OFFICER/MEMBER EXCLUDED? N N/A C (Mandatory In NH) y 0001282643 2/5/2018 2/5/2019 E.L.DISEASE-EA EMPLOYEE $ 1,000,000 If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY UMIT $ 1,000,000 U Installation Floater OT6608A09893A 1/21/2018 1/21/2019 Per Occurrence 500,000 E Excess Umbrella Exc30000045402 1/21/2018 1/21/2019 Per Occurrence/Aggregate 8,000,000 DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) 2018 Joint and Crack Sealing Project. Bid No. 0818-59. Where required by written contract, City of Pearland is add'l insured for General Liability (GL) as respects ongoing & completed operations on a primary & non-contributory basis and add'l insured with respects to Automobile liability. GL, Auto & Workers Comp policies include waiver of subrogation on behalf of City of Pearland as required by written contract and where allowed by law. Umbrella/Excess liability coverage follows form over GL, Auto & Employers Liability. Insurer will endeavor to mail 30 days written notice of cancellation to the certificate holder for Auto, GL, WC. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE City of Pearland THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN 3519 Liberty Drive ACCORDANCE WITH THE POLICY PROVISIONS. Pearland, TX 77581 AUTHORIZED REPRESENTATIVE Robert Trobec/V46 -- ©1988-2014 ACORD CORPORATION. All rights reserved. ACORD 25(2014/01) The ACORD name and logo are registered marks of ACORD INS025(201401) COMMENTS/REMARKS Leased/Rented: $350,000 Limit Travelers Insurance #QT6608A09893A 1/21/2018 - 1/21/2019 Scheduled Equipment: $6,770,626 Limit $7,500 Deductible. $25,000 Windstorm Deductible Travelers Insurance #QT6608A09893A 1/21/2018 - 1/21/2019 IOFREMARK COPYRIGHT 2000, AMS SERVICES INC. Additional Named Insureds Other Named Insureds levo Equipment LLC Additional Named Insured Main Lane Management LLC Additional Named Insured MC2 Development LLC Additional Named Insured MC2 Civil Inc. Additional Named Insured MC2 Oilfield Services LLC Additional Named Insured Norwest Services LLC Additional Named Insured 1 OFAPPINF(02/2007) COPYRIGHT 2007,AMS SERVICES INC Main Lane Industries Ltd. Policy Number: DT-CO-1 E958445-IND18 COMMERCIAL GENERAL LIABILITY 1/21/2018-1/21/2019 THIS ENDORSEMENT CHANGES THE POLICY.PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED - AUTOMATIC STATUS IF REQUIRED BY WRITTEN CONTRACT (CONTRACTORS) This endorsement modifies Insurance provided under the following. COMMERCIAL GENERAL LIABILITY COVERAGE PART 1. The following is added to SECTION II—WHO Is (a) The Additional Insured — Owners, AN INSURED: Lessees or Contractors— Scheduled Any person or organization that: Person or Organization endorsement a. You agree in a "written contract requiring In- CO 20 on 04 C 20 1 13, surance" to Include as an additional insured the Additional cura d — Owners. o on this CoveragePart;end Lessees or Contrrnactors—Completed Operations endorsement CG 20 37 b. Has not been added as an additional insured 07 04 or CG 20 37 04 13, or both of for the same project by attachment of an en- such endorsements with either of dorsemant under this Coverage Part which those edition dates;or includes such person or organization In the (b) Either or both of the following; the endorsement's schedule; Additional Insured — Owners, Lee- is en insured,but: sees or Contractors — Scheduled a. Only with respect to liability for"bodily Injury'. Person Or Organization endorsement damage" u"personal in CO 20 10,or the Additional Insured— "property ge p injury";end Owners, Lessees or Contractors — b. Only as described in Paragraph(1),(2)or(3) Completed Operations endorsement below,whichever applies: CG 20 37, without an edition dale of (1) If the ''written contract requiring insur- such endorsement specified; ante" specifically requires you to provide the person or orgarrltalictt is an eddlilonal additional Insured coverage to that per- Insured only, if INS Injury or damags Is son or organization by the use of; Goosed, In vetoes or in pert, by acts or (a) The Additional Insured — Owners, omissions of you or your subCCntrrctlor In Lessees or Contractors — (Form B) the performance of"your work"to which endorsement CG 201D 11 85;or the "written contract requiring insurance' (b) Either or both of the foNowing: the applies;or Additional Insured — Owners, Les- (3) If neither Paragraph(1)nor(2)above tip- saes or Contractors — Scheduled plies: Person Or Organization endorsement (a) The person or organization is an ad- CO 20 10 10 01, or the Additional in- ditlonal insured only 11, and to the ax- sured-Owners,Lessees or Contract tent that, the Injury or damage Is tors — Completed Operations en- caused by acts or omissions of you or dorsement CG 20 3710 01; your subcontractor in the perform- the person or organization Is an additional ance of"your work"to which the"writ- insured only if the Injury or damage arises ten contract requiring insurance" sp- out of "your work" to which the 'written plies;and contract requiring Insurance"applies; (b) The person 0"organttalon does not (2) If the "written contract requiring insur- 4, et an additional insured V,k:h anca"specifically requires you to provide 1110PIXII to irre triirlspenoe;1 1,13 Or additional Insured coverage to that per- emissions aior':s of such person of drU401. son or organization by the use of: zetion. CO D6 04 OS 13 0 2013 The Travelers indemnity Company.At rigN*reserved, Page 1 0f 3 COMMERCIAL GENERAL LIABILITY 2. The insurance provided to the additional insured and collectible other insurance, whether primary, by this endorsement is limited as follows: excess, contingent or on any other basis, that is a. If the Limits of Insurance of this Coverage available to the additional Insured When that per- Part shown in the Declarations exceed the son or organization Is an additional insured,or is minimum limits of liability required by the any other Insured that does not qualify as a "wrItten contract requiring insurance", the In- named Insured,under such other Insurance. surance provided to the additional insured will 4. As a condition of coverage provided to the addi- be limited to such minimum required limits of Lionel Insured by this endorsement: liability. For the purposes of determining a. The additional Insured MOM give us written whether this limitation applies, the minimum notice as soon as pradlcable of an 'occur- limits of liability required by the "written Con- rence" or an offense which may result in a tract requiring insurance' will be considered claim. To the extent possible, such notice to include the minimum limits of liability of any should include: Umbrella or Excess liability coverage required for the additional insured by that`written con- (1) How, when and where the "occurrence' tract requiring Insurance". This endorsement or offense look place; will not increase the limits of Insurance de- (2) The names and addresses of any injured scribed in Section III–Limits Of Insurance, persons and witnesses;and b. The insurance provided to the additional in- (3) The nature end location or any Injury or suited does not apply to"bodily injury","prop- damage arising out of the"occurrence"or erty damage" or'personal injury" arising out offense. of the rendering of. or failure to render, any b. II a claim is made or'suit"is brought against professional architectural,engineering Of sur- the additional insured, the additional Insured veying services,including: must; (1) The preparing, approving, or failing to prepare or approve, maps, shop draw- (11 claim Immediately recordt the specificsev ; the ings, opinions, reports, surveys, field or- claim or'suit"and the dale received;and dens or change orders, or the preparing. 12) Notify us as soon as practicable, approving, or failing to prepare or ap- The additional insured must see to it That we -IIS prove,drawings and specifications;and receive written notice of the claim or"suit'as . (2) Supervisory, inspection, architectural or soon as predicable. illi engineering activities. c. The additional insured must immediately send JO c. The insurance provided to the additional in- us copies of all legal papers received in con- ./' sured does not apply to "bodily injury" or nection with the claim or"suit",cooperate with "property damage"caused by"your work"and us In the investigation or settlement of the Included in the 'products-completed opera- claim or defense against the "suit", and 0th- ; 2 2 tions hazard"unless the"written Contract re- Owls.comply with all policy conditions. quiring insurance"specifically requires you to d. The additional insured must tender the de- alkd provide such coverage for That additional in- tense and Indemnity of any claim or"suit'to "+M sured during the policy period. any provider of other insurance which would AB 3, The Insurance provided to the additional insured cover the additional insured for a loss we "S by this endorsement is excess over any valid and cover under this endorsement. However,this collectible other insurance, Whether primary, ex- condition does not affect whether the Insur- cess, contingent or on any other basis, that is mace provided to the additional Insured by this 21 available to the additional insured.However,If the endorsement le primary to other insurance `written contract requiring insurance" specifically available to the additional insured which coy- requires that this insurance apply on a primary ers that person or organization as a named API basis or a primary and non-contributory basis,this insured as described in Paragraph 3.above. War Insurance Is primary to other insurance available 5, The following is added to the DEFINITIONS Sec- Ilto the additional Insured under which that person — or organization qualifies as a named insured,and tion: we will not share with that Other insurance. But "Written contract requiring insurance"means that the insurance provided to the additional Insured part of any written contract or agreement under by this endorsement still Is excess over any valid which you are required to include a person or or- Page 2 of 3 Q,2013 The Trawlers Indemnity Company,AM rights resemd. CO De 04 Olt 13 COMMERCIAL GENERAL LIABIUTY gent:atlon as an additional insured on this Cover- a. After the signing and execution of the contract ape Part, provided that the 'bodily injury" and or agreement by you;and "property damage"occurs, and the'personal in- b. While that pan of the contract or agreement Is OW is caused by an offense committed, during in effect. the policy period and, CO DI 04 0113 Co 201 a The%mien Indemnay Company,at rlpMe rnervrd. Page 3 of 3 Main Lane Industries Ltd Policy Number: DT-CO-1 E958445-IND18 1/21/2018- 1/21/2019 COMMERCIAL GENERAL LIABILITY 40 THIS ENDORSEMENT CHANGES THE POLICY.PLEASE READ IT CAREFULLY. CONTRACTORS XTEND ENDORSEMENT This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART GENERAL DESCRIPTION OF COVERAGE-This endorsement broadens coverage, However.coverage for any injury, damage or medical expenses described in any of the provisions of this endorsement may be excluded or limited by another endorsement to this Coverage Part,and these coverage broadening provisions do not apply to the extent that coverage Is excluded or limited by scab air endorsernem,The following listing Is a general cover- age description only.Limitations and exclusions may apply to them coverages.Read all the provisions of this en- dorsement and the rest of your policy carefully to determine rights,duties,and what is and Is not covered. A. Aircraft Chartered With Pilot H. Blanket Addillonai Insured - Lessors Of Leased B. Damage To Premises Rented To You Equipment C. Increased Supplementary Payments I. Blanket Additional Insured - States Or Political D. Incidental Medical Malpractice Subdivisions-Permits , E. Who Is An Insured -Newly Acquired Or Formed J. Knowledge And Notice Of Occurrence Or Offense Organizations K. Unintentional Omission F. Who Is An Insured - Broadened Named Insured L. Blanket Waiver Of Subrogation -Unnamed Subsidiaries M. Amended Bodily injury Definition 0 G. Blanket Additional Insured - Owners, Managers N. Contractual Liability-Railroads Or Lessors 01 Premises -ini PROVISIONS INJURY AND PROPERTY DAMAGE U- "mg i1C ABILITY:A. AIRCRAFT CHARTERED WITH PILOT IO The following Is added to Exclusion g.. Aircraft, Exclusions C.and g.lhrutih a.do eat apply Auto Or Watercraft,in Paragraph 2.of SECTION to 'l).-ernises damage". Exclusion I,(1)Ial -COVERAGES-COVERAGE A BODILY IN- dams not apply to prerrrrtts dmage"caused int JURY AND PROPERTY DAMAGE LIABILITY; by: Jill This exclusion does not apply to an aircraft that a. Fire; AM Is: b. Explosion; .1M (a) Chartered with a pilot to any Insured; c. Lightning; (b) Not owned by any insured;and d. Smoke resulting from such tire,explosion, . i (c) Not being used to carry any person or prop or lightning;or M arty for a charge. a. Water; 1 B. DAMAGE TO PREMISES RENTED TO YOU unless Exclusion f.of Section I-Coverage A AN - r?:'.ry a+r y land Property Cterot{gb t.rmbllrlv 1IMi . The first pitniOrnet M the tilt epllona In Ex- elusion j. Damage To Property. it Para- 1111 arte ac retJaca':f try se er enikrrslrmtnt w. this e111 graph 2. of SECTION I = COVERAGES - ico..r-raija bawl 1+.11 tsps a as►cn -AU Polio -in COVERAGE A COONS INJURY AND t°?r' tirir! Zr D.rin a tit toia= P. Irr04n Fr- PROPERTY DAMAGE LIABILITY Is deleted. dusion In Its title. 2. The following replaces the Iasi paragraph of A eePwate limn of insureece applies to —'- Paragraph 2., Exclusions, of SECTION I- -prernit.As demepe' as described la Para- . 411 COVERAGES - COVERAGE A. BODILY graph 6, of SECTION III - LIMITS OP IN- SURANCE. CO D3 16 11 11 a 2011 The Trwdns Irdvnnty employ.All'IOU rMVVM. Page 1 Of 6 OGD"? COMMERCIAL GENERAL LIABILITY 3, The following replaces Paragraph 5. of SEC. C. INCREASED SUPPLEMENTARY PAYMENTS TION HI-LIMITS OF INSURANCE: 1. The following replaces Paragraph 1.b. of Subject to 5. above, the Damage To Prom- SUPPLEMENTARY PAYMENTS - COVER- ises Rented To You Limit Is the most we wiM AGES A AND B of SECTION I -COVER. pay under Coverage A for damages because AGE: of "premises damage' to any one premises. b. Up to $2,500 for the cost of ball bonds The Damage To Premises Rented To You required because at accidents or traffic Limit will apply to all "properly damage" law violations arising out of the use of any proximately oaused by the same occur- vehicle to%ech the Bodily Injury Liability rence", whether such damage results from: Coverage applies,We do not have to fur- fin);explosion;lightning;smoke resulting from nish these bonds. such fire, explosion,or lightning; or water; or any combination of any of these causes. Z. The following replaces Paragraph 1.d. of SUPPLEMENTARY PAYMENTS - COVER- The Damage To Premises Rented To You AGES A AND B of SECTION I -COVER- Limit will be: AGES: a. The amount shown for the Damage To d. All reasonable expenses incurred by the Premises Rented To You Limit on the Insured at our request to assist us in the Declarations of this Coverage Part;or Investigation or defense of the claim or b. $300,000 if no amount is shown for the "suit',Including actual loss of earnings up Damage To Premises Rented To You to $500 a day because of lime off from Limit on the Declarations of this Coverage work. Pert. D. INCIDENTAL MEDICAL MALPRACTICE 4. The following replaces Paragraph a. of the 1. The following is added to the definition of"co- definition of'insured contract"in the DEFINi- TIONS Section: aumanoe"In the DEFINITIONS Seddon: "Occurrence"also means an act or omission a. A contract for a lease of premises. How- committed in providing or falling to provide ever, that portion of the contract fora "Incidental medical services", first aid or lease of premises that indemnifies any Good Samaritan services'to a person. person or organization for "premises 2. The following Is added to Paragraph ta.(1)of damage"is not en"Insured contract'. SECTION II-WHO IS AN INSURED: 6, The following is added to the DEFINITIONS Paragraph (1)(d) above does notto Section: a9 ph ( )( ) apply "bodily injury arising out of providing or fall- "Premises damage" means "property darn- Ing to provide: age'to: a. Any premises while rented to you or tem- (I) "Incidental medical services" by any of il- your occupied by you with permission youe'employees" who Is a nursedpractical of the owner,or Boner,registered nurse,licensed practical nurse, nurse assistant, emergency medi- b. The contents of any premises while such cal technician or paramedic;or premises Is rented to you,If you rent such (Il) First aid or'Good Samaritan services"by premises for a period of seven or fewer consecutive days. any of your "employees' or "volunteer workers",other than an employed or vot- 6. The following replaces Paragraph 4.b.(1)(b) unteer doctor, Any such "employees" or of SECTION IV-COMMERCIAL GENERAL "volunteer workers" providing or failing to LIABILITY CONDITIONS: ser- (b) That is insurance for' remises damage": provide first theirid or"Good Samaritanyo P vlCea"during work hours for you will or be deemed to be acting within the soope 7. Paragraph 4.b.(1)(C) of SECTION IV - of their employment by you or performing COMMERCIAL GENERAL LABILITY CON- duties related to the conduct of your bust- DITIONS is deleted. ness. • Page 2 of 8 0 2011 T1.Trawlers Indomnlry Company All Apia resery d. CO D31E 11 11 COMMERCIAL GENERAL LIABILITY 3. The following Is added to Paragraph 5. of 4. Any organization y'oo newly ocilaire or form, • SECTION III-LIMITS OF INSURANCE: other than a padnecshlp, k1nt venture el ilm- For the purposes of determining the applies- ited liability company'. of which yon are the ble Each Occurrence Limit,all related acts or sole owner or in which you maintain the ma- omissions committed in providing or failing to prey ownership interest, will quality as a provide "incidental medical services",first aid Named Insured if there Is no other Insurance or"Good Samaritan services"to any one per- which provides similar coverage to that or- son will be deemed to be one"occurrence ganizatlon.However: 4. The following exclusion Is added to Para- a. Coverage under this provision is afforded graph 2.,Exclusions, of SECTION I-COV- only: ERAGEB-COVERAGE A BODILY INJURY (1) Until the 180th day after you acquire or AND PROPERTY DAMAGE LIABILITY: form the organization or the end of the Sade Of PharmaceutIcals policy period, whichever is earlier, It you 'Bodily injury' or "property damage" arising do not report such organization in wiling out of the willful violation of a penal statute or to us within 180 days after you acquire or ordinenoe relating to the sale of pharmaceutl• form It;or cels committed by. or with the knowledge or (2) Until the end of the policy period, when consent of,the Insured, that date Is later than 180 days after you 6. The following is added to the DEFINITIONS acquire or form such cap aiirealon, k yOu Section: rep.4 such orgerolza icn h writing to Ira "Incidental medical services"means: within 1E4 days.after you acgttlre or Io.m a. Medical.surgical,dental,laboratory,x-ray it,and xrr+agree in writing thai i1 vitt core or nursing service or treatment, advice or h ue to be a framed insured until the end Instruction, or the related furnishing of of the policy period; food or beverages;or b. Coverage A does not apply to'badly Injury" • b. The furnishing or dispensing of drugs or or "property damage" that occurrri before medical, dental, or surgical supplies or you acquired or formed the organization;and •I appliances. c, Coverage B does not apply to "personal in- "g "Good Samaritan services'means any emer- jury' or"advertising injury" arising out of an "� geecy medical services for wench no compen- offense committed before you acquired or ,IN sation Is demanded or received. formed the organization. . 6. The following Is added to Paragraph 4.b.,Ex- F. WHO IS AN INSURED-BROADENED NAMED alli cera Insurance, of SECTION IV - COM- INSURED-UNNAMED SUBSIDIARIES alffi MERCIAL GENERAL LIABILITY CONDI- AM TIONS: The following is added to SECTION II-WHO IS NommenAN The insurance is excess over any valid and INSURED: J EN collectible other insurance available to the In- Any of your subsidiaries,other than a partnership, M cured,whether primary,excess,contingent or joint venture or limited liability company, that is SE on any other basis, that Is available to any of not shown as a Named Insured In the Declare- Al your "employees" or "volunteer workers" for lions is a Named Insured if you maintain an own- "bodily injury" that arises out of providing or ership interest of more than 50% in such subsldl- A▪ N falling to provide "Incidental medical ser cry on the first day of the policy period. vices",first aid or"Good Samaritan services" NO such 6ttk13idiflry U an tinned for"bodily Injury" o� to any person to the extent not subject to or "property damage-Rat occurred;or"personal off, Paragraph 4a,(1j of Section II-Who Is An ink, or "a vartlssng injury- zauLed by an of• Insured, tent* ,crommtlted arler the dale, it any,during the ''� E. WHO IS AN INSURED - NEWLY ACQUIRED policy period, that you no longer maintain an .= OR FORMED ORGANIZATIONS ownership interest of more than 50%in such sub- The following replaces Paragraph 4. of SECTION sidlery. 11110 ii_WHO IS AN INSURED: CO D3 1$11 11 m Nil The Trawlers indemnity Company.AN 140 reserved, Page 3 of 6 OUTS COMMERCIAL GENERAL LIABILITY O. BLANKET ADDITIONAL INSURED-OWNERS, H. BLANKET ADDITIONAL INSURED-LESSORS MANAGERS OR LESSORS OF PREMISES OF LEASED EQUIPMENT1111 The following Is added to SECTION II-WHO IS The following is added to SECTION II-WHO IS AN INSURED: AN INSURED: Any person or organization that is a premises My pence, or o9selzet rl that Is an equipment owner, manager or lessor end that you have tess:r and that you have agreed in a written con- agreed in a written contract or agreement to In- tract or agreement to Include as an Insured on dude as an additional insured on this Coverage this Outrage Part Is en Insured. but only with re- Part is an Insured,but only with respect to liability speet to(lability for'bodily injury",'property dam- for 'bodily injury", "property damage", "personal age","personal injury"or"advertising Injury'that: injury"or"advertistog injury'that; a. I6 "bodily injury" or "property damage" that a. Is 'bodily injury' or 'property' ttatr,ege' that occurs, or is "personal injury" or 'advertising oscura, ar is personei injury" or Is cc sint- injury'caused by an offense that Is commit- tent subsequent ceased bit era offxecu tl,tvt rbmmft- led, subsequent to the execution of that ton Led, ragreemto the execution of that eon tract or agreement;and tract or agreement;end b. Arises out of the ownership, maintenance or b. Is caused, In whole or in part,by your acts or use of that part of any premises leased to omissions in the maintenance, operation or usu use of equipment leased to you by such equipment lessor. The insurance provided to such premises owner, The insurance provided la such equipment lessor manager or lessor Is subject to the following pro- is subject to the following provisions: visions: a. The limits of insurance provided to such a. The limits of insurance provided to such premises owner, manager or lessor will be equipment lessor willo be vithd minimum theem limHs the minimum limits whichyou which you agreed to provide in written agreed to pro- contract or agreement,or the Emits shown on 4. vide in the written contract or agreement, or the Declarations,whichever are less. the limits shown on the Deolaratlons,which- ever are less. b. The Insurance provided to such equipment b. The insurance provided to such premises lessor does not apply to any"bodily Injury"or 'property damage" that occurs, or 'personal owner,manager or lessor does not apply lo: injury or-aduertising 4nJ4uy caused by art of- (1) Any "bodily Injury" or"property darnaae" tense that is committed, after the eryJiprnent that occurs,or'personal injury"or"adver- lease expires, tieing Injury"caused by an offense that Is c. The insurance provided to such equipment Committed,after you Cease to be a tenant lessor is excess over any valid and collectible In that premises;or other insurance available to such equipment (2) Structural alterations,new construction or lessor, whether primary, excess, contingent demolition operations performed by or on or on any other basis, unless you have behalf of such premises owner, lessor or agreed In the written contract or agreement manager. that this insurance must be primary to, or C. The insurance provided to such premises non-contributory with, such other Insurance, owner,manager or lessor Is excess over any In welch case this Insurance will be primary valid and collectible other insurance available to, and non-contributory with, such other in- to such premises owner, manager or lessor. surance. whether primary, excess, contingent or on i, BLANKET ADDITIONAL INSURED - STATES any other basis, unless you have agreed in OR POLITICAL SUBDIVISIONS-PERMITS the written contract or agreement that this in- surance must be primary to, or non- The following is added to SECTION II-WHO IS AN contributory with, such other Insurance, in INSURED- which case this Insurance will be primary to, My stale or political sktbd(vlsion that has Issued a and non-contributory with, such other insur- permit In oomma:Lion with operations performed by • ante. you or on your be•watf and that you are requIred Page 4 of 6 a 2011 TM Tievttsn Mdomnity Comp ny.AI r{ihts rs srvtrd CO D3 161111 COMMERCIAL GENERAL LIABILITY • • by any ordinance,law or building code to include (II) A manager of any limited liability as an additional Insured on this Coverage Part Is company;or an insured, but only with respect to liability for (iii)An executive officer or director of 'bodily injury', "properly damage", "personal In- any other organization: jury"or"advertising injury"arising out of such op- that is your partner, joint venture erations. member or manager,or The Insurance provided to such state or political (b) Amy "emeitevee" euthor'rted by such subdivision does not apply to: :partnership, joint venture, limited li- e. Any "bodily Injury,' "property damage," "per- Lability company or other organization sonal Injury"or"advertising injury"arising out to give notice of an 'occurrence" or of operations performed for that slate or pa offense. !local subdivision;or (3) Notice to us of such"occurrence"or of an b. Any "bodily Injury" or "property damage" in- offense will be deemed to be given as cluded In the"products-completed operations soon as practicable if it Is given in good hazard". faith as soon as practicable to your work- J. KNOWLEDGE AND NOTICE OF OCCUR- ers' compensation insurer. This applies RENCE OR OFFENSE only if you subsequently give notice to us The following is added to Paragraph Z,Duties In of the"occurrence"or offense as soon as The Event of Occurrence, Offense, Claim or practicable after any of the persons de- Suit, of SECTION IV – COMMERCIAL OEN- scribed in Paragraphs a.(1) or(2)above ERAL LIABILITY CONDITIONS: discovers that the"occurrence'or offense applymay result In sums to which the insurance a. The following provisions to Paragraph provided under this Coverage Part may a. above. but only for the purposes of the in- apply. suranoe provided under this Coverage Part to if this C6verar2a Part fndu4ss an err you• for any insured listed in Paragraph 1.or 2, However, en' that povert4eoves limited d ceverege fir of Section II–Who Is An insured: (1) Notice to us of such "occurrence" or of- •badily ik*iry" or 'pr'oper1} damage' or polutfon Allcosts arising out of a dlscharge, fecal?' Of 06- "n tense must be given as soon as practice- cape el-potetents'which contains a require nest bie only after the "occurrence'or offense Is known by you (it you are an individual), the; the di;<ohatge, taloa-se 07 escape of `pc4�l- anti" must be reported 10 us wtlnln a spccific "S any of your partners or members who is number of days after its abrupt commencement, an individual (if you are a partnership or this Paragraph e. does not affect that require- •= joint venture), any of your managers who melts, e== is an individual(if you are a limited liability K. UNINTENTIONAL OMISSION AS company), any of your "executive offi vers"or directors(if you are an organize- The following is added to Paragraph 8., Repro- 41111 lion other than a partnership,joint venture sentallons, of SECTION IV – COMMERCIAL in or limited liability company) or any "em- *yea' LIABILITY CONDITIONS: ployee" authorized by you to give notice The unintentional omission of, or unintentional • of en"occurrence"or offense. error in, any Information provided by you which _atil (2) If you are a partnership, joint venture or we relied upon In issuing this policy will not preJu- �im limited liability company,and none of your CL" fairv� y;3 order this +rtsr«acs Hr?�Urnf - partners, joint venture members or men- I s f•C.ISo' 7r�ri not aI(ati our ripfil in (-okra o� agars are indivtdw its,notice to us of such cir)11aur,.4 ;:it'r�nrn• er to eueruse out rQ, tv+r r I "occurrence"or offense must be given es cancel.tinn or aonnrrfwal is e4carria'ttie with Ailf soon as practicable only after the"occur- applicable Insurance laws or regulations. AI rents"or offense Is known by: L. BLANKET WAIVER OF SUBROGATION (a) Any Individual who is: The following Is ridded to Paagrapat IL,TIonifor • (I) A partner or member of any part- Of Rights Of Recovery Against WW1Ta US, part- nership or joint venture: of SECTION IV–COMMERCIAL GENERAL LI- ABILITY CONDITIONS; CO 03 16 11 11 G 2011 The Travelers Irrr■mnlly Company.AI rlahta reserved. Pegg Sof 6 003319 COMMERCIAL GENERAL LIABILITY If the Insured has agreed In a contract or agree- 3. "Bodily Injury" means bodily Injury, menial ment to waive that Insured's right of recovery anguish,mental injury,shock,fright,disability, against any person or organization,we waive our humiliation,sickness or disease sustained by right of recovery against such person or organize- a person, Including death resulting from any lion,but only for payments we make because of: of these at any time. a. "Bodily injury" or'property damage" that oc N. CONTRACTUAL UABIUTY—RAILROADS curs;or 1. The following replaces Paragraph c, of the b. "Personal injury' or "advettieing injury" definition of"Insured contract"In the DEFINI- caused by an offense that Is committed; TIONS Section: subsequent to the execution of that contract or c. Any easement or license agreement: agreement. 2. Paragraph f.I1) of the definition of "insured M. AMENDED BODILY INJURY DEFINITION contract"in the DEFINITIONS Section Is de- The following replaces the definition of "bodily feted. injury'In the DEFINITIONS Section: S • Page 6 of 6 o 2011 The Tnvl«a Indemnity Conpony.At rlghti monied, CO 0316 1111 Policy Number: DT-CO-1 E958445-IND18 COMMERCIAL GENERAL LIABILITY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY DESIGNATED PROJECT(S) GENERAL AGGREGATE LIMIT This endorsement mortifies insurance provided under the following COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Designated Project Designated Project(s): General Aggregate(s): EACH "PROJECT" FOR WHICH YOU HAVE AGREED, IN GENERAL AGGREGATE A WRITTEN CONTRACT WHICH IS IN EFFECT DURING LIMIT SHOWN ON THE THIS POLICY PERIOD. TO PROVIDE A SEPARATE DECLARATIONS GENERAL AGGREGATE LIMIT. PROVIDED THAT THE CONTRACT IS SIGNED AND EXECUTED BY YOU BEFORE THE "BODILY INJURY" OR "PROPERTY DAMAGE' OCCURS. A. For all sums which the insured becomes legally 3. Any payments made under COVERAGE A. obligated to pay as damages caused by "occur- for damages or under COVERAGE C. for .ji= rences" under COVERAGE A. (SECTION I), and medical expenses shall reduce the Desig- for all medical expenses caused by accidents un- nated Project General Aggregate Limit for ellumas der COVERAGE C (SECTION I). which can be that designated "project Such payments attributed only to operations at a single desig- shall not reduce the General Aggregate Limit nated "project"shown in the Schedule above: shown in the Declarations nor shall they re- o— 1. A separate Designated Project General Ag- duce any other Designated Project General gregate Limit applies to each designated"pro- Aggregate Limit for any other designated aim ject", and that limit is equal to the amount of "project"shown in the Schedule above. the General Aggregate Limit shown in the 4. The limits shown in the Declarations for Each Declarations, unless separate Designated Occurrence, Damage To Premises Rented im Project General Aggregates) are sched- To You and Medical Expense continue to tiled above. apply. However, instead of being subject to 2. The Designated Project General Aggregate the General Aggregate Limit shown in the Limit is the most we will Declarations,such lirnits will be subject to the _�--� pay for the sum of all 1 damages under COVERAGE A.. except applicable Designated Project General Ag- -� damages because of "bodily injury" or"prop- • gregate Limit erty damage" included in the "products- B. For all sums which the insured becomes legally affs completed operations hazard", and for medi- obligated to pay as damages caused by "occur- cal expenses under COVERAGE C, regard- rencas" under COVERAGE A. (SECTION I), and less of the number of: for all medical expenses caused by accidents un- a. Insureds: der COVERAGE C. (SECTION I). which cannot be attributed only to operations at a single desig- b. Claims made or"suits"brought; or nated"project'shown in the Schedule above: c. Persons or organizations making claims or bringing"suits". CG D2 11 01 04 Copyright,The Travelers Indemnity Company,2004 Page 1 of 2 raawa COMMERCIAL GENERAL LIABILITY 1. Any payments made under COVERAGE A. vided, any payments for damages because of for damages or under COVERAGE C. for "bodily injury' or "property damage' included in medical expenses shall reduce the amount the "products-completed operations hazard" will available under the General Aggregate Limit reduce the Products-Completed Operations Ag- or the Products-Completed Operations Ag- gregate Limit, and not reduce the General Aggre- gregate Limit, whichever is applicable;and gate Limit nor the Designated Project General 2. Such payments shall not reduce any Desig- Aggregate Limit. nated Project General Aggregate Limit. E. For the purposes of this endorsement the Defini- C. Part 2.of SECTION III—LIMITS OF INSURANCE tions Section is amended by the addition of the is deleted and replaced by the following: following definition: 2. The General Aggregate Limit is the most we "Project" means an area away from premises will pay for the sum of: owned by or rented to you at which you are per- a. Damages under Coverage B; and forming operations pursuant to a contract or agreement For the purposes of determining the b. Damages from "occurrences" under applicable aggregate limit of insurance, each COVERAGE A (SECTION I) and for ail "project" that includes premises involving the medical expenses caused by accidents same or connecting lots, or premises whose con- under COVERAGE C (SECTION I) which nection is interrupted only by a street, roadway cannot be attributed only to operations at waterway or right-of-way of a railroad shall be a single designated"project"shown in the considered a single "project". SCHEDULE above. F. The provisions of SECTION III — LIMITS OF D. When coverage for liability arising out of the INSURANCE not otherwise modified by this en- 'products-completed operations hazard" is pro- dorsement shall continue to apply as stipulated. Page 2 of 2 Copyright,The Travelers Indemnity Company,2004 CG D2 11 01 04 Main Lane Industries Ltd. Policy Number: DT-810-1 E958445-PHX18 1/21/2018-1/21/2019 COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY.PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED-- PRIMARY AND NON-CONTRIBUTORY WITH OTHER INSURANCE This endorsement modtlee Insurance provided under the following: BUSINESS AUTO COVERAGE FORM 1Mth respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modi- fied by this endorsement. PROVISIONS B. The following is added to Paragraph 6., Other A. The following Is added to Paragraph c.In A. 1., . Insurance, In B. General Conditions of SEC- Who Is An Insured,of SECTION II—LIABILITY PION W—BUSINESS AUTO CONDITIONS: COVERAGE: Regardless of the p'ouirrscnz of pengraPh a.and My persdn or organization who is recfrlred under paragraph d,of this pert 6.Other insurance,this e written contrail or agreement between Y8,1 end Intutalce It primary to and non-cottrtMoy with that person or oigisnlzaC;an. Iher k trod apFkable other Insurance under which an WO- executed by y+qu beim the .badly injury' car Botnil'IneLaod person or organization le the first "waimei' eeenepd vcwrra and ami Is In out mimed thawed when the written contract or during the Katy period.to be rwrnad 111 an&milt- stgren ant between you and that person or or- tlorreJ Truces* la an'moved'for l4tkfitl Cower- penizaltel, that Is signed end executed by you age,bul arty fix citrrtapOil to whit:tilt Insurance Detre the 'bodily InJur or 'property damage" apples end Only to the °xteet that person cr cr» occurs end that Is to effect during the policy Pa- rjn (peruse es an 'tnelsred' under the Hod, rOt7,[tee this insurance to be primary and WIO Is An inrrrred pCaw lien conilkie,13 to non-contivtory. Section IL CA T4 74 0212 02012 Tim Trowlent kelorragr evrpirro AnMt&hpaanid Page 1 of 1 NdNdaa earetihted milled&of inoullus,604440 O&.lira wwlh N pen r Ion. Main Lane Industries Ltd. Policy Number: DT-810-1 E958445-PH X18 1/21/2018- 1/21/2019 COMMERCIAL AUTO THIS ENDORSEMENT CHANGES THE POLICY.PLEASE READ IT CAREFULLY. BUSINESS AUTO EXTENSION ENDORSEMENT This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM With respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modi- fied by the endorsement. GENERAL DESCRIPTION OF COVERAGE-This endorsement broadens coverage.However,coverage for any Injury, damage or medical expenses described in any of etre pewees aria of flies errdoreemenl may be excluded or limited by another endorsement to the Coverage Part,and these ctivciaoe broadening provisions-do COL apply to the extent that coverage Is excluded or limited by such en ondorserr,eni.Thu'foriowirg listing is a general cover- age description only,Limitations and exclusions may apply to thus urverages.Read CHM'prevasiord of tale ert•- dorsemerd and the rest of your policy carefully to determine rigits,duties,and whet is end is col covered A. BROAD FORM NAMED INSURED H. HIRED AUTO PHYSICAL DAMAGE - LOSS OF USE-INCREASED LIMIT B. BLANKET ADDITIONAL INSURED I. PHYSICAL DAMAGE - TRANSPORTATION EXPENSES-INCREASED LIMIT C. EMPLOYEE HIRED AUTO .1. PERSONAL EFFECTS D. EMPLOYEES A8 INSURED K. AIRBAGS E. SUPPLEMENTARY PAYMENTS -INCREASED L. NOTICE AND KNOWLEDGE OF ACCIDENT LIMITS OR LOSS F. HIRED AUTO - LIMITED WORLDWIDE M. BLANKET WAVER OF SUBROGATION 7114 COVERAGE-INDEMNITY BASIS im G. WAVER OF DEDUCTIBLE-GLASS N. UNINTENTIONAL ERRORS OR OMISSIONS Ai PROVISIONS A. BROAD FORM NAMED INSURED sxted by you before the "bodily injury" or The following is added to Paragraph Al.,Who is "property t amsge• occurs aid that is in effect An Insured, of SECTION I1 - LIABILITY COV- durino e'e policy period,to be named as an addl- tlanel lowed is an 'Insured' for Liability Cover- ERAOE: age,but only for damages to which this insurance .116 Any organization you newly acquire or form dur- applies and only to the extent that person Or Or- jig r- - Ing the policy period aver which you maintain ganization qualifies as an Insured" under the Note 50% or more ownership interest and that Is not Who is An Insured provision contained In Section separately Insured for Business Aulo Coverage. It. Coverage under this provision Is afforded only un- . 1111 til the 150th day after you acquire or form the or- C. EMPLOYEE HIRED AUTO ganization or the end of the policy period,which- 1. The following is added to Paragraph A.1., al ever is earlier. Who Is An Insured, of SECTION II - U- B. BLANKET ADDITIONAL INSURED-. , ABILITY COVERAGE: -M The following is added to Paragraph c. in A.1„ An"employee"of yours Is an"Insured" while Who Is An Insured,of SECTION II-LIABIVTY operating an 'auto" hired or rented under a IIICOVERAGE: contract or agreement In that "employee's" Anyperson or organization who isrequired under name,with your permission,while performing Pa duties related to the conduct of your busi- a written contract or agreement between you and tress. that person or organization, that is signed and CA T3 53 03 10 0 2oroTr*Travelers Mdemrrtty Company. Page 1 of 4 !harder oopy,i il.d matertar or Insurance Services OtToe.Inc,with its pwrrn4.ioh- MOO COMMERCIAL AUTO 2. The following replaces Paragraph b. in 5.5., within such country or jurisdiction,for Liability Other Insurance, of SECTION IV — BUSI- Coverage for any covered "auto" that you NESS AUTO CONDITIONS: lease,hire,rent or borrow without a driver for b. For Hired Auto Physical Damage Cover- a period of 36 days or less and that Is not an age,the following are deemed to be coo. 'auto' you lease, hire, rent or borrow from wed"autos"you own: any of your'employees", partners (If you are (1) Any covered "auto" you lease, hire, a partnership), members(it you we a limited liability company)or members of their house- rent or borrow,awl holds. (2) Any covered'auto"hired or rented by your "employee" under a contract In (a) With respect to any claim made "suit" that Individual `un brought outside the United States of 'employee's" name, America, the territories and possessions with your permission, while perform- of the United States of America, Puerto Mg duties related to the conduct of Rico and Canada: your business. "In- However,any"auto"that Is leased,hired, (I) You must arrange to defend the t- rented or borrowed with a driver is not a tiered such claim and investigate"suit" creep ib any such orand keep coveted"auto". us advised of ail proceedings and ac- D. EMPLOYEES AS INSURED tions. The following is added to Paragraph A.1.,Who Is (ii) Neither you nor any other Involved An Insured, of SECTION II — LIABILITY COV- "Insured' will make any settlement ERAGE: without our consent. Any"employee"of yours Is en"Insured"while us- till)We may,at our discretion,participate ing a covered"auto"you don't own,hire or borrow in defending the"Insured"against, or In your business or your personal affairs, in the settlement of, any claim or E. SUPPLEMENTARY PAYMENTS —INCREASED "suit . LIMITS (Iv)We vAl reimburse the "Insured" for 1. The following replaces Paragraph A.2.■.(2), sums that the "Insured" legally must of SECTION 11—UASIUTYCOVERAGE: pay as damages because of"bodily injury"or"property damage"to which (2) Up to $3,000 for cost of ball bonds (in- this Insurance applies, that the 'in- cluding bonds for related traffic law viola- cured" pays with our consent, but , tions) required because of an "accident" only up to the limit described In Para- we cover. We do not have to furnish graph C.,Limit Of Insurance,of SEC- these bonds. TION II—LIABILITY COVERAGE. 2, The following replaces Paragraph A.2.■.(4), (v) We will reimburse the 'Insured" for of SECTION 11—LIABIUTY COVERAGE: the reasonable expenses Incurred (4) AN reasonable expenses Incurred by the with our consent for your knvestige- 'lnsured" at our request, including actual tion of such claims and your defense loss of earnings up to MOD a day be- of the insured" against any such cause of time off from work. "suit", but only up to and included F. HIRED AUTO — LIMITED WORLDWIDE COV- within the limit described in Para- graph C., Limit Of Insurance, of ERAGE—INDEMNITY BASIS SECTION II — LIABILITY COVER- The following replaces Subparagraph(5)In Para- AGE,and not In addition to such limit. graph 01., Policy Period" Coverage Territory, Our duty to make such payments of SECTION IV — BUSINESS AUTO CONDI- ends when we have used up the ap- TIONS: plicable limit of Insurance in pay- (6) Anywhere in the world,except any country or menu for demegee, settlements or Jurisdiction while any trade sanction, em- defense expenses. barge, or similar regulation Imposed by the (b) This insurance Is excess over any valid United States of America applies to and pro- and collectible other insurance available hibits the transaction of business with or Page 2 of 4 o 2010 me Trawl.rs Ind.mnty Company. CA T3 63 03 10 includes OapyrlaMed mutarial or 1Munnee Servos OMce,Inc,MO It.parml.oroa COMMERCIAL AUTO to the "insured" whether primary, excess J. PERSONAL EFFECTS contingent or on any other basis, The following Is added to Paragraph A.4.,Cover- (c) This Insurance is not a substitute for re- age Extensions, of SECTION III - PHYSICAL guired or compulsory Insurance in any DAMAGE COVERAGE: country outside the United States, its ler- personal Effects Anodes and possessions,Puerto Rico and Canada, We will pay up to$400 for"loss" to wearing ap- You agree to maintain all required or parel and other personal effects which are: compulsory insurance in any such coun- (1) Owned by an"Insured";and try up to the minimum limits required by (2) 10 or on your covered"auto`, local law, Your failure to comply with This coverage applies only In the event of a total compulsory insurance requirements will theft of your covered"auto". not Invalidate the coverage afforded by this policy,but we will only be liable to the No deductibles apply to this Personal Effects same extent we would have been liable coverage. had you compiled with the compulsory in- K. AIRBAGS aurorae requirements. The following is added to Paragraph 8.3., EXckt" (d) It is understood that we are not an admit- lions, of SECTION III - PHYSICAL DAMAGE ted or authorized insurer outside the COVERAGE: United Stales of America, Its tenitotles Exclusion 3.a,does not apply to loss"to one or and possessions,asume Puerto Rion and Can- more airbags in a covered"auto"you own that lo- a ds.Wein assume no responsibility for the Sate due to a cause other than a cause of loss" furnishing l of certificates of insurance, or set forth In Paragraphs A.1.b. and A.1.c., but pliers In any way with the taws of other countries relating to Insurance, only: 0, WAIVER OF DEDUCTIBLE-GLASS a. If that"auto"Is a covered"auto"for Compre The foNowtng is added to Paragra0 D.,Oeductl• hensrve Coverage under this policy; ick, of SECTION III - PHYSICAL DAMAGE b. The airbags are not covered under any war- •= COVERAGE: ranty;and AIIII i No deductible for a covered "auto" will apply to c. The airbags were not Intentionally inflated, glass damage If the glass is repaired rather than We will pay up to a maximum of 61,000 for any replaced. one"loss". la H. HIRED AUTO PHYSICAL DAMAGE-LOSS OF L NOTICE AND KNOWLEDGE OF ACCIDENT OR USE-INCREASED LIMIT LOSS MI AN The following replaces the last sentence of Para The following is added to Paragraph A 2,a., of graph A.4.b., Lou Of ties Expense,, of SEC- SECTION IV-BUSINESS AUTO CONDITIONS: AU AU TION III PHYSICAL DAMAGE COVERAGE: Your duty to give us or our authorized represents- AN However,the most we will pay for any expenses live prompt notice of the "accident"or"loss" lip- ase for loss of use Is $85 per day, to a maximum of plies only when the"accident"or"loss"is known liE $750 for any one"accident",AM to: I. PHYSICAL DAMAGE - TRANSPORTATION (a) You(if you are an individual); AM EXPENSES-INCREASED LIMIT (b) A partner(if you are a partnership); cia The following replaces the first sentence in Para- (c) A member(If you are a limited liability Com- pany);graph A.4.a., Transportation Expenses. of pany); All SECTION III - PHYSICAL DAMAGE COVER- (d) An executive officer, director or insurance AGE: sm. We win pay up to$50 per day to a maximum of 1111 $1,600 for temporary manager Of gayour are a corporation or other or. Transportation expense In- (a) Any"employee"authorized by you to give no- owned by you because of the total theft of a Cor- floe of the"accident"or"loss". erred"auto"of the private passenger type. CA T3 63 0310 02010 The Travelers Indemnity Company. Page 3 of 4 Inductee copyrighted materiel or Insurance Services Office,Ino.With Ito permission Mill COMMERCIAL AUTO M. BLANKET WAIVER OP SUBROGATION such contract.The waiver applies only to the The following repfeoes Paragraph , „ Tutfsr person or organization designated In such Of Rights Of Re-covery Against Otlwre To Us contract, of SECTION IV - BUSINESS AUTO I• N. UNINTENTIONAL ERRORS OR OMISSIONS TION0: The following s added d. Transfer Of Rights Of Recovery Against ceaknent, Misrepresentation,o Orrai Fraud,ILL, Co of Others To Us SECTION IV—BUSINESS AUTO CONDITIONS: We waive any Opt of recovery ws may have The unintentional omission ot, or unintentional $Datrdl any persn or organization to the ex- error in, any information given by you shalt not lent requkad or yogi by a written contract prejudice your rights under this Insurance, How- signed and executed prior to any "accident` ever this provision does not affect our right to col- or'loss",provided that the"accident"or loss" lett additional premium or exercise our right of arises out of operations contemplated by cancellation or non-renewal, Page 4 of 4 O 2010 The Trp ,.Indemnity Company CA T3 63 03 10 Includes oopy'lphted mslsrlsi of lneuranoe SerYbee Dabs,Inc With Its pwmission WORKERS'COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY In uracc Corrkpauy WC 42 03 04 B TEXAS WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A, of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy.We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule whore you aro required by a written contract to obtain this waiver from us. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule 1. ( ) Specific Waiver Name of person or organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver 2. Operations: ALL TEXAS OPERAT IONS 3. Premium The premium charge for this endorsement shall be 2,D.0. percent of the premium developed on payroll in connection with work performed for the above person(s)or organization(s)arising out of the operations described. 4. Advance Premium INCLUDED, SEE INFORMATION PAGE, This endorsement changes the policy to which it is attached effective on the Inception date of the policy unless a different date Is Indicated below (The fallowing"attaching clause"need be completed only when this endorsement is issued subsequent to preparation of the policy) This endorsement effective on 2-5-2018 at I2:01 A.M.standard time.forms a part of Policy No TSF-0001202643 of the Texas Mutual Insurance Company Issued to MAIN L ANE INDUSTRIES L TD Cndorsement No. Premium S 14446,412.06-150.4—'' NCCI Career Code 29939 - � Authorized Representative WC420304B(ED.6-01.2014) CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Section 00700 GENERAL CONDITIONS OF AGREEMENT TABLE OF CONTENTS Page No. 1.0 DEFINITIONS AND INTERPRETATIONS 1 1.01 Owner, Contractor and Engineer 1.02 Contract Documents 1.03 Subcontractor 1.04 Written Notice 1.05 Work 1.06 Extra Work 1.07 Work Day 1.07-1 Rain Day 1.07-2 Impact Day 1.08 Calendar Day 1.09 Substantially Completed 1.10 Interpretation of Words and Phrases 1.11 Referenced Standards 1.12 Contract Time 1.13 Construction Inspector 1.14 Balancing Change Order 2.0 RIGHTS AND RESPONSIBILITIES OF THE OWNER 4 2.01 No Warranty of Design 2.02 Right of Entry 2.03 Ownership of Plans 10-2012 00700-i • CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 2.04 Changes and Alterations 2.05 Damages 3.0 RIGHTS AND RESPONSIBILITIES OF THE ENGINEER 6 3.01 Owner-Engineer Relationship 3.02 Keeping of Plans and Specifications Accessible 3.03 Preliminary Approval 3.04 Inspection by Engineer 3.05 Determination of Questions and Disputes 3.06 Recommendation of Payment 4.0 RIGHTS AND RESPONSIBILITIES OF THE CONTRACTOR 8 4.01 Independent Contractor 4.02 Contractor's Understanding 4.03 Laws and Ordinances 4.04 Assignment and Subletting 4.05 Performance and Payment Bonds [and Maintenance Bond] 4.06 Insurance 4.07 Permits and Fees 4.08 Texas State Sales Tax 4.09 Contractor's Duty and Superintendence 4.10 Character of Workers 4.11 Labor, Equipment, Materials, Construction Plant and Buildings 4.12 Sanitation 4.13 Cleaning and Maintenance 4.14 Performance of Work 4.15 Right of Owner to Accelerate the Work 10-2012 00700-ii CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.16 Layout of Work 4.17 Shop Drawings 4.18 Engineer-Contractor Relationship; Observations 4.19 Observation and Testing 4.20 Defects and Their Remedies 4.21 Liability for Proper Performance 4.22 Protection Against Accident To Employees and the Public 4.23 Protection of Adjoining Property 4.24 Protection against Claims of Subcontractors, Laborers, Materialmen, and Furnishers of Equipment, Machinery and Supplies 4.25 Protection Against Royalties or Patented Invention 4.26 Indemnification 4.27 Losses From Natural Causes 4.28 Guarantee 5.0 PROSECUTION AND PROGRESS 18 5.01 Time and Order of Completion 5.02 Extension of Time 5.03 Hindrances and Delays 5.04 Suspension of Work 5.05 Liquidated Damages for Delay 5.06 Change of Contract Time 5.07 Delays Beyond Owner's and Contractor's Control 6.0 MEASUREMENT AND PAYMENT 21 6.01 Discrepancies and Omissions 6.02 Quantities and Measurements 10-2012 00700-iii CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 6.03 Estimated Quantities 6.04 Price of Work 6.05 Payments 6.06 Partial Payments 6.07 Use of Completed Portions& Punchlist 6.08 Substantial Completion 6.08-1 6.09 Final Payment 6.10 Correction of Work Before Final Payment 6.11 Correction of Work After Final Payment 6.12 Payments Withheld 6.13 Delayed Payments 7.0 EXTRA WORK AND CLAIMS 7.01 Differing Site Conditions 7.02 Change Orders 7.03 Change Orders 7.04 Request for Work Approval for Work on Non-Work Days 7.05 Minor Changes 7.06 Extra Work 7.07 Time of Filing Claims 8.0 DEFAULT 30 8.01 Default by Contractor 8.02 Supplementation of Contractor Forces 8.03 Cumulative Remedies & Specific Performance 8.04 Cross-Default 10-2012 00700-iv CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 8.05 Insolvency 8.06 Contingent Assignment 8.07 Waiver of Consequential Damages 8.08 Termination for Convenience 8.09 Default by Owner 9.0 DISPUTE RESOLUTION 35 ATTACHMENT NO. 1: WORKERS' COMPENSATION INSURANCE COVERAGE Al ATTACHMENT NO. 2: AGREEMENT FOR FINAL PAYMENT AND CONTRACTOR'S SWORN RELEASE Bl ATTACHMENT NO. 3: OWNER'S INSURANCE REQUIREMENTS OF CONTRACTOR Cl 10-2012 00700-v CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Section 00700 GENERAL CONDITIONS OF AGREEMENT 1.0 DEFINITIONS AND INTERPRETATIONS 1.01 OWNER, CONTRACTOR AND ENGINEER. The OWNER, the CONTRACTOR and the ENGINEER are those persons or organizations identified as such in the Agreement. The term ENGINEER as used in these General Conditions shall refer to the Engineer or Architect identified in the Agreement, as applicable, and means a person authorized to act as a representative of the entity designated by the OWNER to provide professional services required in connection with the preparation of plans and specifications of this Contract. The term CONSTRUCTION MANAGER as used in these General Conditions shall refer to the Construction Manager identified in the Agreement, as applicable, and means a person authorized to act as representative of the entity designated by the OWNER to provide professional services required in connection with the performance of the work of this Contract. The Owner's representative on the project site shall be the CONSTRUCTION MANAGER or ENGINEER as designated. 1.02 CONTRACT DOCUMENTS. The Contract Documents shall consist of all of the documents identified in Article 8 of the Standard Form of Agreement, which documents, excluding such documents as may be delivered or issued after the Effective Date of the Agreement, as referenced in Article 8, shall be bound together in a Project Manual for the Work. All references to the "Contract" or the "Agreement" in these General Conditions of Agreement shall include the Contract Documents. The Contract Documents are complementary, and what is required by one shall be binding as if required by all. In the event of any conflict among the Contract Documents, the Contract Documents shall govern in the following order: (1) Modifications in writing and signed by both parties, including any Change Orders; (2) Standard Form of Agreement; (3) Special Conditions of Agreement; (4) General Conditions of Agreement, including Attachment No. 1 — Workers' Compensation Insurance Coverage, Attachment No. 2 — Agreement for Final Payment and CONTRACTOR'S Sworn Release, and Attachment No. 3 — Owner's Insurance Requirements of Contractor; (5) Addenda, if any; (6) Plans and Specifications referenced or included in the Project Manual; (7) Instructions to Bidders; (8) Bid Proposal; and 10-2012 00700- 1 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT (9) Exhibits: The following Exhibits, if any, attached hereto, are incorporated herein, and are a part of this Contract: In the event a conflict or inconsistency remains between or within the Contract Documents, or the Contract Documents and applicable standards, codes and ordinances, CONTRACTOR shall provide the greater quantity or better quality, or CONTRACTOR shall comply with the more stringent requirements, as determined by ENGINEER. Terms or phrases used in the Contract Documents with a well-known technical or construction industry meaning shall have such recognized meanings. References to standards, specifications, manuals or codes of any technical society, organization or association, or to the laws or regulations of any governmental authority, shall mean the latest in effect on the effective date of the Contract, unless otherwise stated in the Contract Documents. 1 .03 SUBCONTRACTOR. The term "subcontractor", as employed herein, includes those entities having a contract with the CONTRACTOR or a subcontractor for performance of work on the Project. OWNER shall have no responsibility to any subcontractor for performance of work on the Project contemplated by these Contract Documents, and any such subcontractor shall look exclusively to CONTRACTOR for any payments due subcontractor. 1.04 WRITTEN NOTICE. Written Notice shall be deemed to have been duly served if delivered in person or by electronic means through the Pro-Trak to the individual or to a partner of the partnership or joint venture, or to an officer of the corporation or company for whom it is intended, or if delivered at or sent by Certified Mail, Return Receipt Requested, to the last known business address or registered office of such individual, partnership,joint venture or corporation or company, or to the address for giving notices listed in the Standard Form of Agreement. 1.05 WORK. Unless otherwise stipulated, the CONTRACTOR shall provide and pay for all materials, supplies, machinery, equipment, tools, superintendence, labor, services, insurance, and all water, light, power, fuel, transportation and all other facilities or services of any nature whatsoever necessary for the execution and completion of the Work described in the Standard Form of Agreement. Unless otherwise specified, all materials shall be new, and both workmanship and materials shall be of good quality. The CONTRACTOR shall, if required by the ENGINEER as representative of the OWNER, furnish satisfactory evidence as to the kind and quality of materials. Materials or work described in words which so applied have well-known, technical or trade meaning shall be held to refer to such recognized standards. All work shall be done and all materials shall be furnished in strict conformity with the Contract Documents. 1.06 EXTRA WORK. The term "Extra Work", as used in this Contract, shall be understood to mean and include all work that may be required by the ENGINEER as representative of the OWNER, to be performed by the CONTRACTOR to accomplish any change, alteration or addition to the work shown in the plans. Extra work shall be authorized in writing by the ENGINEER prior to commencement. Extra Work items are paid for on an as needed, as authorized basis only. 1.07 WORK DAY: As used herein, a "Work Day" is defined as any Monday through Friday, not a legal holiday, and any Saturday or Sunday specifically approved by the OWNER, in which the CONTRACTOR can perform six or more hours of work per the current construction schedule. CONTRACTOR agrees to request specific approval from the Construction Manager or 10-2012 00700-2 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Owner, in advance, to perform work on Saturdays or Sundays and in so doing agrees to pay all charges and costs for Inspection and or Construction Management services required during the performance of any such approved work. Refer to paragraph 7.05 for procedure to determine cost for Construction Management and Inspection Services for work on non-work days. 1.07-1 RAIN DAY: As used herein, is defined as any WORK DAY during which weather related conditions prevent the CONTRACTOR from performing four (4) or more consecutive hours of work on critical path items as identified in the current construction schedule. CONTRACTOR shall record Rain Days on the Pay Application each month for the review and possible approval by the OWNER. The approved Rain Day is then added to the Contract Time. (See 1.12 Contract Time below) 1.07-2 IMPACT DAY: As used herein, is a day that is added to the CONTRACT TIME by the OWNER by Change Order to extend the Contract Time by one full Work Day. (See 1.12 Contract Time below) Impact Days, once approved by the OWNER, shall extend the Contract Time on a one-to-one basis to replace a Work Day lost to conditions that prevented the CONTRACTOR from performing four (4) or more consecutive hours of work on critical path items. Impact Days are added to the Contract Time by Change Order only at the end of the work and then only if, in the opinion of the OWNER, a time extension is warranted due to delays beyond the control of the Contractor and required to complete the work within the Contract Time. 1.08 CALENDAR DAY. A "calendar day" is any day of the week, month or year no days being excepted. Unless otherwise expressly provided, all references to "day(s)" shall mean calendar day(s). 1 .09 SUBSTANTIALLY COMPLETED: The terms "Substantially Completed", or "Substantially Complete" or"Substantial Completion" as used in this Contract, shall mean that all major process components of the facility or work have been made suitable for use or occupancy, including appropriate documentation from the equipment suppliers that all of the individual components have been installed in accordance with the specifications and manufacturer's recommendations,the installations have been approved by the ENGINEER and the items have met the start-up and testing requirements of the contract documents or is deemed to be in a condition to serve its intended purpose or requires only minor miscellaneous work and adjustment to achieve Final Completion and Acceptance as determined by the ENGINEER. Upon compliance with the above referenced criteria, ENGINEER shall issue a Certificate of Substantial Completion. PARTIAL SUBSTANTIAL COMPLETION: designation will be given on components of the Work that must be placed into service prior to the completion of the entire Work. The contractor's One Year Warranty period for these items shall begin on the date of Partial Substantial Completion as designated by the ENGINEER. The ENGINEER shall determine and make all such designations. 1.10 INTERPRETATION OF WORDS AND PHRASES. Whenever the words "directed", "permitted", "designated", "required", "ordered", "considered necessary", "prescribed" or words of like import are used, it shall be understood that the direction, requirement, permission, order, opinion designation or prescription of the ENGINEER as the OWNER's representative is intended. Similarly, the words "approved", "acceptable", "satisfactory" or words of like import shall mean that no exception is taken by ENGINEER, but does not relieve CONTRACTOR of responsibility for compliance with the Contract Documents. 10-2012 00700-3 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Whenever in the Specifications or Plans of the Contract Documents, the terms of description of various qualities relative to finish, workmanship or other qualities of similar kind which cannot, from their nature, be specifically and clearly described and specified, but are necessarily described in general terms, the fulfillment of which must depend on individual judgment, then, in all such cases, any question of the fulfillment of said Specifications shall be decided by the ENGINEER as the OWNER's representative, and said work shall be done in accordance with his interpretations of the meaning of the words, terms or clauses defming the character of the work. 1.11 REFERENCED STANDARDS. No provision of any referenced standard specification, or manual shall be effective to change the duties and responsibilities of the Owner, Engineer, Contractor, or their consultants, employees, or representatives from those set forth in the Contract Documents, nor shall it be effective to assign to the Engineer or its consultants, employees, or representatives any duty or authority to supervise or direct the furnishing or performance of the Work or any duty or authority to undertake responsibilities contrary to provisions of the Contract Documents. 1.12 CONTRACT TIME The term Contract Time as used herein, refers to the number of Calendar days provided to complete the work or the date, stated in the Agreement: (i) to achieve Substantial Completion, and (ii) to complete the Work so that it is ready for final payment as evidenced by ENGINEER's written recommendation of final payment in accordance with Paragraph 6.09 and as modified as a result of any authorized Extensions. The established Contract Time includes 40 Rain Days per year, based on the average number of rain days per year for the period of June 1898 to December 1996 as recorded by the Alvin Weather Center Record. The Contract Time shall only be extended by (a) the addition of Rain Days equal to the number of actual Rain Days in excess of 40 days per year and (b) the number of Impact Days granted for delays, in the opinion of the Owner, beyond the control of the Contractor. The extension of the Contract Time shall be the CONTRACTOR's sole and exclusive remedy for delays. 1.13 CONSTRUCTION INSPECTOR The term "Construction Inspector" here in includes those professionals engaged by the OWNER to ensure CONTRACT work's compliance with the specifications and any applicable statutory requirements. 1.14 BALANCING CHANGE ORDER is a change order executed during the close-out process that may add/remove pay items, or adjust quantities of existing items or remove unused pay items or quantities Balancing Change Orders are used to reconcile the unit cost of the work performed or installed by the Contractor. 2.0 RIGHTS AND RESPONSIBILITIES OF THE OWNER 2.01 NO WARRANTY OF DESIGN. It is understood that the OWNER MAKES NO WARRANTY OF THE ADEQUACY, ACCURACY OR SUFFICIENCY OF THE PLANS AND SPECIFICATIONS OR ANY OTHER DESIGN DOCUMENTS, AND OWNER HEREBY EXPRESSLY DISCLAIMS ANY SUCH WARRANTY, EXPRESSED OR IMPLIED. Prior to commencing each portion of the Work, CONTRACTOR shall carefully study and compare the relevant Contract Documents, shall observe conditions at the site affecting the Work, and shall take field measurements of existing conditions related to the Work. Any errors, omissions or 10-2012 00700-4 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT inconsistencies in the Contract Documents noted by the CONTRACTOR, and/or any variance between the Contract Documents and applicable codes, standards or ordinances, shall be promptly reported by CONTRACTOR to ENGINEER in writing as a Request for Information. Work performed prior to a Request for Information shall be at the Contractor's risk. If CONTRACTOR fails to perform its obligations under this paragraph, CONTRACTOR shall pay such costs and damages to OWNER as would have been avoided if CONTRACTOR had reported any errors, omissions, inconsistencies or variances in the Contract Documents noted by CONTRACTOR or which should have been noted by a careful study of the Contract Documents. CONTRACTOR shall comply with the Contract Documents, all approved modifications thereof and additions and alterations thereto approved in writing by the OWNER. The burden of proof of such compliance shall be upon the CONTRACTOR to show that he has complied with the requirements of the Contract Documents and approved modifications thereof and all approved additions and alterations, thereto, as the same shall have been interpreted by the ENGINEER. 2.02 RIGHT OF ENTRY. The OWNER reserves the right to enter the property or location on which the work herein contracted for is to be performed, constructed or installed, for itself or such agent or agents as it may select, for the purpose of inspecting the work, or for the purpose of performing, constructing or installing such collateral work as the OWNER may desire. The OWNER shall have the right to make inspections at all reasonable times, and the CONTRACTOR hereby waives any claims for extension of time and/or compensation for any loss or damage if his work shall be delayed by reason of such inspection, performance, construction or installation of collateral work. 2.03 OWNERSHIP OF PLANS. All plans, specifications and copies thereof furnished by the OWNER shall not be reused on other work and, with the exception of the sets forming the part of the signed Contract Documents, are to be returned to the OWNER on request at the completion of the Work. All plans and models are the property of the OWNER. 2.04 CHANGES AND ALTERATIONS. The CONTRACTOR further agrees that the Owner may make such changes and alterations, additions and deletions as the OWNER may see fit, in the Work, including but not limited to changes in line, grade, form, dimensions, plans or specifications for the Work herein contemplated, or any part thereof, either before or after the beginning of construction, without affecting the validity of this Contract and the corresponding Performance and Payment Bonds. If such changes or alterations or deletions diminish the quantity or the value of the Work to be done, they shall not constitute the basis for a claim for compensation or damages, including lost or anticipated profits on the Work that may be affected. If the amount of Work is increased and the work can fairly be classified under the specifications, such increase shall be paid for according to the quantity actually done and at the unit price, if any, established for such work under this Contract, otherwise, such additional work shall be paid for as provided under Article 7 hereof for Extra Work. In case the OWNER shall make such changes or alterations as shall make useless any Work already done or material already furnished or used in said Work, then the OWNER shall compensate the CONTRACTOR for any material or labor so used and for any actual loss occasioned by such change due to actual expenses incurred in preparation for the Work as originally planned. 2.05 DAMAGES. In the event the OWNER is damaged in the course of the work by the act, negligence, omission, mistake or default of the CONTRACTOR, or should the 10-2012 00700-5 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT CONTRACTOR unreasonably delay the progress of the work being done by others on the job so as to cause loss for which the OWNER becomes liable, then the CONTRACTOR shall reimburse the OWNER for such loss. 3.0 RIGHTS AND RESPONSIBILITIES OF THE ENGINEER 3.01 OWNER-ENGINEER RELATIONSHIP. The ENGINEER shall serve as the OWNER'S representative during construction. The duties, responsibilities and limitations on the authority of the ENGINEER as the OWNER's representative during construction are set forth in the Contract Documents; and the ENGINEER shall not have authority to extend the OWNER's liability or to bind the OWNER for any additional liability of any nature whatsoever without the written consent of the OWNER. Any communications by the OWNER to the CONTRACTOR regarding the Work shall be issued through the ENGINEER. It is the intent of this Agreement that there shall be no delay in the execution of the Work; therefore, written decisions or directions rendered by the ENGINEER as the OWNER's representative shall be promptly carried out, and any claim arising therefrom shall be resolved as provided in Article 7. Unless otherwise specified, it is mutually agreed between the parties to this Agreement that the OWNER'S representative shall have the authority to issue written stop work orders whenever such stoppage may be necessary to insure the performance of the Work in accordance with the Contract Documents. 3.02 KEEPING OF PLANS AND SPECIFICATIONS ACCESSIBLE. The ENGINEER shall furnish the CONTRACTOR with four(4) copies of all Plans and Specifications without expense to the CONTRACTOR, and the CONTRACTOR shall keep one full size copy of the same constantly accessible on the job site, with the latest revisions noted thereon. The CONTRACTOR shall be responsible for preserving the Plans and Specifications, timely and accurately updated, for reference and review by the OWNER or the ENGINEER and submittal of redlines during closeout. 3.03 PRELIMINARY APPROVAL. The ENGINEER shall not have the power to waive the obligations imposed under this Contract for the furnishing by the CONTRACTOR of new material of good quality, and for good and workmanlike performance of the Work as herein described, and in full accordance with the Contract Documents, without alteration, deletion or change. No failure or omission of the OWNER'S representative to discover, object to or condemn any non-conforming or defective work or material, or to stop work, shall release the CONTRACTOR from the obligation to fully and properly perform the Contract, including without limitation, the obligation to at once remove and properly replace any defective work or material at any time prior to final acceptance, upon discovery of such non-conforming or defective work or material. Any questioned Work may be ordered taken up or removed for inspection by the ENGINEER prior to final acceptance, and if found not to be in accordance with the Contract Documents, all expense of removing, inspection and repair or replacement shall be borne by the CONTRACTOR; otherwise the expense thus incurred shall be allowed as Extra Work and shall be paid for by the OWNER, provided that where inspection or approval is specifically required by the Specifications prior to performance of certain work, should the CONTRACTOR proceed with such work without requesting prior inspection or approval, he shall bear all expense of taking up, removing and replacing this work if so directed by the ENGINEER. 10-2012 00700-6 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 3.04 INSPECTION BY ENGINEER. The ENGINEER will make periodic visits to the site to observe the progress and quality of the executed Work and to determine if such Work generally meets the essential performance and design features and the technical, functional /or engineering requirements of the Contract Documents, and is in all other respects being performed in compliance with the Contract Documents. However, the ENGINEER shall not be responsible for making any detailed, exhaustive, comprehensive or continuous on-site inspections to check the quality and/or quantity of the work, nor shall the ENGINEER be in any way responsible, directly or indirectly, for the construction means, methods, techniques, sequences, quality, procedures, programs, safety precautions or lack of same incident to the Work being performed or any part thereof. The ENGINEER shall use reasonable care to prevent deviation from the intent and substance of the Contract Documents by the CONTRACTOR in the performance of the Work and any part thereof and, on the basis of such on-site observations, will keep the OWNER informed of the progress of the work and will endeavor to guard the OWNER against defects and deficiencies in the Work of the CONTRACTOR. Notwithstanding any other provision of this Agreement or any other Contract Document, the ENGINEER shall not be in any way responsible or liable for any acts, errors, omissions or negligence of the CONTRACTOR, any subcontractors, agents, servants or employees or any other person, firm or corporation performing or attempting to perform any of the Work. 3.05 DETERMINATION OF QUESTIONS AND DISPUTES. In order to prevent delays and disputes and to discourage litigation, it is agreed that the ENGINEER shall, in all cases, determine the quantities and qualities of the several kinds of Work, which are to be paid for under this Contract. The ENGINEER shall address all questions in relation to said Work and the construction thereof, as well as all claims, disputes and other matters in question between the CONTRACTOR and the OWNER relating to the execution or progress of the Work or the interpretation of the Contract Documents. In the event the ENGINEER shall become aware of or shall receive information that there is a dispute or a possible dispute as to the reasonable interpretation of the terms and conditions of the Contract Documents, or any other dispute or question, the ENGINEER shall, within a reasonable time, provide a written interpretation of the Contract Documents or a written decision on all questions arising relative to the execution of the Work, copies of which shall be delivered to all parties to the Contract. If the CONTRACTOR or OWNER desires to take exception to any directions, order, interpretation or instructions of the ENGINEER, CONTRACTOR or OWNER shall present any such claim to the ENGINEER in accordance with the provisions of Section 7.04. 3.06 RECOMMENDATION OF PAYMENT. The ENGINEER shall review the CONTRACTOR's application for payment and supporting documents, shall determine the amount owed to the CONTRACTOR and shall provide written recommendation to the OWNER for payment to the CONTRACTOR in such amount. Such recommendation of payment to CONTRACTOR shall constitute a representation to the OWNER of the ENGINEER's judgment that the work has progressed to the point indicated, to the best of his knowledge, information and belief; however, such recommendation of an application for payment to CONTRACTOR shall not be deemed an acceptance of any defective or non-conforming Work. Any recommendation of payment by the ENGINEER shall be subject to OWNER's rights to withhold payment under Section 6.11 and as otherwise provided in the Contract. 10-2012 00700-7 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.0 RIGHTS AND RESPONSIBILITIES OF THE CONTRACTOR 4.01 INDEPENDENT CONTRACTOR. CONTRACTOR is, and shall remain, an independent contractor, solely responsible for the manner and method of completing the Work under this Contract, with full and exclusive power and authority to direct, supervise and control his own employees and to determine the means, method and manner of performing such Work, so long as such methods comply with the requirements of the Contract Documents, and do not adversely affect the completed improvements or any other property abutting or adjoining the Work area, the OWNER and ENGINEER being interested only in the result obtained and conformity of such completed improvements to the Plans, Specifications and Contract Documents. The fact that the OWNER or ENGINEER as the Owner's representative shall have the right to observe CONTRACTOR's work during his performance and to carry out the other prerogatives which are expressly reserved to and vested in the OWNER and the ENGINEER hereunder, is not intended to and shall not at any time change or affect the status of the CONTRACTOR as an independent contractor with respect to either the OWNER or the ENGINEER as the OWNER's representative or to the CONTRACTOR's own employees or to any other person, firm or corporation. 4.02 CONTRACTOR'S UNDERSTANDING. It is understood and agreed that the CONTRACTOR has, by careful examination, satisfied himself as to the nature and location of the Work, the conformation of the ground, the character, quality and quantity of the materials to be encountered, the character of equipment and facilities needed preliminary to and during the prosecution of the Work, the general and local conditions, including but not limited to weather, access, lay down and storage areas, and all other matters which in any way affect the Work under this Contract. It is further understood that the CONTRACTOR has satisfied himself as to the terms, meaning, intent and requirements of all of the Contract Documents, and applicable laws, codes, regulations and ordinances. CONTRACTOR hereby warrants and represents that it has taken into consideration all of the foregoing factors, and CONTRACTOR shall perform the Work for the Contract Price and within the Contract Time. No verbal agreement or conversation with any officer, agent or employee of the OWNER or the ENGINEER, either before or after the execution of this Contract, shall affect or modify any of the terms or obligations herein contained. 4.03 LAWS AND ORDINANCES. The CONTRACTOR shall at all times observe and comply with all federal, state or local laws, codes, ordinances, permits and regulations, regardless of whether the same are adopted before or after the execution of this Contract, which in any manner affect the Contract or the work, and shall indemnify, save and hold harmless the OWNER and the ENGINEER against any claim arising out of the violation of any such laws, ordinances and regulations, whether by the CONTRACTOR or his agents, employees, subcontractors or vendors. If the CONTRACTOR observes that the Plans and Specifications are at variance with federal or state laws or codes or the ordinances or regulations of the City, he shall promptly notify the ENGINEER in writing, and any necessary changes shall be made as provided in the Contract for changes in the work. If the CONTRACTOR performs any work knowing it to be contrary to such laws, codes, ordinances, rules or regulations, or if CONTRACTOR reasonably should have known of any such violation, and without such notice to the ENGINEER, CONTRACTOR shall bear all costs arising therefrom. The OWNER is a Political Subdivision of the State of Texas, and the law from which it derives its powers, insofar as the same regulates the objects for which, or the manner in which, or the conditions under which the OWNER may enter into contracts, shall be controlling and shall be considered as part of this Contract to the same effect as though embodied herein. Neither the act 10-2012 00700-8 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT of OWNER entering into this Contract, nor OWNER's performance hereunder, shall constitute a waiver of any immunity from suit enjoyed by OWNER under applicable law, all such rights and defenses being hereby expressly reserved, notwithstanding any term or provision herein to the contrary. The Code of Ordinances and other applicable regulations of the OWNER shall be deemed to be embodied in this Contract. The prevailing wage rates applicable to this Project shall be either Document 00811 —Wage Scale for Engineering Construction, or Document 00813 — Wage Scale for Building Construction, or both, as set out in the Project Manual. 4.04 ASSIGNMENT AND SUBLETTING. The CONTRACTOR further agrees that he will retain personal control and will give his personal attention to the fulfillment of this Contract and that he will not assign, by power of attorney or otherwise, or sublet said Contract, or any rights, duties or obligations arising thereunder, in whole or in part, without the prior written consent of the OWNER, and that no part or feature of the Work will be sublet to anyone objectionable to the ENGINEER or the OWNER. In addition, the OWNER reserves the right to disapprove the subletting of this Contract or any portion hereof on any basis whatsoever. The CONTRACTOR further agrees that the subletting of any portion or feature of the Work or materials required in the performance of this Contract shall not relieve the CONTRACTOR from his obligations to the OWNER, as provided for by this Agreement. 4.05 PERFORMANCE, PAYMENT AND MAINTENANCE BONDS. In the event the Contract Price shall be in excess of $25,000.00, the CONTRACTOR shall execute separate Performance, Payment and Maintenance Bonds, each in the sum of one hundred percent(100%) of the Contract Price, and each in accordance with the provisions of Chapter 2253 of the Texas Government Code. If the Contract Price does not exceed $25,000.00, the statutory bonds will not be required. All required Bonds shall be payable to OWNER and on forms approved by the OWNER, and shall be executed by a corporate surety in accordance with Article 7.19-1 of the Texas Insurance Code. It is agreed that the Contract shall not be in effect until such original Performance, Payment and Maintenance Bonds are delivered to and approved by the OWNER. The cost of the premium for the Performance, Payment and Maintenance Bonds, should Maintenance Bonds be required, shall be included in the CONTRACTOR's Bid Proposal. All bonds shall be issued by Texas Department of Insurance approved surety companies. 4.06 INSURANCE. The CONTRACTOR, at his own expense, shall procure, maintain and keep in force throughout the duration of the Work, and throughout the Guarantee Period, insurance as specified in Attachment No. 1 hereto with regard to Workers' Compensation Insurance, and as specified in Attachment No. 3 hereto with regard to all other Insurance. Such insurance shall be carried with an insurance company licensed to transact business in the State of Texas and shall cover all operations in connection with this Contract, whether performed by the CONTRACTOR or a subcontractor, or others for whom CONTRACTOR is responsible. 4.07 PERMITS AND FEES. Unless otherwise provided in the Contract Documents, the Contractor shall secure and pay for all permits, licenses, and inspections necessary for proper execution and completion of the Work, and which are legally required at the time bids are received. Permits required by the City of Pearland will be issued as a NO FEE permit. 4.08 TEXAS STATE SALES TAX. Materials incorporated into this project are exempt from State Sales according to provisions of the Texas Tax Code, Chapter 151, Subsection H. 10-2012 00700-9 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT The Contractor must obtain a limited sales, excise and use tax permit or exemption certificate which shall enable him to buy the materials to be incorporated into the Work without paying tax at due time of purchase. 4.09 CONTRACTOR'S DUTY AND SUPERINTENDENCE. The CONTRACTOR shall give adequate attention to the faithful prosecution and completion of this Contract and shall keep on the work, during its progress, a competent superintendent and any necessary assistants, all satisfactory to the ENGINEER as the OWNER'S representative. The superintendent shall represent the CONTRACTOR in his absence and shall act as the agent of the CONTRACTOR, and all directions given to him shall be binding as if given to the CONTRACTOR. Adequate supervision by competent and reasonable representatives of the CONTRACTOR is essential to the proper performance of the Work, and lack of such supervision shall be an act of default, and grounds for suspending operations of the CONTRACTOR. The Superintendent cannot be removed from the project without the consent of the Owner; the Superintendent must speak and understand the English language;the Superintendent must be on site when any work on the project is being done, even when a subcontractor is performing the work. The Work, from its commencement to completion, shall be under the exclusive charge and control of the CONTRACTOR, and all risk in connection therewith shall be borne by the CONTRACTOR. Neither the OWNER nor the ENGINEER as the OWNER's representative will be responsible for the acts or omissions of the CONTRACTOR, its subcontractors or any of its agents or employees, or any other persons performing any of the Work. 4.10 CHARACTER OF WORKERS. The CONTRACTOR agrees to employ only orderly and competent workers, skillful in the performance of the type of work required under this Contract, to do the Work, and agrees that whenever the ENGINEER shall inform him in writing that any worker or workers on the Work are, in his opinion, incompetent, unfaithful or disorderly, or in the ENGINEER's opinion, are not using their best efforts for the progress of the Work, such worker or workers shall be discharged from the Work and shall not again be employed on the Work without the ENGINEER's written consent. OWNER reserves the right to bar any person, subcontractor, or supplier found to be incompetent, unfaithful, disorderly, or not using their best efforts to progress work or considered to be a threat to the health, safety and welfare to the project or workforce. 4.11 LABOR, EQUIPMENT, MATERIALS, CONSTRUCTION PLANT, AND BUILDINGS. The CONTRACTOR shall provide all labor, services, tools, equipment, machinery, supplies, facilities, utilities and materials necessary in the prosecution and completion of this Contract where it is not otherwise specifically provided that the OWNER shall furnish same; and further, the CONTRACTOR shall be responsible for the care, preservation, conservation and protection of all materials, supplies, machinery, equipment, tools, apparatus, accessories, facilities, all means of construction and any and all parts of the Work, whether the CONTRACTOR has been paid, partially paid or not paid for such Work, until the entire Work is completed and accepted. The building or placement of structures for housing workers or offices, or the erection of tents or other forms of protection, will be permitted only with the ENGINEER's written permission, and at 10-2012 00700- 10 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT such places as the ENGINEER shall direct, and the sanitary conditions of the grounds in or about such structures shall at all times be maintained in a manner satisfactory to the ENGINEER. Any structures of any nature constructed, placed or erected by the CONTRACTOR for the purposes herein set out, shall be the sole responsibility of the CONTRACTOR as to the proper erection, placement or construction thereof; and the CONTRACTOR agrees to indemnify and hold the ENGINEER or OWNER harmless from any claims of any nature whatsoever brought against either of them for damages allegedly sustained by anyone by reason of the erection, placement, construction or maintenance of CONTRACTOR's buildings or structures. 4.12 SANITATION. Necessary sanitary conveniences for the use of laborers and others on the Work site, properly secluded from public observation, shall be constructed and maintained by the CONTRACTOR in such manner and at such points as shall be approved by the ENGINEER, and their use shall be strictly enforced. Any structures of any nature constructed or erected by the CONTRACTOR for the purposes herein set out, shall be the sole responsibility of the CONTRACTOR as to the proper erection or construction thereof, and the CONTRACTOR agrees to indemnify and hold the ENGINEER and OWNER harmless from any claims of any nature whatsoever brought against either of them for damages allegedly sustained by anyone by reason of the erection, construction or maintenance of CONTRACTOR's buildings. 4.13 CLEANING AND MAINTENANCE. The CONTRACTOR shall at all times keep and maintain the premises free from accumulation of debris, trash and waste. The CONTRACTOR shall remove waste, debris and trash at the end of each work day. CONTRACTOR shall remove all such debris, trash and waste, tools, scaffolding and surplus materials, and shall leave the Work broom-clean or its equivalent, upon completion of the Work. The Work shall be left in good order and condition. In case of dispute, the OWNER may remove the debris, trash, waste and surplus materials, and charge the cost to the CONTRACTOR. 4.14 PERFORMANCE OF WORK. It is further agreed that it is the intent of this Contract that all Work must be done and all material must be furnished in accordance with the generally accepted practice for such materials furnished or work completed, unless otherwise provided in the Contract Documents. 4.15 RIGHT OF OWNER TO ACCELERATE THE WORK. If at any time the methods or equipment used by the CONTRACTOR, or the work force supplied are found to be inadequate to achieve the progress required to Substantially Complete the Work within the Contract Time, the OWNER or the ENGINEER as the OWNER's representative, may order the CONTRACTOR in writing to supplement its forces and/or equipment, or work shifts or overtime, or otherwise improve its efficiency and rate of progress to achieve Substantial Completion of the Work within the Contract Time, and the CONTRACTOR shall comply with such order, at its own cost and expense. 4.16 LAYOUT OF WORK. Except as specifically provided herein, the CONTRACTOR shall be responsible for laying out work by means of construction surveying and shall accomplish this work in a manner acceptable to the ENGINEER and in conformance with the Contract Documents. 4.17 SHOP DRAWINGS. The CONTRACTOR shall submit to the ENGINEER, with such promptness as to cause no delay in his own Work or in that of any other contractor, six (6) checked copies, unless otherwise specified, of all shop and/or setting drawings and schedules 10-2012 00700- 11 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT required for the work of the various trades. Contractor will check and approve shop drawings for compliance with requirements of Contract Documents and will so certify by stamp on each drawing prior to submittal to ENGINEER. Any drawings submitted without Contractor's stamp of approval will not be considered and will be returned to him for proper submission. The ENGINEER shall pass upon them with reasonable promptness, indicating desired corrections. The CONTRACTOR shall make any corrections required by the ENGINEER, file with him two (2) corrected copies and furnish such other copies as may be needed. The ENGINEER's approval of such drawings or schedules shall not relieve the CONTRACTOR from responsibility for deviations from the Contract Documents, unless he has, in writing, called the ENGINEER's attention to such deviations at the time of the submission, and the ENGINEER has acknowledged and accepted such deviations in writing, nor shall it relieve him from responsibility for errors of any sort in shop drawings or schedules. It shall be the CONTRACTOR's responsibility to fully and completely review all shop drawings to ascertain their effect on his ability to perform the required Contract Work in accordance with the Contract Documents, and within the Contract Time. Such review by the ENGINEER shall be for the sole purpose of determining the apparent sufficiency of said drawings or schedules to result in finished improvements in conformity with the Contract Documents, and shall not relieve the CONTRACTOR of his duty as an independent contractor as previously set forth, it being expressly understood and agreed that the ENGINEER does not assume any duty to pass upon the propriety or adequacy of such drawings or schedules, or any means or methods reflected thereby, in relation to the safety of either person or property during CONTRACTOR's performance hereunder, and any action taken by the ENGINEER shall not relieve the CONTRACTOR of his responsibility and liability to comply with the Contract Documents. OWNER, CONSTRUCTION MANAGER, ENGINEER, and CONTRACTOR shall make all submittals, review comments, notes, corrections, schedules and updates, testing results, payment applications, instructions and other communications by means of the OWNER'S Pro-Trak. The OWNER, ENGINEER and CONTRACTOR shall each retain such hard copies form this system as are required for their specific record keeping requirements. No documents shall be removed from this system or destroyed except those being replaced by the systems protocols as a latest version document. All requirements for written communications, submittals, comments, instructions or other documents processed by means of this system shall have the same legal or time sensitive status as if they had been hand delivered in hard copy to their intended addressee. 4.18 ENGINEER-CON TRACTOR RELATIONSHIP; OBSERVATIONS. It is agreed by the CONTRACTOR that the ENGINEER, as the OWNER's representative, shall be and is hereby authorized to appoint such subordinate engineers, representatives or observers as the said ENGINEER may from time to time deem proper to observe the materials furnished and the Work done under this Agreement. The CONTRACTOR shall furnish all reasonable aid and assistance required by the subordinate engineers, representatives or observers for the proper observation and examination of the work. The CONTRACTOR shall regard and obey the directions and instructions of any subordinate engineers, representatives or observers so appointed, when such directions and instructions are consistent with the obligations of this Agreement and the Contract Documents, provided, however, should the CONTRACTOR object to any orders by any 10-2012 00700- 12 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT subordinate engineer, representative or observer, the CONTRACTOR may, within three (3) days, make written appeal to the ENGINEER for his decision. 4.19 OBSERVATION AND TESTING. The OWNER or the ENGINEER as the OWNER's representative shall have the right at all reasonable times to observe, inspect and test the Work. The CONTRACTOR shall make all necessary arrangements and provide proper facilities and access for such observation, inspection and testing at any location wherever Work is in preparation or progress. The CONTRACTOR shall ascertain the scope of any observation, inspection or testing which may be contemplated by the OWNER or the ENGINEER and shall give ample notice as to the time each part of the Work will be ready for such observation, inspection or testing. The OWNER or the ENGINEER may reject any Work found to be defective or not in accordance with the Contract Documents, regardless of the stage of its completion or the time or place of discovery of such deficiencies, and regardless of whether the ENGINEER has previously accepted the Work through oversight or otherwise. If any Work is covered without approval or consent of the OWNER, it must, if requested by the OWNER or the ENGINEER, be uncovered for examination, at the sole expense of the CONTRACTOR. In the event that any part of the Work is being fabricated or manufactured at a location where it is not convenient for the OWNER or the ENGINEER to make observations of such Work or require testing of said Work, then in such event, the OWNER or the ENGINEER may require the CONTRACTOR to furnish the OWNER or the ENGINEER with certificates of inspection, testing or approval made by independent persons competent to perform such tasks at the location where that part of the work is being manufactured or fabricated. All such tests will be in accordance with the methods prescribed by the American Society for Testing and Materials or such other applicable organization as may be required by law or the Contract Documents. If any Work, which is required to be inspected, tested or approved, is covered up without written approval or consent of the OWNER or the ENGINEER, it must, if requested by the OWNER or the ENGINEER, be uncovered for observation and testing, at the sole expense of the CONTRACTOR. The cost of all such inspections, tests and approvals shall be borne by the CONTRACTOR unless otherwise provided herein. Any Work which fails to meet the requirements of such tests, inspections or approval, and any Work which meets the requirements of any such tests or approval but does not meet the requirements of the Contract Documents shall be considered defective. Such defective Work and any other work affected thereby shall be corrected at the CONTRACTOR'S expense. Neither observations by the OWNER or by the ENGINEER, nor inspections, certifications, tests or approvals made by the OWNER, the ENGINEER or other persons authorized under this Agreement to make such inspections, tests or approvals, shall relieve the CONTRACTOR from his obligation to perform the Work in accordance with the requirements of the Contract Documents. 4.20 DEFECTS AND THEIR REMEDIES. It is further agreed that if the Work or any part thereof or any material brought on the site of the Work for use in the Work or selected for the same, shall be deemed by the ENGINEER as unsuitable or not in conformity with the Contract Documents, the CONTRACTOR shall, after receipt of written notice thereof from the ENGINEER, forthwith remove such material and rebuild or otherwise remedy such Work so that it shall be in full accordance with this Contract, It is further agreed that any such remedial action contemplated herein shall be at CONTRACTOR's expense. 10-2012 00700- 13 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.21 LIABILITY FOR PROPER PERFORMANCE. Engineering construction drawings and specifications, as well as any additional instructions and information concerning the Work to be performed, passing from or through the ENGINEER, shall not be interpreted as requiring or allowing the CONTRACTOR to deviate from the Contract Documents, the intent of such drawings, specifications and any other such instructions being to define with particularity the agreement of the parties as to Work the CONTRACTOR is to perform. CONTRACTOR shall be fully and completely liable and contractually bound, at his own expense, for design, construction, installation and use or non-use of all items and methods incident to the performance of the Contract, including, without limitation, the adequacy of all temporary supports, shoring, bracing, scaffolding, machinery or equipment, safety precautions or devices, similar items or devices used by him during construction, and work performed either directly or incident to construction, and for all loss, damage or injury incident thereto, either to person or property, whether such damage be suffered by the ENGINEER,the OWNER or any other person not a party to this Contract. Any review of Work in progress or any visit or observation during construction, or any clarification of Contract Documents by the ENGINEER or OWNER, or any agent, employee or representative of either of them, whether through personal observation on the Project site or by means of approval of shop drawings for construction or construction processes, or by other means or methods, is agreed by the CONTRACTOR to be for the purpose of observing the extent and nature of Work completed or being performed, as measured against the Contract Documents, or for the purpose of enabling the CONTRACTOR to more fully understand the Contract Documents so that the completed construction Work will conform thereto, and shall in no way relieve the CONTRACTOR from full and complete responsibility for proper performance of his Work on the Project, including, without limitation, the propriety of means and methods of the CONTRACTOR in performing said Contract, and the adequacy of any designs, plans or other facilities for accomplishing such performance. Any action by the ENGINEER or the OWNER in visiting or observing during construction, or any clarification of Contract Documents shall not constitute a waiver of CONTRACTOR'S liability for damages as herein set out. Deviation by the CONTRACTOR from Contract Documents, whether called to the CONTRACTOR's attention or not, shall in no way relieve CONTRACTOR from his responsibility to complete all work in accordance with said Contract Documents, and further shall not relieve CONTRACTOR of his liability for loss, damage or injury as herein set out. 4.22 PROTECTION AGAINST ACCIDENT TO EMPLOYEES AND THE PUBLIC. The CONTRACTOR shall be solely responsible for the safety of himself, his employees and persons entering the project site, as well as for the protection of the improvements being erected and the property of himself or any other person, as a result of his operations hereunder. The CONTRACTOR shall take out and procure a policy or policies of Workers' Compensation Insurance with an insurance company licensed to transact business in the State of Texas, which policy shall comply with the Workers' Compensation laws of the State of Texas. The CONTRACTOR shall at all times exercise reasonable precautions for the safety of employees and others on or near the Work and shall comply with all applicable provisions of federal, state and municipal laws and building and construction codes. All machinery and equipment and other physical hazards shall be guarded, as a minimum, in accordance with the "Manual of Accident Prevention in Construction" of the Associated General Contractors of America, except where incompatible with federal, state or municipal laws or regulations. The CONTRACTOR shall provide all necessary machinery guards, safe walkways, ladders, bridges, gangplanks, barricades, fences, traffic control, warning signs and other safety devices. 10-2012 00700- 14 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT No alcoholic beverages, non-prescription drugs, or unsafe practices shall be allowed on the Work site. CONTRACTOR shall dismiss anyone participating in any of the above from the Work site for the duration of the Project. Only prescription drug uses with a doctor's authorization to perform construction activities shall be allowed on the Work site. Violation of this provision is a default under the Contract. The use, possession, sale, transfer, purchase or being under the influence of alcohol, drugs or any other illegal or unlawful substance by CONTRACTOR or CONTRACTOR's employees, or CONTRACTOR's subcontractors and employees at any time at the Work site or while on company business is prohibited. CONTRACTOR shall institute and enforce appropriate drug testing guidelines and program. All accidents or injuries to CONTRACTOR's employees working on the job site must be reported verbally and in writing to the ENGINEER immediately, and within no more than eight (8)hours. The safety precautions actually taken and their adequacy shall be the sole responsibility of the CONTRACTOR, in his sole discretion as an independent contractor. Inclusion of this paragraph in the Agreement, as well as any notice which may be given by the OWNER or the ENGINEER as the OWNER's representative concerning omissions under thus paragraph as the Work progresses, are intended as reminders to the CONTRACTOR of his duty and shall not be construed as any assumption of duty by ENGINEER, or OWNER's representative to supervise safety precautions by either the CONTRACTOR or any of his subcontractors. 4.23 PROTECTION OF ADJOINING PROPERTY. The CONTRACTOR shall employ proper means to protect the adjacent or adjoining property or properties in any way encountered, which might be injured or seriously affected by any process of construction to be undertaken under this Agreement, from any damage or injury by reason of said process of construction; and he shall be liable for any and all claims for such damage on account of his failure to fully protect all adjacent or adjoining property. THE CONTRACTOR AGREES TO INDEMNIFY, DEFEND, SAVE AND HOLD HARMLESS THE CONSTRUCTION MANAGER, OWNER AND ENGINEER AGAINST ANY CLAIM OR CLAIMS FOR DAMAGES, LOSS, COSTS OR EXPENSES, INCLUDING BUT NOT LIMITED TO ATTORNEY'S FEES, DUE TO ANY INJURY TO ANY ADJACENT OR ADJOINING PROPERTY, ARISING OR GROWING OUT OF THE PERFORMANCE OF THE CONTRACT, REGARDLESS OF WHETHER OR NOT SUCH DAMAGE, LOSS, COST OR EXPENSE IS CAUSED IN PART BY THE NEGLIGENCE, GROSS NEGLIGENCE OR STRICT LIABILITY OF OWNER AND/OR ENGINEER. 4.24 PROTECTION AGAINST CLAIMS OF SUBCONTRACTORS, LABORERS, MATERIALMEN AND FURNISHERS OF MACHINERY, EQUIPMENT AND SUPPLIES. THE CONTRACTOR AGREES THAT HE WILL PROMPTLY PAY WHEN DUE, AND WILL INDEMNIFY, SAVE AND HOLD THE OWNER AND THE ENGINEER HARMLESS FROM ALL CLAIMS GROWING OUT OF THE DEMANDS OF SUBCONTRACTORS, LABORERS, WORKERS, MECHANICS, MATERIALMEN AND FURNISHERS OF MACHINERY AND PARTS THEREOF, EQUIPMENT, POWER TOOLS AND ALL SUPPLIES, INCLUDING COMMISSARY, INCURRED IN THE FURTHERANCE OF THE PERFORMANCE OF THIS CONTRACT. When so desired by the OWNER, the CONTRACTOR shall furnish satisfactory evidence that all obligations of the nature hereinabove designated have been paid, discharged or waived. If the CONTRACTOR fails to do so, then the OWNER may, at the option of the OWNER, either pay directly any unpaid bills of which the OWNER has written notice, or withhold from the CONTRACTOR's unpaid compensation a sum of money deemed reasonably 10-2012 00700- 15 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT sufficient to liquidate any and all such claims until satisfactory evidence is furnished that all liabilities have been fully discharged, whereupon payments to the CONTRACTOR shall be resumed in full, in accordance with the terms of this Contract. Any and all communications between any parties under this paragraph shall be in writing. Nothing contained in this paragraph or this Agreement shall create, establish or impose any relationship, contractual or otherwise, between OWNER and any subcontractor, laborer or supplier of CONTRACTOR, nor shall it create, establish or impose any duty upon OWNER to pay or to see to the payment of any subcontractor, laborer or supplier of CONTRACTOR. 4.25 PROTECTION AGAINST ROYALTIES OR PATENTED INVENTION. The CONTRACTOR shall pay all royalties and license fees and shall provide for the use of any design, device, material or process covered by letters patent or copyright, by suitable legal agreement with the patentee or owner thereof THE CONTRACTOR SHALL DEFEND ALL SUITS OR CLAIMS FOR INFRINGEMENT OF ANY PATENT OR COPYRIGHT AND SHALL INDEMNIFY, SAVE AND HOLD THE OWNER AND THE ENGINEER HARMLESS FROM ANY LOSS OR LIABILITY ON ACCOUNT THEREOF, EXCEPT SUCH SUITS AND CLAIMS ARISING OUT OF A PARTICULAR DESIGN, DEVICE, MATERIAL OR PROCESS OR THE PRODUCT OF A PARTICULAR MANUFACTURER OR MANUFACTURERS SPECIFIED OR REQUIRED BY THE OWNER; PROVIDED, HOWEVER, IF CHOICE OF ALTERNATE DESIGN, DEVICE, MATERIAL OR PROCESS IS ALLOWED TO THE CONTRACTOR, OR IF CONTRACTOR KNEW OR SHOULD HAVE KNOWN OF THE PATENT OR COPYRIGHT AND FAILED TO PROMPTLY NOTIFY OWNER IN WRITING, THEN THE CONTRACTOR SHALL INDEMNIFY, DEFEND, SAVE AND HOLD THE OWNER HARMLESS FROM ANY LOSS OR LIABILITY ON ACCOUNT THEREOF. 4.26 INDEMNIFICATION. THE CONTRACTOR AGREES TO DEFEND, INDEMNIFY AND HOLD THE ENGINEER AND THE OWNER HARMLESS FROM ANY CLAIMS OR DEMANDS OF ANY NATURE WHATSOEVER MADE BY ANY EMPLOYEE, EMPLOYEES, AGENTS OR SUBCONTRACTORS OF CONTRACTOR, OR BY ANY UNION, TRADE ASSOCIATION, WORKER'S ASSOCIATION OR OTHER GROUPS, ASSOCIATIONS OR INDIVIDUALS, ALLEGEDLY REPRESENTING EMPLOYEES OF THE CONTRACTOR, IN ANY DISPUTE BETWEEN THE CONTRACTOR AND HIS EMPLOYEES, DIRECTLY OR INDIRECTLY INVOLVING, GROWING OUT OF OR ARISING FROM CLAIMS BY SUCH EMPLOYEES FOR WAGES, SALARY, COMPENSATION, BENEFITS, WORKING CONDITIONS OR ANY OTHER SIMILAR COMPLAINT OR CLAIM WHICH MAY BE MADE. THE CONTRACTOR, HIS SURETIES AND INSURANCE CARRIERS SHALL DEFEND, INDEMNIFY AND HOLD HARMLESS THE OWNER AND THE ENGINEER AND THEIR RESPECTIVE OFFICERS, REPRESENTATIVES, AGENTS AND EMPLOYEES FROM AND AGAINST ALL DAMAGES, CLAIMS, LOSSES, DEMANDS, SUITS, LIABILITIES, JUDGMENTS AND COSTS OF ANY CHARACTER WHATSOEVER, INCLUDING REASONABLE ATTORNEY'S FEES AND EXPENSES, AND SHALL BE REQUIRED TO PAY ANY JUDGMENT THEREFOR, WITH COSTS, WHICH MAY BE OBTAINED AGAINST THE OWNER AND/OR THE ENGINEER OR ANY OF THEIR OFFICERS, REPRESENTATIVES, AGENTS OR EMPLOYEES, ARISING OUT OF OR RESULTING FROM OR ALLEGEDLY ARISING OUT OF OR RESULTING FROM THE PERFORMANCE 10-2012 00700- 16 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT OF THE WORK, PROVIDED THAT ANY SUCH DAMAGES, CLAIM, LOSS, DEMAND, SUIT, LIABILITY, JUDGMENT, COST OR EXPENSE: (A) ARISES OUT OF OR RESULTS FROM IN WHOLE OR IN PART, OR ALLEGEDLY ARISES OUT OF OR RESULTS FROM IN WHOLE OR IN PART, ANY BREACH OF THIS AGREEMENT OR BREACH OF WARRANTY BY CONTRACTOR; OR (B) IS ATTRIBUTABLE TO BODILY INJURY, SICKNESS, DISEASE OR DEATH OR INJURY TO OR DESTRUCTION OF TANGIBLE PROPERTY, INCLUDING THE LOSS OF USE RESULTING THEREFROM; AND IS CAUSED IN WHOLE OR IN PART OR IS ALLEGEDLY CAUSED IN WHOLE OR IN PART BY ANY NEGLIGENT ACT OR OMISSION OF THE CONTRACTOR, ANY SUBCONTRACTOR, THEIR AGENTS OR EMPLOYEES OR ANYONE DIRECTLY OR INDIRECTLY EMPLOYED BY ANY ONE OF THEM OR ANYONE FOR WHOSE ACTS ANY OF THEM MAY BE LIABLE, REGARDLESS OF WHETHER OR NOT IT IS CAUSED IN PART OR ALLEGEDLY CAUSED IN PART BY THE NEGLIGENCE, GROSS NEGLIGENCE OR STRICT LIABILITY OF OWNER, ENGINEER AND/OR A PARTY INDEMNIFIED HEREUNDER. Notwithstanding the foregoing or anything in the Agreement to the contrary, in accordance with the provisions of Section 130.002 of the Texas Civil Practice and Remedies Code, CONTRACTOR shall not be obligated to indemnify or hold harmless the ENGINEER, his agents, servants or employees, from liability for damage that is caused by or results from defects in plans, designs or specifications prepared, approved or used by the ENGINEER, or negligence of the ENGINEER in the rendition or conduct of professional duties called for or arising out of any construction contract and the plans, designs or specifications that are a part of the construction contract, and arises from personal injury or death, property injury, or any other expense that arises from personal injury, death, or property injury. This indemnity agreement is a continuing obligation, and shall survive notwithstanding completion of the Work, Final Payment, expiration of the warranty period, termination of the Contract, and abandonment or takeover of the Work. CONTRACTOR's indemnification obligations hereunder shall not be limited by a limitation on amount or type of damages, compensation or benefits payable by or for the CONTRACTOR or a subcontractor under workers' compensation acts, disability benefit acts or other employee benefit acts, and shall not be limited by any limitation on amounts or coverage of insurance provided or to be provided under this Contract. 4.27 LOSSES FROM NATURAL CAUSES. All loss, cost, expense or damage to the CONTRACTOR arising out of the nature of the Work to be done or from any unforeseen circumstances in the prosecution of the same, or from the action of the elements, or from unusual obstructions or difficulties which may be encountered in the prosecution of the Work, shall be sustained and borne by the CONTRACTOR at his own cost and expense. 10-2012 00700- 17 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.28 GUARANTEE. The CONTRACTOR hereby guarantees all the Work under the Contract to be free from defects or deficiencies in material in every particular and free from defects or deficiencies in workmanship; and against unusual damage from proper and usual use; and agrees to replace or to re-execute without cost to the OWNER such Work as may be found to be defective, deficient or otherwise not in conformance with the Contract Documents, and to make good all damages caused to other work or material, due to such defective Work or due to its required replacement or re-execution. This guarantee shall cover a period of one year from the date of Substantial Completion or Partial Substantial Completion of Work under the Contract, as evidenced by the Certificate of Substantial Completion. Neither the Certificate of Substantial Completion, Final Payment, nor any provision in the Contract Documents shall relieve the CONTRACTOR of the responsibility for defective, deficient or non-conforming material or workmanship during the period covered by the guarantee. The one-year period of guarantee will not limit the OWNER'S other rights under common law with respect to any defects, deficiencies or non-conforming Work discovered after one year. If this one-year guarantee conflicts with other warranties or guarantees, the longer period of warranty or guarantee will govern. 5.0 PROSECUTION AND PROGRESS 5.01 TIME AND ORDER OF COMPLETION. It is the meaning and intent of this Contract, unless otherwise herein specifically provided, that the CONTRACTOR shall be allowed to prosecute his Work at such times and seasons, in such order of precedence, and in such manner as shall be most conducive to economy of construction; provided, however, that the order and the time of prosecution shall be such that the Work shall be Substantially Completed as a whole and in part, in accordance with this Contract and the Contract Time; provided, also, that when the OWNER is having other work done, either by contract or by his own forces, the ENGINEER may direct the time and manner of constructing the Work done under this Contract, so that conflict will be avoided and the construction of the various works being done for the OWNER shall be harmonized, and the CONTRACTOR shall fully cooperate and coordinate its Work with OWNER or such other contractors. The CONTRACTOR shall submit, an updated schedule with every pay estimate for review by the ENGINEER, schedules which shall show the order in which the CONTRACTOR proposes to carry on the Work, with dates on which the CONTRACTOR will start the several parts of the work, and estimated dates of completion of the several parts. Such schedules shall show completion of the Work within the Contract Time, and/or shall show such recovery efforts as CONTRACTOR intends to undertake in the event Substantial Completion of the Work is delayed. 5.02 EXTENSION OF TIME. The CONTRACTOR agrees that he has submitted his Bid Proposal in full recognition of the time required for the completion of this Project, taking into consideration the average climatic range and industrial conditions prevailing in this locality, and has considered the liquidated damage provisions as hereinafter set forth, and that he shall not be entitled to, nor will he request, an extension of time on this Contract, except when Substantial Completion of the Work has been delayed solely by strikes, lockouts, fires, Acts of God, or by any other cause which the ENGINEER shall decide justifies the delay. The CONTRACTOR shall give the ENGINEER prompt notice, in writing and within three (3) days of the start of any such delay, of the cause of any such delay, and its estimated effect on the Work and the schedule for completion of the Work. Upon receipt of a written request for an extension of the Contract Time from the CONTRACTOR, supported by relevant and all requested documentation, the 10-2012 00700- 18 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT ENGINEER shall submit such written request, together with his written recommendation, to the OWNER for consideration. If the delay is not attributable in whole or in part to any act or omission of CONTRACTOR, its subcontractors or suppliers, and if the OWNER determines that CONTRACTOR is entitled to an extension of time under the terms of the Contract, the OWNER shall grant an extension of time for Substantial Completion of the Work, sufficient to compensate for the delay, and such extension of time shall be CONTRACTOR's sole and exclusive remedy, except as may be otherwise provided herein. No extensions of Contract Time shall be made for delays occurring prior to the Contractor's mobilization as defined in Section 01505 MOBILIZATION. The Contract Time as defined in the Bid Proposal and other sections herein incorporates 40 Rain Days per calendar year or an average of 3.33 days per calendar month. The CONTRACTOR is required to keep record of all weather related delays and to submit the monthly count on each Pay Application. The Owner's Representative shall review and sign off on this record as a part of the Pay Application approval process every month. If, during preparation of the Balancing Change Order, the status of the work progress requires an extension of the Contract Time, Impact Days shall be added to the Completion Date equal to the total number of Weather or Impact Days approved less the original 40 days resident in the original Contract Time. The Addition of Weather or Impact Days will only alter the Contract Time when added by Change Order. If the Work is completed prior to the Completion Date, No Days will be added. The addition of Weather or Impact Days shall be the CONTRACTOR's sole remedy for delays to the completion of the Work and their addition to the Contract Time shall not affect the Contract Price through any "per diem" adjustment to the General Conditions costs, Temporary Facilities costs or any other costs associated with the extension of the Contract Time. 5.03 HINDRANCES AND DELAYS. In executing the Contract, the CONTRACTOR agrees that in undertaking to complete the Work within the time herein fixed, he has taken into consideration and made allowances for all interference, disruption, hindrances and delays incident to such Work, whether growing out of delays in securing material, workmen or otherwise. No claim shall be made by the CONTRACTOR for damages, loss, costs or expense resulting from interference, disruption,hindrances or delays from any cause during the progress of any portion of the Work embraced in this Contract, except where the Work is stopped or suspended by order of the OWNER's representative and such stoppage or suspension is not attributable to any act or omission of CONTRACTOR. 5.04 SUSPENSION OF WORK. OWNER may, without cause, order the CON TRACTOR in writing to suspend the Work, in whole or in part, for such period of time as OWNER may request. The Contract Price and/or Contract Time shall be adjusted for any increase in the cost of or the time required for performance of the Work caused by such suspension. No adjustment shall be made to the extent performance was or would have been suspended by a cause for which CONTRACTOR is responsible, or to the extent an adjustment is made or denied under another provision of the Contract Documents. 5.05 LIQUIDATED DAMAGES FOR DELAY: It is understood and agreed that time is of the essence, and that the CONTRACTOR will commence the Work on the date specified herein or in any Notice to Proceed, and will Substantially Complete the Work within the Contract Time. It is expressly understood and agreed, by and between the CONTRACTOR and the OWNER, that the time for the Substantial Completion of the Work described herein is reasonable time for the completion of the same, taking into consideration the average climatic range and conditions and usual industrial conditions prevailing in this locality. The CONTRACTOR further 10-2012 00700- 19 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT agrees that a failure to complete on time will cause damage to the OWNER and that such damages cannot be accurately measured or that ascertainment will be difficult. Therefore, the parties agree that for each and every calendar day the Work or any portion thereof shall remain uncompleted after the expiration of the Contract Time, the CONTRACTOR shall pay, as liquidated damages and as a reasonable estimate of OWNER's damages, and not as a penalty,the amount set out in the Standard Form of Agreement. However, the foregoing agreement as to liquidated damages constitutes only an agreement by the OWNER and the CONTRACTOR as to the amount of damages which the OWNER will sustain by reason of the CONTRACTOR'S failure to complete the work within the Contract Time. Should the OWNER suffer damage by reason of any other breach by CONTRACTOR, the OWNER may recover such actual damages in addition to any liquidated damages due. The OWNER shall have the right to deduct and withhold the amount of any and all such damages whether it be the minimum amount stipulated above or otherwise, from any monies owing by it to said CONTRACTOR, or the OWNER may recover such amount from the CONTRACTOR and the sureties of his bond; all of such remedies shall be cumulative and the OWNER shall not be required to elect any one nor be deemed to have made an election by proceeding to enforce any one remedy. 5.06 CHANGE OF CONTRACT TIME: The Contract Time may only be changed by a Change Order. Any claim for an adjustment of Contract Time shall be based on written notice delivered by the party making such claim to the other party and to the ENGINEER promptly, but in no event later than ten (10) days after the event-giving rise to the claim. Notice of the extent of the claim, along with supporting data, shall be delivered within thirty (30) days of the occurrence and shall be accompanied by the claimant's written representation that the adjustment claimed is the entire adjustment to which the claimant has reason to believe it is entitled as a result of the occurrence of said event. All claims for adjustment in Contract Time shall be determined by the ENGINEER in accordance with the requirements of this paragraph. Contractor shall submit, as a minimum, the following data: A. Information showing that the time requested is not included in the existing Contract and in addition to the Contract. B. Information documenting that the number of days requested is accurate for the event. C. Revised, current construction schedule showing that the time requested affects the project's critical path. 5.07 DELAYS BEYOND OWNER'S AND CONTRACTOR'S CONTROL: Where CONTRACTOR is prevented from completing any part of the Work within the Contract Time due to delays beyond the control of the OWNER and the CONTRACTOR, including, but not limited to, interference by utility owners or other contractors performing other work, Contractor shall be entitled to an extension of the Contract Time in an amount equal to the time lost. CONTRACTOR shall not be entitled to any increase in Contract Price as a result of such delays. IN NO EVENT SHALL OWNER BE LIABLE TO CONTRACTOR FOR DAMAGES ARISING OUT OF OR RESULTING FROM (i) Delays caused by, or within the control of, the CONTRACTOR, or (ii) Delays beyond the control of both parties including, but not limited to, interference by utility owners or other contractors performing other work, fires, floods, epidemics, abnormal weather conditions, acts of God, even if such delays are due in part to the negligence, other fault, breach of contract or warranty, violation of the Texas Deceptive Trade Act, or strict liability without regard 10-2012 00700-20 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT to fault of OWNER. An extension of Contract time shall be CONTRACTOR's sole and exclusive remedy for any such delays. Delays attributed to, and within the control of, a Subcontractor or Supplier shall be deemed to be delays within the control of the CONTRACTOR. 6.0 MEASUREMENT AND PAYMENT 6.01 DISCREPANCIES AND OMISSIONS. If the CONTRACTOR knows or reasonably should have known of any discrepancies or omissions in the Contract Documents, he shall notify the ENGINEER and obtain a clarification by Addendum before the bids are received, and if no such request is received by the ENGINEER prior to the opening of bids, then it shall be considered that the CONTRACTOR fully understands the Work to be performed and has provided sufficient sums in his Bid Proposal to complete the Work in accordance with the Contract Documents. It is further understood that any request for clarification must be submitted no later than five (5) days prior to the opening of bids. 6.02 QUANTITIES AND MEASUREMENTS. No extra or customary measurements of any kind will be allowed, but the actual measured and/or computed length, area, volume, number and weight only shall be considered, unless otherwise specifically provided. 6.03 ESTIMATED QUANTITIES. This Agreement, including the Contract Documents, and including any estimates contained therein, is intended to convey all Work to be done and material to be furnished hereunder. Where the estimated quantities are shown for the various classes of Work to be done and material to be furnished under this Contract, they are approximate and are to be used only as a basis for estimating the probable cost of the Work and for comparing the Bid Proposals offered for the Work. It is understood and agreed that the actual amount of Work to be done and the materials to be furnished under this Contract may differ from the estimates and that the items listed or estimated quantities stated, and/or any difference between estimated and actual Work, shall not give rise to a claim by the CONTRACTOR against the OWNER for loss, cost, expense, damages, unit price adjustment, quantity differences, unrecovered overhead or lost or anticipated profits, or other compensation. 6.04 PRICE OF WORK. It is agreed that it is the intent of this Contract that all Work described in the Bid Proposal, and Contract Documents, is to be done for the prices bid by the CONTRACTOR and that such prices shall include all appurtenances necessary to complete the Work in accordance with the intent of these Contract Documents as interpreted by the ENGINEER, and all costs, expenses, bond and insurance premiums, taxes, overhead, and profit. In consideration of the furnishing of all the necessary labor, equipment and material and the completion of all Work by the CONTRACTOR, and upon the completion of all Work and the delivery of all materials embraced in this Contract in full conformity with the Contract Documents, the OWNER agrees to pay to the CONTRACTOR the prices set forth in the Standard Form of Agreement, OWNER and CONTRACTOR agree that the Contract is a unit cost agreement, unless stated otherwise, and that the final Contract amount is equal to the unit cost multiplied by the number of units authorized, installed and approved by the Owner. The OWNER does not assume any obligation to pay for any services or material not actually authorized and used. The CONTRACTOR hereby agrees to receive such prices as payment in full for furnishing all materials and all labor required for the aforesaid Work, and for 10-2012 00700-21 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT all expenses incurred by him, and for full performance of the Work and the whole thereof in the manner and according to this Agreement, Contract Documents, and the requirements of the ENGINEER. 6.05 PAYMENTS. No payments made or approvals or certificates given shall be considered as conclusive evidence of the performance of the Contract, either in whole or in part, nor shall any certificate, approval or payment be considered as acceptance of defective, deficient or non-conforming Work. CONTRACTOR shall, at any time requested during the progress of the Work, furnish the OWNER or the ENGINEER with an affidavit showing the CONTRACTOR's total outstanding indebtedness in connection with the Work. Before Final Payment is made, the CONTRACTOR shall satisfy the OWNER, by affidavit or otherwise, that there are no unpaid claims due subcontractors, suppliers or laborers by reason of any Work under the Contract. Acceptance by CONTRACTOR of Final Payment shall constitute a waiver of any and all claims of whatsoever nature against OWNER, arising out of or related to the Contract, or the Work, or any acts or omissions of OWNER or ENGINEER, which have not theretofore been timely filed as provided in this Contract. 6.06 PARTIAL PAYMENTS. When the Contract Price is a lump sum amount,prior to the first Application for Payment, CONTRACTOR shall submit to ENGINEER for review and approval a Schedule of Values, which shall fairly allocate the entire Contract Price among the various portions of the Work and shall be prepared in such form and supported by such data to substantiate its accuracy as the ENGINEER may reasonably require. The Schedule of Values shall follow the trade divisions of the Specifications so far as practicable. Upon approval, this Schedule of Values shall be used by ENGINEER as the basis for reviewing the Contractor's Application for Payment. Applications for Payment shall indicate the percentage of completion of each portion of the Work as of the end of the period covered by the Application for Payment. On or before the tenth day of each month, the CONTRACTOR shall prepare and submit to the ENGINEER, for approval or correction, an application for partial payment, being a statement showing as completely as practicable, the agreed unit quantities and extended total value of the Work done by the CONTRACTOR up to and including the twenty-fifth day of the preceding month; said statement shall also include the value of all conforming materials to be fabricated into the Work and stored in accordance with manufacturer's recommendations and as approved by the OWNER or ENGINEER at the Work site only. No payment will be made for materials stored until OWNER has approved in writing storage at the Work site. The ENGINEER shall then review such statement of unit quantities and application for partial payment and the progress of the Work made by the CONTRACTOR and, within ten days after the date ENGINEER receives CONTRACTOR's application for payment, if the application is found to be accurate and correct and the WORK conforming to the requirements of the Contract Documents, the ENGINEER shall certify the application for partial payment and shall deliver his preliminary certification for payment to the OWNER and the CONTRACTOR; or, if the ENGINEER finds that CONTRACTOR's application for payment contains an error or is otherwise disputed, he shall notify CONTRACTOR of such error or dispute, and shall prepare a preliminary certificate for partial payment for the undisputed amount of the application for payment due CONTRACTOR, and deliver it to the OWNER and CONTRACTOR. ENGINEER'S notice to CONTRACTOR that a bona fide dispute for payment exists shall include a list of the specific reasons for nonpayment. All payment applications made by CONTRACTOR and delivered to ENGINEER and all verifications and certification of such applications shall be made and transmitted within the Pro- Trak system and signed with the appropriate electronic signatures as provided for in the software. 10-2012 00700-22 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Such applications for payment shall not be considered complete unless accompanied by the CONTRACTOR'S Partial Waiver of Lien and Payment Affidavit, Section 00615, duly executed by an authorized representative of the CONTRACTOR and reflecting the correct corresponding amount of the payment application. The OWNER shall then pay the CONTRACTOR, within thirty (30) days of the date of ENGINEER's receipt of the application for payment, the undisputed balance due, less applicable retainage, and further less all previous payments and all further sums that may be retained or withheld by the OWNER under the terms of this Agreement. CONTRACTOR may submit a corrected application for payment after its receipt of the ENGINEER's notice of error or dispute, and such corrected application for payment shall be reviewed by the ENGINEER and disputed or paid under the same procedure and within the same time limits set out above. As a condition of any progress payment under this Agreement, CONTRACTOR shall execute and deliver to ENGINEER and OWNER a full release of all claims, direct or indirect, at law or in equity, arising out of or related to the Work to date, excluding retainage or any claims previously submitted as required under the terms of the Contract, and specifically identified and excluded by CONTRACTOR in the release. OWNER shall be entitled to retain from each progress payment five percent (5%) of the amount thereof. Such retainage shall be retained until Final Completion and satisfaction of all conditions for Final Payment. It is understood, however, that in case the whole Work be near to completion, as certified by the ENGINEER, and some unexpected or unusual delay occurs, through no neglect or fault on the part of the CONTRACTOR, the OWNER may, upon written recommendation of the ENGINEER, pay a reasonable and equitable portion of the retained percentage to the CONTRACTOR, or the CONTRACTOR, at the OWNER'S option, may be relieved of the obligation to fully complete the Work, and thereupon, the CONTRACTOR shall receive, at the OWNER'S option, payment of the balance due him under the Contract for Work completed in accordance with the Contract Documents, subject to OWNER's rights to otherwise withhold or retain payments, and subject to the conditions set forth under"6.08 FINAL PAYMENT." The Owner at its option and in compliance with Texas law may reduce retainage to less than the above-stated percentages. 6.07 USE OF COMPLETED PORTIONS & PUNCHLIST. The OWNER shall have the right to take possession of and use any completed or partially completed portions of the Work, notwithstanding that the time for completing the entire work or such portions may not have expired; but such taking possession and use shall not be deemed an acceptance of any work not completed in accordance with the Contract Documents. If such prior use increases the cost of or delays the Work, the CONTRACTOR shall promptly and within three (3) days of OWNER's taking possession, give OWNER written notice of same, and CONTRACTOR may be entitled to such extra compensation or extension of time, or both, as may be determined in accordance with the provisions of this Agreement. 6.08 SUBSTANTIAL COMPLETION. The CONTRACTOR shall notify the OWNER AND ENGINEER, by letter executed by a duly qualified officer of CONTRACTOR, that in CONTRACTOR's opinion, the Work of the Contract, or an agreed portion thereof, is "Substantially Complete". Such notification shall include a list of all outstanding or incomplete items. Upon receipt, and within a reasonable time thereafter, of such notice, the ENGINEER and the CONTRACTOR shall jointly perform a walk-through and inspection of the Work to determine 10-2012 00700-23 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT the status of all or the identified portion of the work, and the ENGINEER shall prepare a detailed list of unfinished, incomplete, defective and/or non-conforming Work ("Punchlist"). If the ENGINEER determines that the Work is Substantially Complete in accordance with the Contract Documents, the ENGINEER shall issue to the OWNER and the CONTRACTOR a Certificate of Substantial Completion. OWNER shall have seven (7) days after receipt of Certificate to make written objection to the ENGINEER as to any provision of the Certificate or the attached list of non-conforming work. If ENGINEER concludes that the Work is not Substantially Complete, ENGINEER will, within fourteen (14) days, notify CONTRACTOR of the reason he believes the Work is not Substantially Complete. Upon Substantial Completion of the Work, ENGINEER will deliver to OWNER and CONTRACTOR a written recommendation as to division of responsibilities, pending final payment and acceptance, with respect to security, maintenance, utilities and damage to the Work, except as otherwise provided in the Certificate of Substantial Completion. NEITHER THE SUBSTANTIAL COMPLETION OF THE WORK, NOR THE OMISSION OF AN ITEM FROM THE PUNCHLIST, SHALL EXCUSE THE CONTRACTOR FROM PERFORMING ALL OF THE WORK UNDERTAKEN, WHETHER OF A MINOR OR MAJOR NATURE, AND THEREBY COMPLETING THE WORK IN ACCORDANCE WITH THE CONTRACT DOCUMENTS. The Certificate of Substantial Completion shall establish the time period within which CONTRACTOR shall complete the Work for Final Acceptance by the Owner and ENGINEER. 6.08-1 OWNER shall have the right to exclude CONTRACTOR from the Work after the date of Substantial Completion, for security requirement reasons. OWNER may establish an access procedure to facilitate CONTRACTOR's uninterrupted access to the Work for the purposes of completing and correcting all items on the Punchlist in an expeditious manner. 6.09 FINAL PAYMENT. Final payment of the Retainage withheld from the Contract Price shall be made by the OWNER to the CONTRACTOR at such time as: (a) the Work, including all Change Orders and including all Punchlist work, has been fully completed in strict accordance with the Contract Documents; (b) the Contract has been fully performed except for the CONTRACTOR's responsibility to correct nonconforming Work during the warranty period set forth in the Contract Documents, and to satisfy other requirements, if any, which necessarily survive final payment; (c) CONTRACTOR delivers to OWNER a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect and will not be cancelled or allowed to expire until at least 30 days prior written notice has been given to OWNER; (d) CONTRACTOR delivers to OWNER a Consent of Surety, if any, to final payment; (e) CONTRACTOR delivers to OWNER a complete set of As-Built Drawings, reflecting all deviations from the Plans, Specifications and approved shop drawings in the Work actually constructed, and delivers all maintenance and operating manuals and/or instructions; 10-2012 00700-24 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT (f) CONTRACTOR delivers to OWNER all building certificates required prior to occupancy and all other required inspections/approvals /acceptances by city, county, state governmental entities or other authorities having jurisdiction; (g) CONTRACTOR delivers to OWNER assignments of all guarantees and warranties from subcontractors, vendors, suppliers or manufacturers, as well as names, addresses and telephone numbers of contacts for each subcontractor, vendor, supplier or manufacturer; (h) CONTRACTOR removes all equipment,tools, temporary facilities, surplus materials and rubbish from the site, and final cleans the site to OWNER's satisfaction; (i) CONTRACTOR delivers to OWNER a Full and Final Release and Affidavit of Bills Paid in the form attached hereto as Attachment No. 2, executed by CONTRACTOR; (j) CONTRACTOR delivers to OWNER all other documentation required to be submitted to OWNER pursuant to the Contract Documents, including but not limited to any special guarantees or warranties, operation and maintenance manuals, etc'. in each case in a form satisfactory to OWNER as determined in OWNER's sole discretion; and (k) the Final Application for Payment has been approved by the ENGINEER and OWNER. Acceptance of Final Payment by the CONTRACTOR shall constitute a waiver of all claims by CONTRACTOR against OWNER other than any claims previously made in writing by CONTRACTOR against OWNER, and still unsettled, and except for claims arising out of third party actions, cross-claims and counterclaims. No interest shall be due or payable by OWNER to CONTRACTOR on any sums retained or withheld by OWNER pursuant to the terms or provisions of the Contract Documents, except as otherwise provided by applicable law. Neither the Certificate of Substantial Completion nor the Final Payment nor possession or acceptance of the Work shall relieve the CONTRACTOR of its obligation for correction of defective or non- conforming Work, or for fulfillment of any warranty, which may be required by law or by the Contract Documents. 6.10 CORRECTION OF WORK BEFORE FINAL PAYMENT. The CONTRACTOR shall promptly remove from OWNER's premises all materials, equipment or Work which is defective or otherwise not in conformance with the Contract Documents, whether actually incorporated in the Work or not, and CONTRACTOR shall, at his own expense, promptly replace such materials, equipment or Work with other materials conforming to the requirements of the Contract. The CONTRACTOR shall also bear the expense of restoring all work of CONTRACTOR or other contractors damaged by any such removal or replacement. If CONTRACTOR does not remove and replace any such unsuitable Work within ten (10) business days after receipt of a written notice from the OWNER or the ENGINEER, the OWNER may remove, replace and remedy such work at CONTRACTOR's expense. 10-2012 00700-25 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 6.11 CORRECTION OF WORK AFTER FINAL PAYMENT. If within one (1) year from the date of Substantial Completion or such longer period of time as may be prescribed by law or by the terms of any applicable special warranty required by the Contract Documents, any of the Work is found to be defective or not in accordance with the Contract Documents, CONTRACTOR shall, at its sole cost, correct it and any other work affected thereby promptly after receipt of a written notice from OWNER to do so. In addition, CONTRACTOR shall be responsible for any damage to building contents, when such damage results from the CONTRACTOR's use of faulty materials or defective workmanship; to the extent such damage is not covered by OWNER's insurance. This warranty period shall renew and recommence for each corrected item of Work upon completion of the remedial work. This time period for correction by CONTRACTOR is in addition to, and not in lieu of, all warranties or remedies, which exist at common law or by statute. These warranty obligations shall survive the termination of this Contract, and shall be enforceable by a decree of specific performance, in addition to such other rights and remedies available to OWNER at law or in equity. 6A2 PAYMENTS WITHHELD. The OWNER may withhold, or on account of subsequently discovered evidence nullify and demand immediate repayment of, the whole or part of any certificate for payment or payment, to such extent as may be necessary to protect OWNER from loss on account of: (a) Defective or non-conforming Work not remedied; (b) Claims filed or reasonable evidence indicating probable filing of claims; (c) Failure of the CONTRACTOR to make payments promptly to subcontractors or for material or labor; (d) Damage to another contractor, OWNER, existing improvements on the site, or to adjacent or adjoining property; (e) Reasonable doubt that the Work can be completed for the unpaid balance of the Contract amount; (0 Reasonable indication that the Work will not be completed within the Contract Time; (g) Failure on the part of the CONTRACTOR to execute any and all documents, releases or other documents presented to the CONTRACTOR for execution, as provided for herein or otherwise; (h) Liquidated or other damages due to late completion; and/or (i) Any breach by CONTRACTOR of this Contract or any other agreement between OWNER and CONTRACTOR. When the above grounds are removed to OWNER's satisfaction, the withheld payment shall be made promptly. If the said causes are not so remedied, OWNER may remedy the same for CONTRACTOR's account, charge the entire cost thereof to CONTRACTOR and deduct such cost 10-2012 00700-26 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT from the Contract Sum or from any payments due or to become due under any other agreement between OWNER and CONTRACTOR. 6.13 DELAYED PAYMENTS. Should the OWNER fail to make payment to the CONTRACTOR when payment is due in accordance with the terms of the Contract Documents, any interest due CONTRACTOR for late payments shall accrue and be paid in accordance with the provisions of Chapter 2251 of the Texas Government Code, as amended, and payment of such interest shall fully liquidate and compensate any injury to the CONTRACTOR growing out of such delay in payment. Should OWNER fail to pay CONTRACTOR an undisputed amount due within the time limits provided in the Contract or applicable law, CONTRACTOR shall give the notice required and comply with the provisions of Section 2251.051 of the Texas Government Code, and shall thereupon be entitled to the rights and remedies provided therein. 7.0 EXTRA WORK AND CLAIMS 7.01 DIFFERING SITE CONDITIONS. During the progress of the work, if subsurface, latent physical conditions or unknown physical conditions of an unusual nature are encountered at the site that differ materially from those indicated in the contract or from those ordinarily encountered and generally recognized as inherent in the work provided for in the contract, the CONTRACTOR shall notify the OWNER's Representative in writing within three (3) calendar days of the specific differing conditions before the site is disturbed and before the affected work is performed. (a)Upon written notification, the ENGINEER will investigate the conditions, and if it is determined that the conditions materially differ and cause an increase or decrease in the cost or time required for the performance of any work under the contract, an adjustment, excluding anticipated profits,will be made and the contract modified in writing accordingly. The ENGINEER will notify the CONTRACTOR in writing of the determination whether or not an adjustment of the contract is warranted. (b)No contract adjustment which results in a benefit to the CONTRACTOR will be allowed unless the CONTRACTOR has provided the required written notice. (c)No contract adjustment will be allowed under this clause for any effects caused on unchanged work. 7.02 SUSPENSIONS OF WORK ORDERED BY THE ENGINEER. If the performance of all or any portion of the work is suspended by the ENGINEER in writing for seven(7) calendar days and the CONTRACTOR believes that additional compensation and/or contract time is due as a result of such suspension, the CONTRACTOR shall submit a written request for adjustment to the ENGINEER within seven(7) calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment. (a) Upon receipt, the ENGINEER will evaluate the CONTRACTOR's request. If the ENGINEER agrees that the cost and/or time required for the performance of the contract has increased as a result of such suspension and the suspension was caused by conditions beyond the control of and not the fault of the CONTRACTOR, its suppliers, or subcontractors at any approved tier, and not caused by weather, the ENGINEER will make 10-2012 00700-27 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT an adjustment(excluding profit)and modify the contract in writing accordingly. The CONTRACTOR will be notified of the ENGINEER's determination, in writing, whether or not an adjustment of the contract is warranted. (b)No contract adjustment will be allowed unless the CONTRACTOR has submitted the request for adjustment within the time prescribed. (c)No contract adjustment will be allowed under this clause to the extent that performance would have been suspended by any other cause, or for which an adjustment is provided or excluded under any other term or condition of this contract. 7.03 CHANGE ORDERS. Without invalidating this Agreement, the OWNER may, at any time or from time to time, order additions, deletions or revisions to the Work; such changes will be authorized by Change Order to be prepared by the ENGINEER for execution by the OWNER and the CONTRACTOR. The Change Order shall set forth the basis for any change in Contract Price, as hereinafter set forth for Extra Work, and any change in Contract Time, which may result from the change. 7.04 In accordance with paragraph 1.07 CONTRACTOR'S request to work weekends, the Owner's Construction Manager shall,upon receipt of written notice by the CONTRACTOR of the need to conduct work on otherwise non-Work Days,prepare a cost estimate for providing Construction Management and Inspection services during the requested period and submit this to both OWNER and CONTRACTOR. If approved by both parties the Construction Manager shall prepare a Deductive Change Order in the amount stated in the estimate for the signature of the CONTRACTOR and the OWNER for inclusion in the next Pay Application. The Deductive Change Order must be signed and executed by both the OWNER and CONTRACTOR prior to start of work on any non-Work Day. 7.05 MINOR CHANGES. The ENGINEER may authorize minor changes in the Work not inconsistent with the overall intent of the Contract Documents and not involving an increase in Contract Price or time. If the CONTRACTOR believes that any minor changes authorized by the ENGINEER involves Extra Work or entitles him to an increase in the Contract Price or the Contract Time, the CONTRACTOR shall give notice of same by written request to the ENGINEER for a written Work Order, with a copy to OWNER. Any such notice and request by the CONTRACTOR shall be given prior to beginning the changed work. CONTRACTOR's commencement of any minor change in the Work prior to such written notice and request shall constitute a waiver of any and all claims for an increase in the Contract Price or the Contract Time arising out of or related to such changed work. 7.06 EXTRA WORK. It is agreed that the CONTRACTOR shall perform all work when presented with a written Change Order, Work Change Directive or Work Order signed by the ENGINEER, subject, however, to the right of the CONTRACTOR to require written confirmation of such Change Order, Work Change Directive or Work Order by the OWNER. It is agreed that the basis of compensation or adjustment to the CONTRACTOR for work either altered, added or deleted by a Change Order or Work Change Directive, or for which a claim for Extra Work is made, shall be determined by one or more of the following methods: Method(A) —By Contract unit prices applicable to the work, if any; or 10-2012 00700-28 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT Method (B) --By agreed unit prices or agreed stipulated lump sum price; or Method(C)--If neither Method (A) nor Method (B) can be agreed upon before the Extra Work is commenced, then the CONTRACTOR shall be paid the "Actual Field Cost" of the work plus: a) For subcontractors performing work mark-up shall be limited to fifteen percent, ten(10%) for the subcontractor plus five (5%) for the General Contractor or b) For the General Contractor alone, self-performing the extra work,without subcontractor, the mark-up shall not exceed ten percent (10%), as full and final compensation for the Extra Work and all costs and expenses, direct or indirect, arising out of or related thereto. In the event said Extra Work or Change Order or Work Change Directive work is performed and paid for under Method(C), then the provisions of this paragraph shall apply and the "Actual Field Cost" is hereby defined as the cost to the CONTRACTOR of all workers, such as foremen, timekeepers, mechanics and laborers, and materials, supplies, trucks, rentals of machinery and equipment, for the time actually employed or used on such Extra Work or Change Order or Work Change Directive work, plus actual transportation charges necessarily incurred together with all power, fuel, lubricants, water and similar operating expenses, plus all necessary incidental expenses incurred directly on account of such Extra Work, including Social Security, Old Age Benefits and other payroll taxes, and a rateable proportion of premiums on Performance and ' Payment Bonds and Maintenance Bonds, Public Liability and Property Damage and Workers' Compensation, and all other insurance as may be required by law or ordinance, or the Contract Documents, plus all payments to subcontractors for such work. The ENGINEER may direct the form in which accounts of the "Actual Field Cost" shall be kept and the records of these accounts shall be made available to the ENGINEER. The ENGINEER or OWNER may also specify in writing, before the work commences, the method of doing the work and the type and kind of machinery and equipment to be used; otherwise these matters shall be determined by the CONTRACTOR. Unless otherwise agreed upon, the prices for the use of machinery and equipment shall be determined by using one hundred percent (100%), unless otherwise specified, of the latest schedule of Equipment Ownership Expense adopted by the Associated General Contractors of America where practicable. The mark-up of the "Actual Field Cost" to be paid to the CONTRACTOR, shall cover and compensate him for his profit, overhead, and all other elements of cost and expense not embraced within the "Actual Field Cost" as herein defined, save that where the CONTRACTOR's field office must be maintained solely on account of such Extra Work, then the cost to maintain and operate the same shall be included in the "Actual Field Cost." No claim for Extra Work of any kind will be allowed unless ordered by the ENGINEER in a written Work Order. In case any orders or instructions, either oral or written, appear to the CONTRACTOR to involve Extra Work for which he should receive compensation or an adjustment in the Contract Time, he shall make written request to the ENGINEER for a written Work Order authorizing such Extra Work within ten (10) days of ENGINEER's orders or instructions, otherwise the orders or instructions will be considered minor changes. The issuance of a Work Order by the ENGINEER shall not constitute or be construed as an agreement or 10-2012 00700-29 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT acknowledgement by the ENGINEER that the work which is the subject of the Work Order is Extra Work outside the scope of the Contract Work, but shall merely constitute a direction to the CONTRACTOR to perform the work, and the CONTRACTOR shall proceed with the work, and shall keep an accurate account of the "Actual Field Cost" thereof, as provided under Method (C). Upon completion of the alleged Extra Work, the CONTRACTOR shall promptly and within ten (10) days submit his claim to the ENGINEER by proper certification and attestation, on forms provided by the ENGINEER. The ENGINEER shall render a written decision on CONTRACTOR's claim within ten (10) days. It is mutually agreed between the parties that the ENGINEER's decision on all claims or questions in relation to the Work, CONTRACTOR's performance of the Work, any changes in the Work or Extra Work, the Contract Price and/or the Contract Time, shall be final and conclusive and binding upon the parties. If the ENGINEER shall fail to respond in writing to CONTRACTOR's claim within thirty (30) days of the date of submission, or if CONTRACTOR shall dispute or object to ENGINEER's decision on any claim, and CONTRACTOR fails to file a Request for Mediation of such claim in accordance with the provisions of Article 9.0,within sixty (60) days after the date of submission to the ENGINEER, or such longer period as the parties may agree to in writing, the CONTRACTOR shall lose and forfeit his right to make such claim for Extra Work at any later date, and all such claims held by the CONTRACTOR shall be deemed waived, forfeited and forever barred. CONTRACTOR shall continue to diligently prosecute the Work notwithstanding any pending claim, dispute, or dispute resolution process between OWNER and CONTRACTOR. 7.07 TIME OF FILING CLAIMS. Except as otherwise provided herein, all questions of dispute or adjustment shall be made within the Pro-Trak system and filed with the ENGINEER within three (3) days after the ENGINEER has given any directions, order or instruction to which the CONTRACTOR desires to take exception. The ENGINEER shall reply within thirty (30) days to such written exceptions, and render his final decision in writing. It is mutually agreed between the parties that the ENGINEER's decision on all claims or questions in relation to the Work, CONTRACTOR's performance of the Work, any changes in the Work or Extra Work, the Contract Price and/or the Contract Time, shall be final and conclusive and binding upon the parties. In case the CONTRACTOR should desire to appeal from the ENGINEER's decision, the CONTRACTOR may request a meeting between representatives of the OWNER and the CONTRACTOR for the purposes of appealing the ENGINEER's decision directly to the OWNER, such meeting to occur within ten (10) days after the date of the CONTRACTOR's request, or such longer period as may be agreed to by the parties in writing. If the CONTRACTOR shall still be aggrieved after a meeting with the OWNER and/or his representative, the CONTRACTOR shall have sixty (60) days after the date of the meeting, or such longer period as the parties may agree to in writing, to file a Request for Mediation of such claim in accordance with the provisions of Article 9.0. In the event the CONTRACTOR shall fail, for any reason, to timely file a Request for Mediation, the OWNER shall be released of any and all liability, and the CONTRACTOR's failure to timely file a Request for Mediation shall constitute a waiver, forfeit and final bar of all such claims held by the CONTRACTOR against the OWNER. CONTRACTOR shall continue to diligently prosecute the Work notwithstanding any pending claim, dispute, or dispute resolution process between OWNER and CONTRACTOR. 8.0 DEFAULT 8.01 DEFAULT BY CONTRACTOR. In case the CONTRACTOR should abandon and fail or refuse to resume Work within five (5) days after written notification from the OWNER 10-2012 00700-30 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT or the ENGINEER, or if the CONTRACTOR fails to comply with the orders of the ENGINEER when such orders are consistent with the Contract Documents, or if the CONTRACTOR otherwise defaults on its obligations under the Contract, OWNER shall have the right, if it so elects and without prejudice to any other rights it may have, after giving five (5) days written notice of default to CONTRACTOR and any surety, to terminate the Contract or any part thereof and/or to take over or cause others to take over the Work or any part thereof, and to complete such Work for the account of CONTRACTOR. Where Performance and Payment Bonds exist, the sureties on these bonds shall be directed to complete the Work in conjunction with the notice of default, and a copy of said notice shall be delivered to the CONTRACTOR. After receiving said notice of default, the CONTRACTOR shall promptly and within no more than three (3) days, remove from the Work any machinery, equipment, or tools then on the job, not intended for incorporation into the Work. Should CONTRACTOR fail to promptly remove such machinery, equipment or tools, OWNER may remove such machinery, equipment or tools and store same at CONTRACTOR's expense; return such machinery, equipment or tools to their purported owner; or otherwise dispose of such machinery, equipment or tools as OWNER sees fit. Any materials, supplies and/or equipment delivered for use in the Work, may be used in the completion of the Work by the OWNER or the surety on the Performance Bond, or another contractor in completion of the Work; it being understood that the use of such equipment, supplies and materials will ultimately reduce the cost to complete the Work and be reflected in the final settlement. Where there is no Performance Bond or in case the surety should fail to commence compliance with the notice for completion hereinabove provided for within ten (10) days after the service of such notice, then the OWNER may provide for completion of the Work in either of the following elective manners: (a) The OWNER may thereupon employ such force of workers and use such machinery, equipment, tools, materials and supplies as the OWNER may deem necessary to expeditiously complete the Work, and charge the expense of such labor, machinery, equipment, tools, materials and supplies to said CONTRACTOR, and expense so charged shall be deducted and paid by the OWNER out of such monies as may be due or that may thereafter at any time become due to the CONTRACTOR under and by virtue of this Agreement or any other agreement between OWNER and CONTRACTOR. In case such expense is less than the sum which would have been payable under this Contract if the same had been completed by the CONTRACTOR, then said CONTRACTOR shall be credited with the difference. In case such expense is greater than the sum which would have been payable under this Contract if the same had been completed by such CONTRACTOR, then the CONTRACTOR and/or his surety shall promptly pay the amount of such excess to the OWNER upon demand; or (b) The OWNER, under sealed bids, under the times and procedures provided for by law, may let the contract for completion of the Work under substantially the same terms and conditions which are provided in this Contract. In case of any increase in cost to the OWNER under the completion contract, as compared to what would have been the cost under this Contract, such increase shall be charged to the CONTRACTOR, and the amount of such increase may be deducted by the OWNER out of such monies as may be due or that may thereafter at any time 10-2012 00700-31 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT become due to the CONTRACTOR under and by virtue of this Agreement or any other agreement between OWNER and CONTRACTOR, or the CONTRACTOR and/or his surety shall promptly pay the amount of such increase to the OWNER upon demand. However, should the cost to complete any such completion contract prove to be less than what would have been the cost to complete under this Contract,the CONTRACTOR and/or his surety shall be credited therewith. In the event of a default by CONTRACTOR, no further payments shall be made to CONTRACTOR under the Contract until the Work is Finally Completed. When the Work shall have been Finally Completed,the CONTRACTOR and his surety shall be so notified. A complete itemized statement of the Contract accounts, certified by the ENGINEER as being correct, shall then be prepared and delivered to the CONTRACTOR and his surety, whereupon the CONTRACTOR and/or his surety shall pay the balance due as reflected by said statement. The OWNER, prior to incurring an obligation to make payment hereunder, shall have such statement of completion attested to by the CONTRACTOR and the surety as accurate, and in exchange for payment of the sum stated therein, the OWNER shall be entitled to a full and final release of any claims or demands by the CONTRACTOR or the surety. In the event the statement of accounts shows that the cost to complete the work is less than that which would have been the cost to the OWNER had the work been completed by the CONTRACTOR under the terms of this Contract, or when the CON TRACTOR and/or his surety shall pay the balance shown to be due by them to the OWNER, then all machinery, equipment, tools or supplies left on the site of the Work shall be turned over to the CONTRACTOR and/or his surety. Should the cost to complete the Work exceed the Contract Price, and the CONTRACTOR and/or his surety fail to pay the amount due the OWNER within the time designated above, and there remains any machinery, equipment, tools, materials or supplies which are the property of CONTRACTOR on the site of the Work, notice thereof, together with an itemized list of such equipment and materials, shall be mailed to the CONTRACTOR and his surety at the respective addresses designated in the Contract, provided, however, that actual written notice given in any manner will satisfy this condition. After mailing or other giving of such notice, such property shall be held at the risk of the CONTRACTOR and his surety, subject only to the duty of the OWNER to exercise ordinary care to protect such property. After fifteen (15) days from the date of such notice, the OWNER may sell such property, equipment, tools, materials or supplies, and apply the net sum derived from such sale to the credit of the CONTRACTOR and his surety. Such sale may be made at either public or private sale, with or without notice, as the OWNER may elect. The OWNER shall release any machinery, equipment, tools, materials or supplies, which remain on the Work, and belong to persons other than the CONTRACTOR or his surety, to their reputed owners. 8.02 SUPPLEMENTATION OF CONTRACTOR FORCES. If CONTRACTOR at any time shall, in OWNER'S sole opinion, fail to furnish skilled workers, suitable materials, supplies or adequate equipment sufficient for the prompt, timely and diligent prosecution of the Work in accordance with OWNER's direction, OWNER shall have the right, without prejudice to the exercise of other remedies for the same default and without fully taking over the Work, to supplement CONTRACTOR's forces and to expedite delivery of and to procure and furnish such workers, materials, tools, supplies or equipment for CONTRACTOR's account by employing other contractors and suppliers engaged in the same class of work and charge the entire cost thereof to CONTRACTOR, said cost to be deducted from sums due or to become due to 10-2012 00700-32 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT CONTRACTOR under the Contract or any other agreement with OWNER or any parent, subsidiary or affiliate of OWNER. 8.03 CUMULATIVE REMEDIES & SPECIFIC PERFORMANCE. All rights and remedies of OWNER, under the terms of the Contract and/or available at law or in equity, are cumulative. In the event CONTRACTOR or any of its subcontractors, vendors or suppliers fails or refuses for any reason to provide timely manufacture, fabrication, delivery, installation, erection, construction or completion of any supplies, materials, expendables, equipment, machinery, accessories or appurtenances to be furnished hereunder, CONTRACTOR acknowledges and agrees that such items are required, necessary, essentially unique to the Project and the Work and will cause irreparable harm to OWNER and the Project if not furnished in accordance with the Contract, and OWNER shall have the right to obtain a decree of specific performance and mandatory injunctive relief from any Court of competent jurisdiction to ensure the timely furnishing of such items. 8.04 CROSS-DEFAULT. If, for any reason, CONTRACTOR is declared in default and/or terminated by OWNER under any other agreement with OWNER, whether related to the Project or not related to the Project, OWNER shall have the right to offset and apply any amounts which might be owed to OWNER by CONTRACTOR under any other such agreements against any earned but unpaid amounts owing to CONTRACTOR by OWNER under the Contract, any retainage earned by CONTRACTOR under the Contract or any unearned, unpaid amount under the Contract. 8.05 INSOLVENCY. It is recognized that if CONTRACTOR becomes a debtor in voluntary or involuntary bankruptcy proceedings, makes a general assignment for the benefit of creditors, or if a receiver is appointed on account of his insolvency, such events could seriously impair or frustrate CONTRACTOR's performance of the Work. Accordingly, it is agreed that should CONTRACTOR become a debtor in bankruptcy, either voluntary or involuntary, CONTRACTOR shall notify OWNER in writing within twenty-four (24) hours of the filing with the bankruptcy court. Further, it is agreed that upon occurrence of any one or more such events, OWNER shall be entitled to request of CONTRACTOR or its successors, trustees or receivers, adequate assurances of future performance. In the event such adequate assurances are not given to the reasonable satisfaction of OWNER within seventy-two (72) hours of such request, OWNER shall have the right to immediately invoke the remedies of this Section 8 or as provided by law. Pending receipt of such adequate assurances of such future performance, OWNER may proceed with the Work on a temporary basis and deduct the costs, plus reasonable overhead and profit, from any amounts due or which may become due to CONTRACTOR under the Contract or any other agreement with OWNER. In this regard, OWNER and CONTRACTOR agree that delays in performance could result in more damages to CONTRACTOR than would be sustained if OWNER failed to exercise such remedies. 8.06 CONTINGENT ASSIGNMENT. CONTRACTOR hereby assigns to OWNER, all of CONTRACTOR's rights under and interest in any and all subcontracts and/or purchase orders entered into by CONTRACTOR pursuant to this Agreement, such assignment to become effective upon CONTRACTOR's default under this Agreement or OWNER's termination of this Contract, and OWNER's acceptance of such assignment. Upon CONTRACTOR's default or OWNER's termination of this Contract, OWNER may, in the event there is no performance bond for the Contract, or in the event the performance bond surety fails to complete the Contract, or if OWNER otherwise so elects in its sole discretion, accept such assignment by written notice of such 10-2012 00700-33 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT acceptance to CONTRACTOR and subcontractor, and may require subcontractors to perform all of the then unperformed duties and obligations under the subcontract, for the direct benefit of OWNER. In the event OWNER requires such performance by a subcontractor, then OWNER shall be obligated to pay such subcontractor any amounts due and owing under the terms of the subcontract/purchase order, at the subcontract prices and rates, and subject to any rights of withholding or offset and other terms and conditions of the subcontract, for all work properly performed by such subcontractor, to the date of OWNER's acceptance and thereafter. OWNER's liability in this connection, however, shall not exceed the amount obtained by subtracting all payments made by CONTRACTOR to subcontractor from the Subcontract Price at the time of CONTRACTOR's default or OWNER's termination of CONTRACTOR. CONTRACTOR shall include a provision in its subcontracts that allows such assignment and allows OWNER to take these actions, and further provides that in the event of CONTRACTOR's termination for default, the subcontractor agrees to give the OWNER or its agent the right to inspect all books and records of subcontractor relating to the Work. 8.07 WAIVER OF CONSEQUENTIAL DAMAGES. CONTRACTOR expressly waives any and all claims for consequential damages against OWNER arising out of or related to this Contract, or any other agreements between CONTRACTOR and OWNER, including, but not limited to, claims for damages incurred by CONTRACTOR for principal office expenses, including the compensation of personnel stationed there, losses of financing, bonding capacity, business and reputation, and claims for lost profit, whether on this Contract or otherwise. 8.08 TERMINATION FOR CONVENIENCE. OWNER may at its sole discretion, upon five (5) days written notice to CONTRACTOR, terminate this Contract, in whole or in part, if and when OWNER determines that it is in the best interest of OWNER to do so. Upon receipt of such written notice from OWNER, CONTRACTOR shall cease all terminated Work and take reasonable precautions to protect and preserve such work, and shall take all reasonable measures after consultation with OWNER to terminate or assign to OWNER all subcontracts, purchase orders or other commitments related to the Work or the Project on terms and conditions acceptable to OWNER. CONTRACTOR will be paid for all Work performed in strict accordance with the Contract Documents, based upon the Contract Price and the percentage of completion on the date of termination, and less amounts previously paid, subject to any reasonable backcharges attributable to CONTRACTOR's failure to comply with any of the provisions of this Contract and further subject to the other terms of this Contract regarding payment. In no event will CONTRACTOR receive or be entitled to any payment or compensation whatsoever for interruption of business or loss of business opportunities, any other items of consequential damages, for overhead or loss of profits on the unperformed Work and/or services and unfurnished materials or for any intangible, impact or similarly described cost, damages or expense, and under no circumstances shall the total sum paid to or received by CONTRACTOR under this Contract exceed the Contract Price. The compensation provided herein shall be CONTRACTOR's sole and exclusive remedy arising out of a termination for convenience. 8.09 DEFAULT BY OWNER. In case the OWNER shall default on its material obligations under this Contract, other than OWNER's failure to pay CONTRACTOR a disputed amount due within the time limits provided in the Contract or applicable law, as addressed by Section 6.13 of this Agreement, and shall fail or refuse to cure, or to commence and diligently pursue cure of such default within fifteen (15) days after written notification by the CONTRACTOR, then the CONTRACTOR may suspend or wholly abandon the Work, and may remove therefrom all machinery, tools and equipment, and all materials on the site of the Work 10-2012 00700-34 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT that have not been included in payments to the CONTRACTOR and have not been incorporated into the Work. And thereupon, the ENGINEER shall make an estimate of the total amount earned by the CONTRACTOR, which estimate shall include the value of all Work actually completed by said CONTRACTOR (at the Contract Prices), the value of all partially completed Work at a fair and equitable price, and the amount of all Extra Work performed at the prices agreed upon, or provided for by the terms of this Contract, and a reasonable sum to cover the cost of any provisions made by the CONTRACTOR to carry the whole Work to completion and which cannot be utilized. The ENGINEER shall then make a final statement of the balance due the CONTRACTOR by deducting from the above estimate all previous payments by the OWNER and all other sums that may be retained by the OWNER under the terms of this Agreement, and shall present the same to the OWNER, and OWNER's payment of said sum to the CONTRACTOR, on or before thirty (30) days after OWNER's receipt of such statement, shall satisfy any and all rights, claims or causes of action of CONTRACTOR arising out of or related to such default by OWNER, and shall be CONTRACTOR's sole and exclusive remedy for such default. A disputed or unilateral claim by the Contractor cannot by itself constitute a default hereunder. 9.0 DISPUTE RESOLUTION Any dispute or pending claim or dispute resolution process between OWNER and CONTRACTOR shall not excuse or relieve CONTRACTOR of its obligations under the Contract, and CONTRACTOR shall diligently prosecute the Work notwithstanding any pending claim, dispute, or dispute resolution process between OWNER and CONTRACTOR. All claims, disputes and other matters in question arising out of or relating to, the Contract, or the breach thereof, shall be subject to mediation as a condition precedent to any other dispute resolution process as may be selected by OWNER. Unless mutually agreed otherwise the mediation shall be conducted by a third party who will be selected by agreement between OWNER and CONTRACTOR, and Request for Mediation shall be filed with the other party. The parties shall share the mediator's fee and any filing fees equally. If a claim, dispute or other matter in question between OWNER and CONTRACTOR involves the work of a subcontractor or supplier, OWNER or CONTRACTOR may join such subcontractor or supplier as a party to any mediation proceeding between OWNER and CON TRACTOR hereunder. CONTRACTOR shall include in all subcontracts and/or purchase orders related to the Work a specific provision whereby the subcontractor or supplier consents to being joined in mediation between OWNER and CONTRACTOR involving the work of such subcontractor or supplier. This Contract shall be governed by the laws of the State of Texas and shall be considered performable in Brazoria County, Texas, for venue purposes. Further, the OWNER and CON"TRACTOR stipulate that venue for any dispute resolution proceeding involving or touching upon the Contract other than the conduct of an arbitration hearing shall be in Brazoria County, Texas, or, if such choice of venue is prohibited or unenforceable by law, shall be held in the county where the Project is located. CONTRACTOR agrees to pay OWNER all reasonable attorneys' fees incurred by OWNER in the event OWNER seeks to enforce any provision of this Contract whether by arbitration or other dispute resolution process. Further, in the event OWNER defends any claim instituted by CONTRACTOR against OWNER, whether in arbitration or other dispute resolution 10-2012 00700-35 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT process, CONTRACTOR agrees to pay OWNER all reasonable attorneys' fees incurred by OWNER in defending such claim provided OWNER is the prevailing party, in whole or in part, in such proceeding. 10-2012 00700-36 of 36 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT ATTACHMENT NO. 1 TO GENERAL CONDITIONS WORKERS' COMPENSATION INSURANCE COVERAGE A. DEFINITIONS: Certificate of coverage ("certificate") _ A copy of a certificate of insurance, a certificate of authority to self-insure issued by the commission, or a coverage agreement (TWCC81, TWCC-82, TWCC-83 or TWCC-84), showing statutory workers' compensation insurance coverage for the person's or entity's employees providing services on a project for the duration of the Project. Duration of the Project .includes the time from the beginning of the Work on the Project until the contractor's/person's work on the Project has been completed and the Project warranty period has expired. Persons providing services on the project includes persons or entities performing all or part of the services the contractor has undertaken to perform on the project, regardless of whether that person contracted directly with due contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, subcontractors, motor carriers and owner- operators, (as defined at Section 406.121 of the Texas Labor Code), leasing companies, and employees of any such entity, or employees of any entity which furnishes persons to provide services on the project. "Services" include, without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a project. "Services" does not include activities unrelated to the project, such as food/beverage vendors, office supply deliveries, and delivery of portable toilets. B. The CONTRACTOR shall provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Title 5 Workers' Compensation, Subtitle A Texas Workers' Compensation Act, for employees of the contractor providing services on the project, for the duration of the project. C. The CONTRACTOR must provide a certificate of coverage to the OWNER prior to being awarded the Contract. D. If the coverage period shown on the CONTRACTOR's current certificate of coverage ends during the duration of the project, the CONTRACTOR must, prior to the end of the coverage period, file a new certificate of coverage with the OWNER showing that coverage has been extended. E. The CONTRACTOR shall obtain from each subcontractor or other person providing services on a project, and provide to the OWNER: (I) a certificate of coverage, prior to that person beginning work on the Project, so the OWNER will have on file certificates of coverage showing coverage for all persons providing services on the Project; and 05/2007 00700-AI CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT (2) no later than seven days after receipt by the CONTRACTOR and prior to the end of the coverage period, a new certificate of coverage showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the Project. F. The CONTRACTOR shall retain all required certificates of coverage for the duration of the Project and for one year thereafter. G. The CONTRACTOR shall notify the OWNER in writing by certified mail or personal delivery, within 10 days after the CONTRACTOR knew or should have known, of any changes that materially affect the provision of coverage of any person providing services on the Project. H. The CONTRACTOR shall post on each Project site a notice, in the text, form and manner prescribed by the Texas Workers' Compensation Commission, informing all persons providing services on the Project that they are required to be covered, and stating how a person may verify coverage and report lack of coverage. NOTICE REQUIRED WORKERS' COMPENSATION COVERAGE "The law requires that each person working on this site or providing services related to this construction project must be covered by workers' compensation insurance. This includes persons providing, hauling, or delivering equipment or materials, or providing labor or transportation or other service related to the project, regardless of the identity of their employer or status as an employee." "Call the Texas Workers' Compensation Commission at (512) 440- 3789 to receive information on the legal requirements for coverage, to verify whether your employer has provided the required coverage, or to report an employer's failure to provide coverage." The CONTRACTOR shall contractually require each person with whom it contracts to provide services on a project, too: (1) provide coverage, based on proper reporting of classification codes and payroll amounts and filing of any coverage agreements, which meets the statutory requirements of Texas Labor Code, Title 5 Workers' Compensation, Subtitle A Texas Workers' Compensation Act, for all of its employees providing services on the Project, for the duration of the Project; (2) provide to the CONTRACTOR, prior to that person beginning work on the Project, a certificate of coverage showing that coverage is being provided for all employees of the person providing services on the project, for the duration of the Project: 05/2007 00700-A2 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT (3) provide the CONTRACTOR, prior to the end of the coverage period, a new certificate of coverage, showing extension of coverage, if the coverage period shown on the current certificate of coverage ends during the duration of the Project; (4) obtain from each other person with whom it contracts, and provide to the CONTRACTOR: (a) a certificate of coverage,prior to the other person beginning work on the Project; and (b) a new certificate of coverage showing extension of coverage,prior to the end of the coverage period, if the coverage period shown on the current certificate of coverage ends during the duration of the Project; (5) retain all required certificates of coverage on file for the duration of the Project and for one year thereafter; (6) notify the OWNER in writing by certified mail or personal delivery,within 10 days after the person knew or should have known, of any change that materially affects the provision of coverage of any person providing services on the Project; and (7) contractually require each person with whom it contracts, to perform as required by paragraphs (1) - (7),with the certificates of coverage to be provided to the person for whom they are providing services. J. By signing this Contract or providing or causing to be provided a certificate of coverage, the CONTRACTOR is representing to the OWNER that all employees of the CONTRACTOR who will provide services on the Project will be covered by workers' compensation coverage for the duration of the Project, that the coverage agreements will be based on proper reporting of classification codes and payroll amounts, and that all coverage agreements will be filed with the appropriate insurance carrier or, in the case of a self-insured, with the commission's Division of Self-Insurance Regulation. Providing false or misleading information may subject the CONTRACTOR to administrative penalties, criminal penalties, civil penalties, or other civil actions. K. The CONTRACTOR's failure to comply with any of these provisions is a breach of contract by the CONTRACTOR, which entitles the OWNER to pursue all rights and remedies available to it under the Contract, at law or in equity, if the CONTRACTOR does not remedy the breach within ten days after receipt of notice of breach from the OWNER. 05/2007 00700-A3 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT ATTACHMENT NO. 2 TO GENERAL CONDITIONS AGREEMENT FOR FINAL PAYMENT AND CONTRACTOR'S SWORN RELEASE In consideration of the Final Payment under that certain contract between (hereafter "CONTRACTOR")and the City of Pearland (hereafter"OWNER") for the Project known as 2018 Joint and Crack Sealing Project (the "Contract"), the CONTRACTOR makes the following representations to OWNER, either individually if a proprietorship, or jointly and severally by all general partners if a partnership, or if a corporation, by action of the president and secretary of said corporation, as duly authorized by appropriate action of the stockholders and/or board of directors of said corporation, their signatures hereon constituting a representation under oath by said individuals that they have the authority to execute this Agreement for and on behalf of the said corporation: 1. The undersigned CONTRACTOR represents to OWNER that the Application for Payment for the Final Payment under the Contract, and the final Change Order issued under the Contract if any, whether or not modified, corrected or changed in some way by the ENGINEER, the CONTRACTOR or the OWNER, a copy of which are attached hereto and marked Exhibit "A", are true, correct and accurate, and that CONTRACTOR has received payment in full for all other Applications for Payment submitted under the Contract, and that CONTRACTOR has been fully compensated for all labor, materials, equipment and/or services furnished in connection with the Contract, except for the Final Payment. 2. It is agreed and stipulated by the undersigned CONTRACTOR that upon the receipt of Final Payment in the amount as set out on the attached Application for Payment, the CONTRACTOR, by execution of this instrument of release, does, therefore, RELEASE and FOREVER DISCHARGE OWNER of and from all manner of debts, claims, demands, obligations, suits, liabilities and causes of action of any nature whatsoever, at law or in equity, in contract or in tort, now existing or which may hereafter accrue, arising out of or related to the Contract, any Change Orders or Work Orders, the Work, or any labor, materials, equipment or services furnished by CONTRACTOR to OWNER. 3. The CONTRACTOR, acting by and through the person or persons whose names are subscribed hereto, does solemnly swear and affirm that all bills and claims have been paid to all materialmen, suppliers, laborers, subcontractors, or other entities performing services or supplying materials or equipment, and that OWNER shall not be subject to any bills, claims, demands, litigation or suits in connection therewith. 4. It is further specifically understood and agreed that this Agreement for Final Payment and Contractor's Sworn Release shall constitute a part of the Contract, and it is also specifically understood and agreed that this Agreement shall not act as a modification,waiver or renunciation by OWNER of any of its rights or remedies as set out in the Contract itself, but this Agreement for Final Payment and Contractor's Sworn Release shall constitute a supplement thereto for the additional 05/2007 00700-B1 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT protection of OWNER. SIGNED and EXECUTED this, the_day of , 20_ CONTRACTOR: By: Signature Print Name: Title: [If CONTRACTOR is a proprietorship, owner must sign; if a partnership, each general partner must sign; if a corporation, the following language should be used.] SIGNED and EXECUTED this, the day of 20_by , a Texas corporation, under authority granted to the undersigned by said corporation as contained in the Charter,By-Laws or Minutes of a meeting of said corporation regularly called and held. CONTRACTOR: By: President ATTEST: Corporate Secretary (Corporate Seal) [This form is for use by either a proprietorship or a partnership. In the event CONTRACTOR is a partnership or a joint proprietorship, additional signature lines should be added for each individual.] 05/2007 00700-B2 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT AFFIDAVIT STATE OF TEXAS § COUNTY OF § BEFORE ME, the undersigned authority, on this day personally appeared the person or persons whose name(s) are subscribed to the above and foregoing Agreement for Final Payment and Contractor's Sworn Release, who each, after being by me duly sworn, on their oaths deposed and said: I (We) am (are) the person(s) who signed and executed the above and foregoing Agreement for Final Payment and Contractor's Sworn Release, and I (we)have read the facts and statements as therein set out and the representations as made therein, and I (we) state that the above and foregoing are true and correct. CONTRACTOR- Affiant SWORN TO AND SUBSCRIBED TO before me, the day of 20 . Notary Public, State of Texas My Commission Expires: [This form is for use in the event CONTRACTOR is a corporation.] 07/2006 00700-B3 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT AFFIDAVIT STATE OF TEXAS § COUNTY OF § BEFORE ME, the undersigned authority, on this day personally appeared the persons who signed and executed the above and foregoing Agreement for Final Payment mid Contractor's Sworn Release, whose names are set out above,who each, after being by me duly sworn, on their oaths deposed and said: We each are the persons whose names are subscribed above, and hold respectively the offices in the corporation as set out above, and each state under oath that we have the authority to execute this Agreement for Final Payment and Contractor's Sworn Release for and on behalf of said corporation, pursuant to authority granted to us in the Charter of said corporation, the By-Laws of said corporation and/or the Minutes of said corporation; and the facts, statements and representations as set out in the instrument to which this Affidavit is attached, are true and correct. SWORN TO AND SUBSCRIBED TO before me this, the day of 20 Notary Public, State of Texas My Commission Expires: 07/2006 00700-B4 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT ATTACHMENT NO. 3 TO GENERAL CONDITIONS OWNER'S INSURANCE REQUIREMENTS OF CONTRACTOR 1. Definitions. For purposes of this Agreement: 1.1 Owner Parties. "Owner Parties" means (a) the City of Pearland, its successors and assigns, and the Engineer, (b) any officers, employees, or agents of such persons or entities, and(c) others as required by the Contract Documents, if any. 1.2 Contractor. "Contractor" shall mean the vendor providing the service or work to be performed under this Agreement. 1.3 Subcontractor. "Subcontractor" shall include subcontractors of any tier. 1.4 ISO. "ISO"means Insurance Services Office. 2. Contractor Insurance Representations to Owner Parties 2.1 It is expressly understood and agreed that the insurance coverages required herein: 2.1.1 represent Owner Parties' minimum requirements and are not to be construed to void or limit the Contractor's indemnity obligations as contained in this Agreement nor represent in any manner a determination of the insurance coverages the Contractor should or should not maintain for its own protection; and 2.1.2 are being, or have been, obtained by the Contractor in support of the Contractor's liability and indemnity obligations under this Agreement. Neither the requirements as to insurance to be carried as provided for herein, the insolvency, bankruptcy or failure of any insurance company carrying insurance of the Contractor, nor the failure of any insurance company to pay claims accruing, shall be held to affect, negate or waive any of the provisions of this Agreement. 2.2 Failure to obtain and maintain the required insurance shall constitute a material breach of, and default under, this Agreement. If the Contractor shall fail to remedy such breach within five (5) business days after notice by the Owner, the Contractor will be liable for any and all costs, liabilities, damages and penalties resulting to the Owner Parties from such breach, unless a written waiver of the specific insurance requirement(s) is provided to the Contractor by the Owner. In the event of any failure by the Contractor to comply with the provisions of this Agreement, the Owner may, without in any way compromising or waiving any right or remedy at law or in equity, on notice to the Contractor, purchase such insurance, at the Contractor's expense, provided that the Owner shall have no obligation to do so and if the Owner shall do so, the Contractor shall not be relieved of or excused from the obligation to obtain and maintain such insurance amounts and coverages. 10-2012 00700-Cl CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 3. Conditions Affecting All Insurance Required Herein 3.1 Cost of Insurance. All insurance coverage shall be provided at the Contractor's sole expense. 3.2 Status and Rating of Insurance Company. All insurance coverage shall be written through insurance companies authorized to do business in the state in which the work is to be performed and rated no less than A-: VII in the most current edition of A. M. Best's Key Rating Guide. 3.3 Restrictive, Limiting, or Exclusionary Endorsements. All insurance coverage shall be provided to the Owner Parties in compliance with the requirements herein and shall contain no endorsements that restrict, limit, or exclude coverage required herein in any manner without the prior express written approval of the Owner. 3.4 Limits of Liability. The limits of liability may be provided by a single policy of insurance or by a combination of primary and umbrella policies, but in no event shall the total limits of liability available for any one occurrence or accident be less than the amount required herein. 3.5 Notice of Cancellation, Nonrenewal, or Material Reduction in Coverage. All insurance coverage shall contain the following express provision: In the event of cancellation, non-renewal, or material reduction in coverage affecting the certificate holder, thirty (30) days prior written notice shall be given to the certificate holder by certified mail or registered mail,return receipt requested. 3.6 Waiver of Subrogation. The Contractor hereby agrees to waive its rights of recovery from the Owner Parties with regard to all causes of property and/or liability loss and shall cause a waiver of subrogation endorsement to be provided in favor of the Owner Parties on all insurance coverage carried by the Contractor, whether required herein or not. 3.7 Deductible/Retention. Except as otherwise specified herein, no insurance required herein shall contain a deductible or self-insured retention in excess of $25,000 without prior written approval of the Owner. All deductibles and/or retentions shall be paid by, assumed by, for the account of, and at the Contractor's sole risk. The Contractor shall not be reimbursed for same. 4. Maintenance of Insurance. The following insurance shall be maintained in effect with limits not less than those set forth below at all times during the term of this Agreement and thereafter as required: 10-2012 00700-C2 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.1 Commercial General Liability Insurance 4.1.1 Coverage. Such insurance shall cover liability arising out of all locations and operations of the Contractor, including but not limited to liability assumed under this contract (including the tort liability of another assumed in a business contract). Defense shall be provided as an additional benefit and not included within the limit of liability. 4.1.2 Form. Commercial General Liability Occurrence form (at least as broad as an unmodified ISO CG 0001 0798 or its equivalent). 4.1.3 Amount of Insurance. Coverage shall be provided with limits of not less than: Each Occurrence Limit $1,000,000 General Aggregate Limit $2,000,000 Product-Completed Operations Aggregate Limit $2,000,000 Personal and Advertising Injury Limit $1,000,000 4.1.4 Required Endorsements a. Additional Insured. Additional insured status shall be provided in favor of the Owner Parties on any of the following: i. ISO form CG 20 10 11 85; or ii. ISO form CG 20 26 11 85; or iii. a combination of ISO forms CG 20 33 10 01 and CG 20 37 10 01; or iv. any form providing equivalent protection to Owner. b. Designated Construction Project(s) Aggregate Limit. The aggregate limit shall apply separately to this Agreement through use of an ISO CG 25 03 03 97 endorsement or its equivalent. c. Notice of Cancellation, Nonrenewal or Material Reduction in Coverage, as required in 3.5, above. d. Personal Injury Liability. The personal injury contractual liability exclusion shall be deleted. e. Primary and Non-Contributing Liability. It is the intent of the parties to this Agreement that all insurance required herein shall be primary to all insurance available to the Owner Parties. The obligations of the Contractor's insurance shall not be affected by any other insurance available to the Owner Parties and shall seek no contribution from the Owner Parties' insurance, whether primary, excess contingent, or on any other basis. The Contractor's insurance coverage shall be endorsed to provide such primary and non- contributing liability. f. Waiver of Subrogation, as required in 3.6, above. 10-2012 00700-C3 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.1.5 Continuing Commercial General Liability Insurance. The Contractor shall maintain such insurance in identical coverage, form and amount, including required endorsements, for at least one (1) year following Date of Substantial Completion of the Work to be performed under this Agreement. The Contractor shall provide written representation to Owner stating Work completion date. 4.2 Auto Liability Insurance 4.2.1 Coverage. Such insurance shall cover liability arising out of any auto (including owned, hired, and non-owned). 4.2.2 Form. Business Auto form (at least as broad as an unmodified ISO CA 0001 or its equivalent). 4.2.3 Amount of Insurance. Coverage shall be provided with a limit of not less than $1,000,000. 4.2.4 Required Endorsements a. Notice of Cancellation, Nonrenewal or Material Reduction in Coverage, as required in 3.5, above. b. Waiver of Subrogation, as required in 3.6, above. 4.3 Employer's Liability Insurance 4.3.1 Coverage. Employer's Liability Insurance shall be provided as follows: 4.3.2 Amount of Insurance. Coverage shall be provided with a limit of not less than: Employer's Liability: $1,000,000 each accident and each disease. 4.3.3 Required Endorsements a. Notice of Cancellation, Nonrenewal or Material Reduction in Coverage, as required in 3.5, above. b. Waiver of Subrogation, as required in 3.6, above. 4.4 Umbrella Liability Insurance 4.4.1 Coverage. Such insurance shall be excess over and be no less broad than all coverages described above and shall include a drop-down provision for exhaustion of underlying limits. 4.4.2 Form. This policy shall have the same inception and expiration dates as the commercial general liability insurance required above. 10-2012 00700-C4 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.4.3 Amount of Insurance. Coverage shall be provided with a limit of not less than $5,000,000. 4.4.4 Continuing Umbrella Liability Insurance. The Contractor shall maintain such insurance in identical coverage, form and amount, including required endorsements, for at least one (1) year following Date of Substantial Completion of the Work to be performed under this Agreement. The Contractor shall provide written representation to the Owner stating Work completion date. 4.5 Professional Liability Insurance 4.5.1 Coverage. The Contractor shall provide professional liability insurance for any professional design or engineering drawing required by the work. Such insurance shall indemnify the Owner from claims arising from the negligent performance of professional services of any type, including but not limited to design or design/build services as part of the Work to be performed. 4.5.2 Form. This insurance shall include prior acts coverage sufficient to cover all services rendered by the Contractor and by its consultants under this Agreement. It is recognized that this coverage may be provided on a Claims-Made basis. 4.5.3 Amount of Insurance. Coverage shall be provided with a limit of not less than$1,000,000. 4.5.4 Continuing Professional Liability Insurance. The Contractor shall maintain such insurance in identical coverage, form and amount for at least one (1) year following Date of Substantial Completion of the Work to be performed under this Agreement. The Contractor shall provide written representation to the Owner stating Work completion date. 4.6 Builder's Risk 4.6.1 Insureds. Insureds shall include: a. Owner, General Contactor and all Loss Payees and Mortgagees as Named Insureds; and b. subcontractors of all tiers in the Work as Additional Insureds. 10-2012 00700-C5 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.6.2 Covered Property. Such insurance shall cover: a. all structure(s) under construction, including retaining walls, paved surfaces and roadways, bridges, glass, foundation(s), footings, underground pipes and wiring, excavations, grading, backfilling or filling; b. all temporary structures (e.g., fencing, scaffolding, cribbing, false work, forms, site lighting, temporary utilities and buildings) located at the site; c. all property including materials and supplies on site for installation; d. all property including materials and supplies at other locations but intended for use at the site; e. all property including materials and supplies in transit to the site for installation by all means of transportation other than ocean transit; and f. other Work at the site identified in the Agreement to which this Exhibit is attached. Form a. Coverage shall be at least as broad as an unmodified ISO Special form, shall be provided on a completed-value basis, and shall be primary to any other coverage insurance available to the insured parties, with that other insurance being excess, secondary and non- contributing. b. No protective safeguard warranty shall be permitted. c. Required coverage shall further include: i. Additional expenses due to delay in $ TBD completion of project(where applicable) ii. Agreed value Included without sublimit iii. Damage arising from error, omission or Included without sublimit deficiency in construction methods, design, specifications, workmanship or materials, including collapse iv. Debris removal additional limit 25% of direct damage loss v. Earthquake (where applicable) $ TBD vi. Earthquake sprinkler leakage (where $ TBD applicable) vii. Expediting expenses $ TBD viii. Flood (where applicable) $ TBD ix. Freezing Included without sublimit x. Mechanical breakdown, including hot& Included without sublimi cold testing (where applicable) xi. Notice of cancellation,non-renewal or Included 10-2012 00700-C6 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT material reduction—60 days prior written notice to each insured xii. Occupancy clause, as required in F, Included below xiii. Ordinance or law Included without sublimit xiv. Pollutant clean-up and removal $ TBD xv. Preservation of property Included without sublimit xvi. Replacement cost Included xvii. Theft Included without sublimit xviii. Waiver of subrogation as required in G, Included below. 4.6.3 Amount of Insurance. Coverage shall be provided in an amount equal at all times to the full replacement value and cost of debris removal for any single occurrence. 4.6.4 Deductibles. Deductibles shall not exceed the following: a. All Risks of Direct Damage, Per $5,000 Occurrence, except b. Delayed Opening Waiting Period 5 Days c. Flood, Per Occurrence $25,000 or excess of NFIP if in Flood Zone A, B or V d. Earthquake and Earthquake Sprinkler $25,000 Leakage, Per Occurrence 4.6.5 Termination of Coverage. The termination of coverage provision shall be endorsed to permit occupancy of the covered property being constructed so long as such occupancy does not exceed 20% of the usable area of the property. This insurance shall be maintained in effect, unless otherwise provided for in the Contract Documents, until the earliest of the following dates: a. the date on which all persons and organizations who are insureds under the policy agree that it shall be terminated; b. the date on which final payment, as provided for in the Agreement to which this Exhibit is attached, has been made; or c. the date on which the insurable interests in the Covered Property of all insureds other than Contractor have ceased. 10-2012 00700-C7 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 4.6.6 Waiver of Subrogation. The waiver of subrogation provision shall be endorsed as follows: a. A waiver of subrogation shall be provided in favor of all insureds. b. The waiver of subrogation provisions shall be endorsed as follows: Should a covered loss be subrogated, either in whole or in part, your rights to any recovery will come first, and we will be entitled to a recovery only after you have been fully compensated for the loss. 5. Intentionally left blank. 6. Evidence of Insurance 6.1 Provision of Evidence. Evidence of the insurance coverage required to be maintained by the Contractor, represented by certificates of insurance, evidence of insurance, and endorsements issued by the insurance company or its legal agent, and must be furnished to the Owner prior to commencement of Work and not later than fifteen (15) days after receipt of this Agreement. New certificates of insurance, evidence of insurance, and endorsements shall be provided to the Owner prior to the termination date of the current certificates of insurance, evidence of insurance, and endorsements. 6.2 Form 6.2.1 All property insurance required herein shall be evidenced by ACORD form 28, "Evidence of Property Insurance". 6.2.2 All liability insurance required herein shall be evidenced by ACORD form 25, "Certificate of Insurance". 6.3 Specifications. Such certificates of insurance, evidence of insurance, and endorsements shall specify: 6.3.1 The Owner as a certificate holder with correct mailing address. 6.3.2 Insured's name, which must match that on this Agreement. 6.3.3 Insurance companies affording each coverage, policy number of each coverage, policy dates of each coverage, all coverages and limits described herein, and signature of authorized representative of insurance company. 6.3.4 Producer of the certificate with correct address and phone number listed. 6.3.5 Additional insured status required herein. 6.3.6 Amount of any deductibles and/or retentions. 6.3.7 Cancellation, non-renewal and material reduction in coverage notification as required by this Agreement. Additionally, the words "endeavor to" and "but failure to mail such notice shall impose no obligation or liability of any kind upon Company, it agents or representatives" shall be deleted from the cancellation provision of the ACORD 25 certificate of insurance form. 10-2012 00700-C8 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT 6.3.8 Designated Construction Project Aggregate Limits required herein. 6.3.9 Personal Injury contractual liability required herein. 6.3.10 Primary and non-contributing status required herein. 6.3.11 Waivers of subrogation required herein. 6.4 Required Endorsements. A copy of each of the required endorsements shall also be provided. 6.5 Failure to Obtain. Failure of any Owner Party to demand such certificate or other evidence of full compliance with these insurance requirements or failure of any Owner Party to identify a deficiency from evidence that is provided shall not be construed as a waiver of the Contractor's obligation to maintain such insurance. 6.6 Certified Copies. Upon request of any Owner Party, the Contractor shall provide to the Owner a certified copy of all insurance policies required herein within ten (10) days of any such request. Renewal policies, if necessary, shall be delivered to the Owner prior to the expiration of the previous policy. 6.7 Commencement of Work. Commencement of Work without provision of the required certificate of insurance, evidence of insurance and/or required endorsements, or without compliance with any other provision of this Agreement, shall not constitute a waiver by any Owner Party of any rights. The Owner shall have the right, but not the obligation, of prohibiting the Contractor or any subcontractor from performing any Work until such certificate of insurance, evidence of insurance and/or required endorsements are received and approved by the Owner. 7. Insurance Requirements of Contractor's Subcontractors 7.1 Insurance similar to that required of the Contractor shall be provided by all subcontractors (or provided by the Contractor on behalf of subcontractors) to cover operations performed under any subcontract agreement. The Contractor shall be held responsible for any modification in these insurance requirements as they apply to subcontractors. The Contractor shall maintain certificates of insurance from all subcontractors containing provisions similar to those listed herein (modified to recognize that the certificate is from subcontractor) enumerating, among other things, the waivers of subrogation, additional insured status, and primary liability as required herein, and make them available to the Owner upon request. 7.2 The Contractor is fully responsible for loss and damage to its property on the site, including tools and equipment, and shall take necessary precautions to prevent damage to or vandalism, theft, burglary, pilferage and unexplained disappearance of property. Any insurance covering the Contractor's or its subcontractor's property shall be the Contractor's and its subcontractor's sole and complete means or recovery for any such loss. To the extent any loss is not covered by said insurance or subject to any deductible or co-insurance, the Contractor shall not be reimbursed for same. Should the Contractor or its subcontractors choose to self insure this risk, it is expressly agreed that the Contractor hereby waives, and shall cause its 10-2012 00700-C9 CITY OF PEARLAND GENERAL CONDITIONS OF AGREEMENT subcontractors to waive, any claim for damage or loss to said property in favor of the Owner Parties. 8. Use of the Owner's Equipment. The Contractor, its agents, employees, subcontractors or suppliers shall use the Owner's equipment only with express written permission of the Owner's designated representative and in accordance with the Owner's terms and condition for such use. If the Contractor or any of its agents, employees, subcontractors or suppliers utilize any of the Owner's equipment for any purpose, including machinery, tools, scaffolding, hoists, lifts or similar items owned, leased or under the control of the Owner, the Contractor shall defend, indemnify and be liable to the Owner Parties for any and all loss or damage which may arise from such use. 9. Release and Waiver. The Contractor hereby releases, and shall cause its subcontractors to release, the Owner Parties from any and all claims or causes of action whatsoever which the Contractor and/or its subcontractors might otherwise now or hereafter possess resulting in or from or in any way connected with any loss covered by insurance, whether required herein or not, or which should have been covered by insurance required herein, including the deductible and/or uninsured portion thereof, maintained and/or required to be maintained by the Contractor and/or its subcontractors pursuant to this Agreement. 10-2012 00700-CIO CITY OF PEARLAND SPECIAL CONDITIONS OF AGREEMENT Section 00800 SPECIAL CONDITIONS OF AGREEMENT The following Special Conditions modify the General Conditions, Document 00700. Where a portion of the General Conditions is modified or deleted by these Special Conditions,the unaltered portions of the General Conditions shall remain in effect. ARTICLE 1 DEFINITIONS AND INTERPRETATIONS 1.01 Add the following paragraph to the end of Article 1.01: The OWNER'S representative on the project site is: telephone: 281. 652. The CONSTRUCTION MANAGER is: telephone: The CONSTRUCTION INSPECTOR is: telephone: ARTICLE 4 RIGHTS AND RESPONSIBILITIES OF THE CONTRACTOR 4.05 Add the following paragraph to Article 4.05: A Maintenance Bond in accordance with Document 00612 of the Project Manual is required for this Project. The cost of this bond shall be included in the CONTRACTOR'S Bid Proposal. Attachment No. 3 To General Conditions, Owner's Insurance Requirements of Contractor, Article 4.6 Builder's Risk—Builder's Risk Insurance is Not Required for this project. ARTICLE 5 PROSECUTION AND PROGRESS 5.08 Add Article 5.08: The Contract Time as defined in the bid and other sections of the Contract Documents includes a certain number of rain days. Based on the Alvin Weather Center Records, the average annual rain days from June 1898 to December 1996 is 40 days calculated from all precipitation days of record. The CONTRACTOR is required to keep a record of rain days at the site. The record of rain days must be accepted and signed by the City Inspector monthly, and shall be reported on the monthly pay estimate submittal. At the end of the contract, the CONTRACTOR will be credited only for the number of accepted rain days that exceed 40 rain days per year, proportionate to the original Contract Time. General Notes: Sections 00100 Invitation to Bidders, 00200 Instructions to Bidders and 01505 Mobilization all make reference to provision by the CONTRACTOR of a laptop computer for use by the OWNER'S representative or CONSTRUCTION MANAGER. BIDDER is Not Required to 2-24-12 00800- 1 of 2 CITY OF PEARLAND SPECIAL CONDITIONS OF AGREEMENT provide this equipment or include this cost in the Bid. See Section 13730 for full details regarding this computer equipment. Section 01500 Temporary Facilities requires CONTRACTOR to provide high speed internet access in the Field Office. BIDDER is Not Required to provide either a Field Office or any internet access for this project. All other requirements remain and will be required per the section. It is the responsibility of the Contractor to coordinate with the Owner for all Traffic Control Documents. Contractor to coordinate with the Owner for procurement of Traffic Control Documents prior to permitting. Contractor is to keep a minimum of one lane open at all times,in both directions. No lane closures to extend beyond the defined work day. Contractor Will Not be required to provide an on-site construction office for the duration of this project. END OF SECTION 2-24-12 00800-2 of 2 General Decision Number: TX180056 01/05/2018 TX56 Superseded General Decision Number: TX20170056 State: Texas Construction Type: Highway Counties: Austin, Brazoria, Chambers, Fort Bend, Galveston, Hardin, Harris, Jefferson, Liberty, Montgomery, Orange, San Jacinto and Waller Counties in Texas. HIGHWAY CONSTRUCTION PROJECTS (excluding tunnels, building structures in rest area projects & railroad construction; bascule, suspension & spandrel arch bridges designed for commercial navigation, bridges involving marine construction; and other major bridges). Note: Under Executive Order (EO) 13658, an hourly minimum wage of $10.35 for calendar year 2018 applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2015. If this contract is covered by the EO, the contractor must pay all workers in any classification listed on this wage determination at least $10.35 per hour (or the applicable wage rate listed on this wage determination, if it is higher) for all hours spent performing on the contract in calendar year 2018. The EO minimum wage rate will be adjusted annually. Please note that this EO applies to the above-mentioned types of contracts entered into by the federal government that are subject to the Davis-Bacon Act itself, but it does not apply to contracts subject only to the Davis-Bacon Related Acts, including those set forth at 29 CFR 5.1(a)(2)-(60). Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Modification Number Publication Date 0 01/05/2018 * SUTX2011-013 08/10/2011 Rates Fringes CEMENT MASON/CONCRETE FINISHER (Paving and Structures) $ 12.98 ELECTRICIAN $ 27.11 FORM BUILDER/FORM SETTER Paving & Curb $ 12.34 Structures $ 12.23 LABORER Asphalt Raker $ 12.36 Flagger $ 10.33 Laborer, Common $ 11.02 Laborer, Utility $ 11.73 Pipelayer $ 12.12 Work Zone Barricade Servicer $ 11.67 PAINTER (Structures) $ 18.62 POWER EQUIPMENT OPERATOR: Asphalt Distributor $ 14.06 Asphalt Paving Machine $ 14.32 Broom or Sweeper $ 12.68 Concrete Pavement Finishing Machine $ 13.07 Concrete Paving, Curing, Float, Texturing Machine $ 11.71 Concrete Saw $ 13.99 Crane, Hydraulic 80 Tons or less $ 13.86 Crane, Lattice boom 80 tons or less $ 14.97 Crane, Lattice boom over 80 Tons $ 15.80 Crawler Tractor $ 13.68 Excavator, 50,000 pounds or less $ 12.71 Excavator, Over 50,000 pounds $ 14.53 Foundation Drill, Crawler Mounted $ 17.43 Foundation Drill, Truck Mounted $ 15.89 Front End Loader 3 CY or Less $ 13.32 Front End Loader, Over 3 CY $ 13.17 Loader/Backhoe $ 14.29 Mechanic $ 16.96 Milling Machine $ 13.53 Motor Grader, Fine Grade $ 15.69 Motor Grader, Rough $ 14.23 Off Road Hauler $ 14.60 Pavement Marking Machine $ 11.18 Piledriver $ 14.95 Roller, Asphalt $ 11.95 Roller, Other $ 11.57 Scraper $ 13.47 Spreader Box $ 13.58 Servicer $ 13.97 Steel Worker Reinforcing Steel $ 15.15 Structural Steel Welder $ 12.85 Structural Steel $ 14.39 TRUCK DRIVER Low Boy Float $ 16.03 Single Axle $ 11.46 Single or Tandem Axle Dump $ 11.48 Tandem Axle Tractor w/Semi Trailer $ 12.27 WELDERS - Receive rate prescribed for craft performing operation to which welding is incidental. Note: Executive Order (EO) 13706, Establishing Paid Sick Leave for Federal Contractors applies to all contracts subject to the Davis-Bacon Act for which the contract is awarded (and any solicitation was issued) on or after January 1, 2017. If this contract is covered by the EO, the contractor must provide employees with 1 hour of paid sick leave for every 30 hours they work, up to 56 hours of paid sick leave each year. Employees must be permitted to use paid sick leave for their own illness, injury or other health-related needs, including preventive care; to assist a family member (or person who is like family to the employee) who is ill, injured, or has other health-related needs, including preventive care; or for reasons resulting from, or to assist a family member (or person who is like family to the employee) who is a victim of, domestic violence, sexual assault, or stalking. Additional information on contractor requirements and worker protections under the EO is available at www.dol.gov/whd/govcontracts. Unlisted classifications needed for work not included within the scope of the classifications listed may be added after award only as provided in the labor standards contract clauses (29CFR 5.5 (a) (1) (ii)). The body of each wage determination lists the classification and wage rates that have been found to be prevailing for the cited type(s) of construction in the area covered by the wage determination. The classifications are listed in alphabetical order of "identifiers" that indicate whether the particular rate is a union rate (current union negotiated rate for local), a survey rate (weighted average rate) or a union average rate (weighted union average rate). Union Rate Identifiers A four letter classification abbreviation identifier enclosed in dotted lines beginning with characters other than "SU" or "UAVG" denotes that the union classification and rate were prevailing for that classification in the survey. Example: PLUM0198-005 07/01/2014. PLUM is an abbreviation identifier of the union which prevailed in the survey for this classification, which in this example would be Plumbers. 0198 indicates the local union number or district council number where applicable, i.e., Plumbers Local 0198. The next number, 005 in the example, is an internal number used in processing the wage determination. 07/01/2014 is the effective date of the most current negotiated rate, which in this example is July 1, 2014. Union prevailing wage rates are updated to reflect all rate changes in the collective bargaining agreement (CBA) governing this classification and rate. Survey Rate Identifiers Classifications listed under the "SU" identifier indicate that no one rate prevailed for this classification in the survey and the published rate is derived by computing a weighted average rate based on all the rates reported in the survey for that classification. As this weighted average rate includes all rates reported in the survey, it may include both union and non-union rates. Example: SULA2012-007 5/13/2014. SU indicates the rates are survey rates based on a weighted average calculation of rates and are not majority rates. LA indicates the State of Louisiana. 2012 is the year of survey on which these classifications and rates are based. The next number, 007 in the example, is an internal number used in producing the wage determination. 5/13/2014 indicates the survey completion date for the classifications and rates under that identifier. Survey wage rates are not updated and remain in effect until a new survey is conducted. Union Average Rate Identifiers Classification(s) listed under the UAVG identifier indicate that no single majority rate prevailed for those classifications; however, 100% of the data reported for the classifications was union data. EXAMPLE: UAVG-OH-0010 08/29/2014. UAVG indicates that the rate is a weighted union average rate. OH indicates the state. The next number, 0010 in the example, is an internal number used in producing the wage determination. 08/29/2014 indicates the survey completion date for the classifications and rates under that identifier. A UAVG rate will be updated once a year, usually in January of each year, to reflect a weighted average of the current negotiated/CBA rate of the union locals from which the rate is based. WAGE DETERMINATION APPEALS PROCESS 1.) Has there been an initial decision in the matter? This can be: * an existing published wage determination * a survey underlying a wage determination * a Wage and Hour Division letter setting forth a position on a wage determination matter * a conformance (additional classification and rate) ruling On survey related matters, initial contact, including requests for summaries of surveys, should be with the Wage and Hour Regional Office for the area in which the survey was conducted because those Regional Offices have responsibility for the Davis-Bacon survey program. If the response from this initial contact is not satisfactory, then the process described in 2.) and 3.) should be followed. With regard to any other matter not yet ripe for the formal process described here, initial contact should be with the Branch of Construction Wage Determinations. Write to: Branch of Construction Wage Determinations Wage and Hour Division U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 2.) If the answer to the question in 1.) is yes, then an interested party (those affected by the action) can request review and reconsideration from the Wage and Hour Administrator (See 29 CFR Part 1.8 and 29 CFR Part 7). Write to: Wage and Hour Administrator U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 The request should be accompanied by a full statement of the interested party's position and by any information (wage payment data, project description, area practice material, etc.) that the requestor considers relevant to the issue. 3.) If the decision of the Administrator is not favorable, an interested party may appeal directly to the Administrative Review Board (formerly the Wage Appeals Board). Write to: Administrative Review Board U.S. Department of Labor 200 Constitution Avenue, N.W. Washington, DC 20210 4.) All decisions by the Administrative Review Board are final. END OF GENERAL DECISION CITY OF PEARLAND TECHNICAL SPECIFICATIONS DIVISION 1 TECHNICAL SPECIFICATIONS DIVISION 1 GENERAL REQUIREMENTS 04/2008 CITY OF PEARLAND SUMMARY OF WORK Section 01100 SUMMARY OF WORK 1.0 GENERAL 1.01 SECTION INCLUDES A A summary of the Work to be performed under this Contract,work by Owner,Owner furnished products,Work sequence, future Work, Contractor's use of Premises, and Owner occupancy. 1.02 WORK COVERED BY CONTRACT DOCUMENTS A Work of the Contract is for furnishing and placing hot poured joint and crack sealant for various concrete pavement streets and asphalt pavement streets within the City of Pearland, as well as all labor, equipment, materials, and incidentals required for the project. B A list of concrete streets and asphalt streets that have been identified by the City of Pearland for joint and crack sealing is included in the Appendix of the Project Manual for bidding purposes. The City of Pearland reserves the right to add and/or remove streets at their discretion, depending on the available budget. C Contractor shall coordinate with City Public Works Department prior to starting the work to obtain their concurrence on which streets and/or street segments to begin the joint and crack sealing. Joint sealing linear footage quantities shall be tracked on a daily basis and provided to the City prior to starting on a new street. D Mobilization and traffic control as needed to facilitate the joint and crack sealing operations shall be considered incidental to the linear foot unit price bid for joint and crack sealing. 1.03 WORK BY OWNER A Not Applicable. 1.04 OWNER FURNISHED PRODUCTS A Not Applicable. 1.05 WORK SEQUENCE A Contractor to submit project schedule to Engineer&Owner for approval as specified in Section 01350 - Submittals. B Contractor shall coordinate the Work with the Engineer and Owner as specified in Section 01310 - Coordination and Meetings. 1.06 FUTURE WORK 08/2016 01100- 1 of 2 CITY OF PEARLAND SUMMARY OF WORK A Not Applicable. 1.07 CONTRACTOR'S USE OF PREMISES A Comply with procedures for access to the site and Contractor's use of rights-of-way as specified in Section 01140 - Contractor's Use of Premises. B Contractor shall be responsible for all utilities required for construction. 1.08 OWNER OCCUPANCY A Cooperate with the Owner to minimize conflict, and to facilitate the Owner's operations. Coordinate Contractor's activities with Engineer. B Schedule Work to accommodate this requirement. 2.0 PRODUCTS -NotUsed 3.0 EXECUTION -NotUsed END OF SECTION 08/2016 01100-2 of 2 CITY OF PEARLAND CONTRACTOR'S USE OF PREMISES Section 01140 CONTRACTOR'S USE OF PREMISES 1.0 GENERAL 1.01 SECTION INCLUDES A General use of the Project Site including properties inside and outside of the limits of construction, work affecting roads, ramps, streets and driveways and notification to adjacent occupants. B References to Technical Specifications: 1 Section 01350—Submittals 2 Section 01730—Cutting& Patching 3 Section 01555 —Traffic Control &Regulation 4 Section 01562—Waste Material Disposal 5 Section 01720—Field Surveying 6 Section 02980—Pavement Repair 7 Section 02770—Curbs, Curb & Gutter, &Headers 8 Section 02255 —Bedding, Backfill, & Embankment Materials 9 Section 02922—Sodding 10 Section 02921 —Hydromulch Seeding 1.02 SUBMITTALS A Make Submittals required by this Section under the provisions of Section 01350 — Submittals. 1.03 LIMITS OF CONSTRUCTION A Confine access,operations,and storage areas to limits of construction as shown on the Plans provided by Owner as stipulated in Section 00700 — General Conditions of Agreement; trespassing on abutting lands or other lands in the area is not allowed. B Contractor may make arrangements,at Contractor's cost,for temporary use of private properties,in which case Contractor and Contractor's surety shall indemnify and hold harmless the Owner against claims or demands arising from such use of properties outside of the limits of construction. 1. Improvements to private properties made for the Contractor's use must be removed upon completion of the Work. a. No fill material may be placed in temporary work areas or on adjacent private properties without the written permission of the Engineer or the issuance of a Fill Permit by the City of Pearland or other governing entity. C Restrict total length which materials may be distributed along the route of the construction at any one time to 1,000 linear feet unless otherwise approved by Engineer. 02/2008 01140- 1 of 4 CITY OF PEARLAND CONTRACTOR'S USE OF PREMISES 1.04 PROPERTIES OUTSIDE OF LIMITS OF CONSTRUCTION A Altering the condition of properties adjacent to and along the limits of construction will not be permitted unless authorized by the Engineer and property owner(s). B Means,methods,techniques,sequences,or procedures which will result in damage to properties or improvements in the vicinity outside of the limits of construction will not be permitted. C Any damage to properties outside of the limits of construction shall be repaired or replaced to the satisfaction of the Engineer and at no cost to the Owner. D Contractor shall protect or replace all property corners, monuments or other demarcations disturbed, damaged or lost as a result of his activities. The replacement of these devices shall be properly documented to the satisfaction of the City by a Registered Public Land Surveyor with copies delivered to the Owner or private property owner. 1.05 USE OF SITE A Obtain approvals of governing authorities prior to impeding or closing public roads or streets. Do not close consecutive intersections simultaneously B Notify Engineer 48 hours prior to closing a street or a street crossing. Permits for street closures are required in advance and are the responsibility of the Contractor. C Maintain access for emergency vehicles including access to fire hydrants. D Avoid obstructing drainage ditches or inlets; when obstruction is unavoidable due to requirements of the Work, provide grading and temporary drainage structures to maintain unimpeded flow. E Locate and protect private lawn sprinkler systems which may exist on rights-of-ways within the Project Site. Repair or replace damaged systems to condition equal to or better than that existing at start of the Work. F When required by the Work, cutting, patching, and fitting of Work to existing facilities,accommodating installation or connection of Work with existing facilities,or uncovering Work for access, inspection, or testing shall be performed in accordance with Section 01730—Cutting &Patching. G Fires are not permitted on the Project Site. 1.06 NOTIFICATION TO ADJACENT OCCUPANTS A Notify individual occupants in areas to be affected by the Work of the proposed construction and time schedule. Notification shall be 24 hours,72 hours and 2 weeks prior to work being performed within 200 feet of the homes or businesses. 02/2008 01140-2 of 4 CITY OF PEARLAND CONTRACTOR'S USE OF PREMISES B Include in notification names and telephone numbers of two representatives for resident contact,who will be available on 24-hour call. Include precautions which will be taken to protect private property and identify potential access or utility inconvenience or disruption. C Submit proposed notification to Engineer for approval. Consideration shall be given to the ethnicity of the neighborhood where English is not the dominant language. Notice shall be in an understandable language. 1.07 EXCAVATION IN STREETS AND DRIVEWAYS A Avoid hindering or needlessly inconveniencing public travel on a street or any intersecting alley or street for more than two blocks at any one time, except by permission of the Engineer. B Obtain the Engineer's approval when the nature of the Work requires closing of an entire street. Permits required for street closure are the Contractor's responsibility. Avoid unnecessary inconvenience to abutting property owners. C Remove surplus materials and debris and open 1000 feet or less for public use as work in that block is complete. D Acceptance of any portion of the Work will not be based on return of street to public use. E Avoid obstructing driveways or entrances to private property. F Provide temporary crossing or complete the excavation and backfill in one continuous operation to minimize the duration of obstruction when excavation is required across drives or entrances. G Provide barricades and signs in accordance with Section 01555 —Traffic Control & Regulation. 1.08 CLEAN-UP A Maintain Project Site in a neat and orderly manner. B Perform daily clean-up in and around construction zone of dirt,debris,scrap materials, other disposable items. C Leave streets, driveways, and sidewalks broom-clean or its equivalent at the end of each work day. D Promptly remove barriers, signs,and components of other control systems that are no longer being utilized. E Dispose of waste and excess materials in accordance with requirements of Section 01562—Waste Material Disposal. 02/2008 01140-3 of 4 CITY OF PEARLAND CONTRACTOR'S USE OF PREMISES 1.09 RESTORATION A Restore damaged permanent facilities to pre-construction conditions unless replacement or abandonment of facilities is indicated on the Plans. B Repair/Replace removed or damaged pavement in accordance with Section 02980— Pavement Repair and removed or damaged curbs, gutters, and headers in accordance with Section 02770 — Curbs, Curb & Gutter, & Headers. Repair/Replace with like materials to match existing style, lines, grades, etc., unless otherwise directed by Engineer. C Repair turf areas which become damaged by Contractor's operations at no additional cost to Owner. Level with bank sand or topsoil, conforming to Section 02255—Bedding, Backfill, & Embankment Materials, as approved by the Engineer. Provide sodding in areas of residential land use over the surface of ground disturbed during construction and not paved, or not designated to be paved, in accordance with Section 02922 —Sodding. Use only block sodding; do not use spot sodding or sprigging Provide hydromulch seeding in areas of commercial, industrial or undeveloped land use over the surface of ground disturbed during construction and not paved, or not designated to be paved, in accordance with Section 02921 —Hydromulch Seeding. Water and level newly sodded areas with adjoining turf using steel wheel rollers appropriate for sodding. 2.0 PRODUCTS - Not Used 3.0 EXECUTION - Not Used END OF SECTION 02/2008 01140-4 of 4 CITY OF PEARLAND MEASUREMENT AND PAYMENT PROCEDURES Section 01200 MEASUREMENT AND PAYMENT PROCEDURES 1.0 GENERAL 1.01 SECTION INCLUDES A Procedures for measurement and payment of Work. B Conditions for nonconformance assessment and nonpayment for rejected products. C References to Technical Specifications: See Bid Proposal Sheet D Reference Standards: 1. Concrete Reinforcing Steel Institute (CRSI) 2. American Institute of Steel Construction (AISC) 1.02 AUTHORITY A Units and methods delineated in this Section are intended to complement the criteria of the Technical Specifications and Section 00300—Bid Proposal. B In the event of conflict, the unit specified for Bid Items in Section 00300 — Bid Proposal shall govern. C Measurements and quantities submitted by the Contractor will be verified by the Engineer. D Contractor shall provide necessary equipment, workers, and survey personnel as required by Engineer to verify quantities. 1.03 UNIT QUANTITIES SPECIFIED A Quantity and measurement estimates stated in Section 00300 —Bid Proposal are for contract purposes only. Quantities and measurements supplied or placed in the Work, authorized and verified by Engineer shall determine payment as stated in Section 00700— General Conditions of Agreement. B If the actual Work requires greater or lesser quantities than those quantities indicated in Section 00300 — Bid Proposal, provide the required quantities at the unit prices contracted except as otherwise stated in Section 00700 — General Conditions of Agreement or in executed Change Order. 1.04 MEASUREMENT OF QUANTITIES A Measurement by Weight: Reinforcing steel, rolled or formed steel or other metal shapes will be measured by CRSI or AISC Manual of Steel Construction weights. Welded assemblies will be measured by CRSI or AISC Manual of Steel Construction or scale weights. 0512007 01200- 1 of 3 CITY OF PEARLAND MEASUREMENT AND PAYMENT PROCEDURES B Measurement by Volume: 1. Stockpiles: Measured by cubic dimension using mean length, width, and height or thickness. 2. Excavation and Embankment Materials: Measured by cubic dimension using the average end area method. C Measurement by Area: Measured by square dimension using mean length and width or radius. D Linear Measurement: Measured by linear dimension, at the item centerline or mean chord. E Stipulated Price Measurement: By unit designated in the agreement. F Other: Items measured by weight, volume, area, or lineal means or combination, as appropriate, as a completed item or unit of the Work. 1.05 PAYMENT A Payment includes full compensation for all required supervision,labor,products,tools, equipment,plant,transportation,services,and incidentals;and erection,application or installation of an item of the Work; and Contractor's overhead and profit. The price bid shall include the total cost for required Work. Claims for payment as Unit Price Work not specifically covered in Section 00300—Bid Proposal will not be accepted. B Progress Payments for Unit Price Work will be based on the Engineer's observations and evaluations of quantities incorporated in the Work multiplied by the unit price. C Progress Payments for Lump Sum Work will be based on the Engineer's observations and evaluations of the percentage of quantities included in the schedule of values incorporated in the Work. D Final Payment for Work governed by unit prices will be made on the basis of the actual measurements and quantities determined by Engineer multiplied by the unit price for Work which is incorporated in or made necessary by the Work. 1.06 NONCONFORMANCE ASSESSMENT A Remove and replace the Work, or portions of the Work, not conforming to the Contract Documents. B If, in the opinion of the Engineer, it is not practical to remove and replace the Work, the Engineer will direct one of the following remedies: 1. The nonconforming Work will remain as is, but the unit price will be adjusted to a lower price at the discretion of the Engineer. 2. The nonconforming Work will be modified as authorized by the Engineer, and the unit price will be adjusted to a lower price at the discretion of the Engineer, if the modified Work is deemed to be less suitable than originally specified. 05/2007 01200-2 of 3 CITY OF PEARLAND MEASUREMENT AND PAYMENT PROCEDURES C Individual Technical Specifications may modify these options or may identify a specific formula or percentage price reduction. D The authority of the Engineer to assess the nonconforming Work and identify payment adjustment is final. 1.07 NONPAYMENT FOR REJECTED PRODUCTS A Payment will not be made for any of the following: 1. Products wasted or disposed of in a manner that is not acceptable to Engineer. 2. Products determined as nonconforming before or after placement. 3. Products not completely unloaded from transporting vehicle. 4. Products placed beyond the lines and levels of the required Work. 5. Products remaining on hand after completion of the Work, unless specified otherwise. 6. Loading, hauling, and disposing of rejected products. 2.0 PRODUCTS - Not Used 3.0 EXECUTION - NotUsed END OF SECTION 05/2007 01200-3of3 CITY OF PEARLAND CHANGE ORDER PROCEDURES Section 01290 CHANGE ORDER PROCEDURES 1.0 GENERAL 1.01 SECTION INCLUDES A Procedures for processing Change Orders, including: 1. Assignment of a responsible individual for approval and communication of changes in the Work; 2. Documentation of change in Contract Price and Contract Time; 3. Change procedures, using proposals and construction contract modifications,Work Change Directive, Stipulated Price Change Order, Unit Price Change Order, Time and Materials Change Order; 4. Execution of Change Orders; 5. Correlation of Contractor Submittals. B References to Technical Specifications: 1. Section 01350—Submittals 2. Section 01760—Project Record Documents C Other References: 1. Rental Rate Blue Book for Construction Equipment(Data Quest Blue Book). Rental Rate is defined as the full unadjusted base rental rate for the appropriate item of construction equipment. 1.02 SUBMITTALS A Make Submittals required by this Section under the provisions of Section 01350 — Submittals. 1.03 RESPONSIBLE INDIVIDUAL A Contractor shall provide a letter indicating the name and address of the individual authorized to execute change documents, and who shall also be responsible for informing others in Contractor's employ and Subcontractors of changes to the Work. The information shall be provided at the Preconstruction Conference. 1.04 DOCUMENTATION OF CHANGE IN CONTRACT PRICE AND CONTRACT TIME A Provide full information required for identification and evaluation of proposed changes, and to substantiate costs of proposed changes in the Work. B Contractor shall document each Proposal for Change in cost or time with sufficient data to allow for its evaluation. 02/2008 01290- 1 of 4 CITY OF PEARLAND CHANGE ORDER PROCEDURES C Proposal for Change shall include, as a minimum, the following information as applicable: 1. Original Quantities of items in Section 00300—Bid Proposal with additions, reductions, deletions, and substitutions. 2. When Work items were not included in Section 00300—Bid Proposal, Contractor shall provide unit prices for the new items, with supporting information as required by the Engineer. 3. Justification for any change in Contract Time. 4. Additional data upon request. D For changes in the Work performed on a time-and-material basis, the following additional information may be required: 1. Quantities and description of products and equipment. 2. Taxes, insurance and bonds. 3. Overhead and profit as noted in Section 00700—General Conditions of Agreement, 7.03 "Extra Work". 4. Dates and times work was performed, and by whom. 5. Time records and certified copies of applicable payrolls. 6. Invoices and receipts for products, rented equipment, and subcontracts, similarly documented. E Rented equipment will be paid to the Contractor by actual invoice cost for the duration of time required to complete the extra work. If the extra work comprises only a portion of the rental invoice where the equipment would otherwise be on the site,the Contractor shall compute the hourly equipment rate by dividing the actual monthly invoice by 176. (One day equals 8 hours and one week equals 40 hours.) Operating costs shall not exceed the estimated operating costs given for the item of equipment in the Blue Book. F For changes in the work performed on a time-and-materials basis using Contractor- owned equipment, compute rates with the Blue Book as follows: 1. Multiply the appropriate Rental Rate by an adjustment factor of 70 percent plus the full rate shown for operating costs. The Rental Rate utilized shall be the lowest cost combination of hourly, daily, weekly or monthly rates. Use 150 percent of the Rental Rate for double shifts (one extra shift per day) and 200 percent of the Rental Rate for more than two shifts per day. No other rate adjustments shall apply. 2. Standby rates shall be 50 percent of the appropriate Rental Rate shown in the Blue Book. Operating costs will not be allowed. 1.05 CHANGE PROCEDURES A Changes to Contract Price or Contract Time can only be made by issuance of a Change Order. Issuance of a Work Change Directive or written acceptance by the Engineer of changes will be formalized into Change Orders. All such changes will be in accordance with the requirements of Section 00700 — General Conditions of Agreement, 7.01 "Change Orders". 02/2008 01290-2 of 4 CITY OF PEARLAND CHANGE ORDER PROCEDURES B The Engineer will advise Contractor of Minor Changes in the Work not involving an adjustment to Contract Price or Contract Time as authorized by Section 00700 — General Conditions of Agreement, 7.02 "Minor Changes", by issuing supplemental instructions. C Contractor may request clarification of Plans, Technical Specifications or Contract Documents or other information. Response by the Engineer to a Request for Information does not authorize the Contractor to perform tasks outside the scope of the Work. All changes must be authorized as described in this Section. 1.06 PROPOSALS FOR CHANGE AND CONTRACT MODIFICATION A The Engineer may issue a Request for Proposal,which includes a detailed description of a proposed change with supplementary or revised Plans and Technical Specifications.The Engineer may also request a proposal in the response to a Request for Information. Contractor will prepare and submit its Proposal for Change within 7 days or as specified in the request. B The Contractor may propose an unsolicited change by submitting a Proposal for Change to the Engineer describing the proposed change and its full effect on the Work, with a statement describing the reason for the change and the effect on the Contract Price and Contract Time including full documentation. 1.07 WORK CHANGE DIRECTIVE A Engineer may issue a signed Work Change Directive instructing the Contractor to proceed with a change in the Work, for subsequent inclusion in a Change Order. B The document will describe changes in the Work and will designate a method of determining any change in Contract Price or Contract Time. C Contractor shall proceed promptly to execute the changes in the Work in accordance with the Work Change Directive. 1.08 STIPULATED PRICE CHANGE ORDER A A Stipulated Price Change Order will be based on an accepted Proposal for Change including the Contractor's lump sum price quotation. 1.09 UNIT PRICE CHANGE ORDER A Where Unit Prices for the affected items of the Work are included in Section 00300- Bid Proposal , the Unit Price Change Order will be based on unit prices as originally bid, subject to provisions of Section 00700—General Conditions of Agreement. B Where unit prices of the Work are not pre-determined in Section 00300 — Bid Proposal, Work Change Directive or accepted Proposal for Change will specify the unit prices to be used. 02/2008 01290-3 of 4 CITY OF PEARLAND CHANGE ORDER PROCEDURES 1.10 TIME-AND-MATERIAL CHANGE ORDER A Contractor shall provide an itemized account and supporting data after completion of change,within time limits indicated for claims in Section 00700—General Conditions of Agreement. B Engineer will determine the change allowable in Contract Price and Contract Time as provided in Section 00700—General Conditions of Agreement. C Contractor shall maintain detailed records of work done on time-and-material basis as specified in this Section, 1.04 "Documentation of Change in Contract Price and Contract Time". D Contractor shall provide full information required for evaluation of changes,and shall substantiate costs for changes in the Work. 1.11 EXECUTION OF CHANGE DOCUMENTATION A Engineer will issue Change Orders, Work Change Directives, or accepted Proposals for Change for signatures of parties named in Section 00500 — Standard Form of Agreement. 1.12 CORRELATION OF CONTRACTOR SUBMITTALS A For Stipulated Price Contracts, Contractor shall promptly revise Schedule of Values and Application for Payment forms to record each authorized Change Order as a separate line item and adjust the Contract Price. B For Unit Price Contracts,the next monthly Application for Payment of the Work after acceptance of a Change Order will be revised to include any new items not previously included and the appropriate unit rates. C Contractor shall promptly revise progress schedules to reflect any change in Contract Time,and shall revise schedules to adjust time for other items of work affected by the change, and resubmit for review. D Contractor shall promptly enter changes to the on-site and record copies of the Plans, Technical Specifications or Contract Documents as required in Section 01760 — Project Record Documents. 2.0 PRODUCTS - NotUsed 3.0 EXECUTION - NotUsed END OF SECTION 02/2008 01290-4 of 4 CITY OF PEARLAND COORDINATION AND MEETINGS Section 01310 COORDINATION AND MEETINGS 1.0 GENERAL 1.01 SECTION INCLUDES A Section includes general coordination including Preconstruction Conference, Site Mobilization Conference, and Progress Meetings. B References to Technical Specifications: 1. Section 01100—Summary of Work 1.02 RELATED DOCUMENTS A Coordination is required throughout the documents. Refer to all of the Contract Documents and coordinate as necessary. 1.03 ENGINEER AND REPRESENTATIVES A The Engineer may act directly or through designated representatives as defined in Section 00700 — General Conditions of Agreement, 1.01 "Owner, Contractor, and Engineer", and as identified by name at the Preconstruction Conference. 1.04 CONTRACTOR COORDINATION A Coordinate scheduling,submittals,and work of the various Technical Specifications to assure efficient and orderly sequence of installation of interdependent construction elements. B Coordinate completion and clean up of the Work for Substantial Completion and for portions of the Work designated for Owner's partial occupancy. C Coordinate access to Project Site for correction of nonconforming work to minimize disruption of Owner's activities where Owner is in partial occupancy. 1.05 PRECONSTRUCTION CONFERENCE A Engineer will schedule a Preconstruction Conference. B Attendance Required: Engineer's representatives,Consultants,Contractor,and major Subcontractors. C Agenda: 1. Distribution of Contract Documents. 2. Designation of personnel representing the parties to the Contract, and the Consultant. 3. Review of insurance. 02/2008 01310- 1 of 3 CITY OF PEARLAND COORDINATION AND MEETINGS 4. Discussion of formats proposed by the Contractor for Schedule of Values, and Construction Schedule. 5. Discussion of required Submittals, including, but not limited to,Work Plans,Traffic Control Plans, Safety Programs, Construction Photographs. 6. Procedures and processing of Shop Drawings and other submittals, substitutions, Applications for Payment, Requests for Information, Request for Proposal, Change Orders, and Contract Closeout. 7. Scheduling of the Work and coordination with other contractors. 8. Review of Subcontractors. 9. Appropriate agenda items listed in this Section, 1.06 "Site Mobilization Conference", when Preconstruction Conference and Site Mobilization Conference are combined. 10. Procedures for testing. 11. Procedures for maintaining Project Record Documents. 12. Designation of the individual authorized to execute change documents and their responsibilities. 13. Discussion of requirements of a Trench Safety Program. 1.06 SITE MOBILIZATION CONFERENCE A When required by Section 01100—Summary of Work,Engineer will schedule a Site Mobilization Conference at the Project Site prior to Contractor occupancy. B Attendance Required: Engineer representatives, Consultants, Contractor's Superintendent, and major Subcontractors. C Agenda: 1. Use of premises by Owner and Contractor 2. Safety and first aid procedures 3. Construction controls provided by Owner 4. Temporary utilities 5. Survey and layout 6. Security and housekeeping procedures 1.07 PROGRESS MEETINGS A Progress Meetings shall be held at Project Site or other location as designated by the Engineer. Meeting shall be held at monthly intervals, or more frequent intervals if directed by Engineer. B Attendance Required: Job superintendent, major Subcontractors and suppliers, Engineer representatives, and Consultants as appropriate to agenda topics for each meeting. C Engineer or City's representative will make arrangements for meetings,and recording minutes. D Engineer or City's representative will prepare the agenda and preside at meetings. 02/2008 01310-2 of 3 CITY OF PEARLAND COORDINATION AND MEETINGS E Contractor shall provide required information and be prepared to discuss each agenda item. F Agenda: 1. Review minutes of previous meeting. 2. Review of Construction Schedule, Applications for Payment, payroll and compliance submittals. 3. Field observations, problems, and decisions. 4. Identification of problems which impede planned progress. 5. Review of Submittal Schedule and status of submittals. 6. Review status of Requests for Information, Requests for Proposal. 7. Review status of Change Orders. 8. Review of off-site fabrication and delivery schedules. 9. Maintenance of updates to Construction Schedule. 10. Corrective measures to regain projected schedules. 11. Planned progress during succeeding work period. 12. Coordination of projected progress. 13. Maintenance of quality and work standards. 14. Effect of proposed changes on Construction Schedule and coordination. 15. Other items relating to the Work. 2.0 PRODUCTS - Not Used 3.0 EXECUTION - NotUsed END OF SECTION 02/2008 01310-3 of 3 CITY OF PEARLAND SUBMITTALS Section 01350 SUBMITTALS 1.0 GENERAL This Section contains general lists of Submittals and Technical Specifications that may be required for the Work. When Submittals are required elsewhere in these Technical Specifications,refer to this Section for Submittal requirements and procedures. 1.01 SECTION INCLUDES A Submittal procedures for: 1. Schedule of Values 2. Construction Schedules 3. Shop Drawings, Product Data, and Samples 4. Operations and Maintenance Data 5. Manufacturer's Certificates 6. Construction Photographs 7. Project Record Documents 8. Design Mixes B References to the following Technical Specifications: 1. Section 01310—Coordination&Meetings 2. Section 01630—Product Options &Substitutions 3. Section 01100—Summary of Work 4. Section 01380—Construction Photographs 5. Section 01760—Project Record Documents 6. Section 02530—Gravity Sanitary Sewers 1.02 SUBMITTAL PROCEDURES A Scheduling and Handling 1. Schedule Submittals well in advance of the need for material or equipment for construction. Allow time to make delivery of material or equipment after Submittal is approved. 2. Develop a Submittal Schedule that allows sufficient time for initial review, correction,resubmission and final review of all submittals.The Engineer will review and return submittals to the Contractor as expeditiously as possible but the amount of time required for review will vary depending on the complexity and quantity of data submitted. In no case will a Submittal Schedule be acceptable which allows less than 30 days for initial review by the Engineer. This time for review shall in no way be justification for delays or additional compensation to the Contractor. 3. The Engineer's review of submittals covers conformity to the Plans,Technical Specifications, and dimensions which affect the layout. The Contractor is responsible for quantity determination. The Contractor is responsible for any errors, omissions or deviations from the Contract requirements; review of 01/2008 01350- 1 of 6 CITY OF PEARLAND SUBMITTALS submittals in no way relieves the Contractor from his obligation to furnish required items according to the Plans and Technical Specifications. 4. Submit 5 copies of documents unless otherwise specified in this Section or by individual Technical Specifications. 5. Revise and resubmit submittals as required. Identify all changes made since previous submittal. 6. The Contractor shall assume the risk for material or equipment which is fabricated or delivered prior to approval. No material or equipment shall be incorporated into the Work or included in Applications for Payment until approval has been obtained in the specified manner. B Transmittal Form and Numbering 1. Transmit each submittal to the Engineer with a transmittal form. 2. Sequentially number each transmittal form beginning with the number 1. Re- Submittals shall use the original number with an alphabetic suffix(i.e.,2A for first Re-Submittal of Submittal 2 or 15C for third Re-Submittal of Submittal 15). Each submittal shall only contain one type of work, material, or equipment. Mixed submittals will not be accepted. 3. Identify variations from requirements of Contract Documents and identify product or system limitations. 4. For submittal numbering of video tapes, see this Section, 1.10"Video". C Contractor's Certification 1. Each submittal shall contain a statement or stamp signed by the Contractor, certifying that the items have been reviewed in detail and are correct and in accordance with Contract Documents, except as noted by any requested variance. 1.03 SCHEDULE OF VALUES A Submit a Schedule of Values at least 10 days prior to the first Application for Payment. A Schedule of Values shall be provided for each of the items indicated as Lump Sum (LS) in Section 00300 — Bid Proposal for which the Contractor requests to receive Progress Payments. B Schedule of Values shall be typewritten on 8-1/2"x 11",plain bond,white paper. Use the Table of Contents of this Project Manual as a format for listing costs of Work by Section. C Round off figures for each listed item to the nearest $100.00 except for the value of one item, if necessary, to make the total price for all items listed in the Schedule of Values equal to the applicable Lump Sum in Section 00300—Bid Proposal. D For Unit Price Contracts, items should include a proportional share of Contractor's overhead and profit, such that the total of all items listed in the Schedule of Values equals the Contract amount. For Stipulated Price Contracts,Mobilization,Bonds,and Insurance may be listed as separate items in the Schedule of Values. 01/2008 01350-2 of 6 CITY OF PEARLAND SUBMITTALS E For Lump Sum equipment items, where Submittals for Testing, Adjusting, and Balancing Reports in conjunction with Operation and Maintenance Data are required, include a separate item for equipment Operation and Maintenance Data Submittals and a separate item for Submittals of equipment Testing, Adjusting, and Balancing Reports, each valued at five (5) percent of the Lump Sum. F Revise the Schedule of Values and resubmit for items affected by contract modifications,Change Orders,and Work Change Directives. Submit revised Schedule of Values 10 days prior to the first Application for Payment after the changes are approved by the Engineer. 1.04 CONSTRUCTION SCHEDULES A Submit Construction Schedules for the Work in accordance with the requirements of this Section. The Construction Schedule Submittal shall be,at a minimum,a bar chart, (computer generated or prepared manually) and a narrative report. B During the Preconstruction Meeting, as noted in Section 01310 - Coordination and Meetings, the Contractor shall provide a sample of the format to be used for the Construction Schedule Submittal. The format is subject to approval by the Engineer. Review of the Submittal will be provided within 7 days of the Submittal of the sample. C Within 7 days of the receipt of approval of the Contractor's format, or 14 days of the Notice to Proceed, whichever is later, the Contractor shall submit a proposed Construction Schedule for review. The Construction Schedule Submittal shall meet the following requirements: 1. The Construction Schedule shall usually include a total of at least 20 but not more than 50 activities. Fewer activities may be accepted,if approved by the Engineer. 2. For Projects with work at different physical locations,each location should be indicated separately within the Construction Schedule. 3. For projects with multiple crafts or significant subcontractor components,these elements should be indicated separately within the Construction Schedule. 4. For Projects with multiple types of tasks within the scope,these types of work should be indicated separately within the Construction Schedule. 5. For Projects with significant major equipment items or materials worth over 25 percent of the Total Contract Price, the Construction Schedule shall indicate dates when these items are to be purchased, when they are to be delivered,and when installed. 6. For Projects where operating plants are involved, each period of work which will require the shut down of any process or operation shall be identified in the Construction Schedule and must be agreed to by the Engineer prior to starting work in the area. 7. A Billing Schedule(tabulation of the estimated monthly billings)for the Work shall be prepared and submitted by the Contractor with the first Construction Schedule. This information is not required in the monthly updates, unless significant changes in Work require re-submittal of the Construction Schedule for review. The total for each month and a cumulative total will be indicated. 01/2008 01350-3 of 6 CITY OF PEARLAND SUBMITTALS These monthly forecasts are only for planning purposes of the Engineer. Monthly payments for actual work completed will be made by the Engineer in accordance with Section 00700 - General Conditions of Agreement. D The Contractor must receive approval of the Engineer for the Construction Schedule and Billing Schedule prior to the first monthly Application for Payment. No payment will be made until these are accepted. E Upon written request from the Engineer, the Contractor shall revise and submit for approval all or any part of the Construction Schedule to reflect changed conditions in the Work or deviations made from the original plan and schedule. F The Contractor's Construction Schedule shall thereafter be updated with the Actual Start and Actual Finish Dates, Percent Complete, and Remaining Duration of each Activity and submitted monthly. The date to be used in updating the monthly Construction Schedule shall be the same Date as is used in the monthly Application for Payment. This monthly update of the Construction Schedule shall be required before the monthly Application for Payment will be processed for payment. G The narrative Construction Schedule Report shall include a description of changes made to the Construction Schedule; Activities Added to the Construction Schedule; Activities Deleted from the Construction Schedule; any other changes made to the Construction Schedule other than the addition of Actual Start Dates and Actual Finish Dates and Remaining Durations. 1.05 SHOP DRAWINGS,PRODUCT DATA, AND SAMPLES A Shop Drawings 1. Submit Shop Drawings for review as required by the Technical Specifications. 2. Contractor's Certification, as described in this Section, 1.02 "Submittal Procedures" shall be placed on each Shop Drawing. 3. The Shop Drawing shall accurately and distinctly present the following: a. Field and erection dimensions clearly identified as such. b. Arrangement and section views. c. Relation to adjacent materials or structure including complete information for making connections between work under this Contract and work under other contracts. d. Kinds of materials and finishes. e. Parts list and descriptions. f. Assembly Shop Drawings of equipment components and accessories showing their respective positions and relationships to the complete equipment package. g. Where necessary for clarity, identify details by reference to sheet numbers and detail numbers, schedule or room numbers as shown on the Plans. 4. Shop Drawing Drawings shall be to scale,and shall be a true representation of the specific equipment or item to be furnished. 01/2008 01350-4 of 6 CITY OF PEARLAND SUBMITTALS B Product Data 1. Submit Product Data for review when required in individual Technical Specifications. 2. Contractor's Certification, as described in this Section, 1.02 "Submittal Procedures" shall be placed on each data item submitted. 3. Mark each copy to identify applicable products,models,options to be used in this Project. Supplement manufacturers'standard data to provide information unique to this Project, where required by the Technical Specification. 4. For products specified only by reference standard,submit manufacturer,trade name, model or catalog designation, and applicable reference standard. 5. For Approved Products, those designated in the Technical Specifications followed by the words"or approved equal",submit manufacturer,trade name, model or catalog designation, and applicable reference standard. 6. For products proposed as alternates to Approved Products, refer to Section 01630-Product Options and Substitutions, 1.04"Selection Options"and 1.07 "Substitution Procedures". 7. For products that are neither Pre-Approved, Approved, specified only by reference standard, nor proposed as alternates, submit product description, trade name, manufacturer, and supplier. Contractor shall provide additional information upon written request by Engineer or Owner. C Samples 1. Submit samples for review as required by the Technical Specification. 2. Contractor's Certification, as described in this Section, 1.02 "Submittal Procedures", shall be placed on each sample or a firmly attached sheet of paper. 3. Submit the number of samples specified in the Technical Specification;one of which will be retained by the Engineer. 4. Reviewed samples which may be used in the Work are identified in the Technical Specifications. 1.06 OPERATIONS AND MAINTENANCE DATA A When specified in Technical Specification,submit manufacturers'printed instructions for delivery, storage, assembly, installation, start-up, operation, adjusting, finishing, and maintenance. B Contractor's Certification, as described in this Section. 1.02 "Submittal Procedures", shall be placed on front page of each document. C Identify conflicts between manufacturers'instructions and Contract Documents. 1.07 MANUFACTURER'S CERTIFICATES A When specified in Technical Specification, submit manufacturers' certificate of compliance for review by Engineer. B Contractor's Certification, as described in this Section, 1.02 "Submittal Procedures", shall be placed on front page of the certificate. 01/2008 01350-5 of 6 CITY OF PEARLAND SUBMITTALS C Submit supporting reference data, affidavits, and certifications as appropriate. D Manufacturer's Certificates may be recent or previous test results on material or product, but must be acceptable to Engineer. 1.08 CONSTRUCTION PHOTOGRAPHS A Submit photographs in accordance with Section 01380—Construction Photographs. 1. Prints: Prepare 2 prints of each view and submit 1 print directly to the City's Representative within 7 days of taking photographs. One print shall be retained by the Contractor and made available at all times for reference on the job site. B PRECONSTRUCTION PHOTOGRAPHS: 1. Prior to the commencement of any construction,take digital color photographs on the entire route of the project 2. Photographs: Two prints, color, matte finish; 3 x 5 inch size, mounted on 8' x 11-inch soft card stock, with left edge binding margin for three hole punch, or in plastic pockets in three-ring notebook. 3. Th photographs shall show: a. Date photographs were taken b. Location of the photograph, house number and street name. (This information may be shown on a chalk board in the photograph by a label on the mountings.) 4. Photographs should show the condition of the following a. Esplanades and boulevards b. Yards (near, side and far side of street) c. Housewalk, sidewalk and driveway; curb d. Area between walk and curb 1) Particular features(yard lights, shrubs, fences, trees, etc.) 2) Landscaping and decorative features. C POST CONSTRUCTION PHOTOGRAPHS 1. On completion of construction, provide photographs of any public or private property which has been repaired or restored and any damage which is or may be the subject of complaints. 1.09 PROJECT RECORD DOCUMENTS A Submit Project Record Documents in accordance with Section 01760—Project Record Documents. 1.10 VIDEO A Submit television video in DVD format as required in individual Technical Specifications. B Transmittal forms for video disks shall be numbered sequentially beginning with T01, T02, T03, etc. 01/2008 01350-6 of 6 CITY OF PEARLAND SUBMITTALS 1.11 DESIGN MIXES A When specified, submit design mixes for review. B Contractor's Certification, as described in this Section, 1.02 "Submittal Procedures", shall be placed on front page of each design mix. C Mark each design mix to identify proportions, gradations, and additives for each class and type of design mix submitted. Include applicable test results on samples for each mix. D Maintain a copy of approved design mixes at mixing plant. 2.0 PRODUCTS - Not Used 3.0 EXECUTION - NotUsed END OF SECTION 01/2008 01350-7of6 CITY OF PEARLAND REFERENCED STANDARDS Section 01420 REFERENCED STANDARDS 1.0 GENERAL 1.01 SECTION INCLUDES A General quality assurance as related to Reference Standards and a list of references. B References to Technical Specifications: None 1.02 QUALITY ASSURANCE A For Products or workmanship specified by association, trade, or Federal Standards comply with requirements of the standard, except when more rigid requirements are specified or are required by applicable codes. B Conform to reference standard by date of issue current on the date as stated in Section 00700— General Conditions of Agreement. C Request clarification from Engineer before proceeding should specified reference standards conflict with Contract Documents. 1.03 SCHEDULE OF REFERENCES AASHTO American Association of State Highway and Transportation Officials 444 North Capitol Street, N.W. Washington, DC 20001 ACI American Concrete Institute P.O. Box 19150 Reford Station Detroit, MI 48219-0150 AGC Associated General Contractors of America 1957 E Street, N.W. Washington, DC 20006 AI Asphalt Institute Asphalt Institute Building College Park, MD 20740 AITC American Institute of Timber Construction 333 W. Hampden Avenue Englewood, CO 80110 02/2008 01420- 1 of 5 CITY OF PEARLAND REFERENCED STANDARDS AISC American Institute of Steel Construction 400 North Michigan Avenue,Eighth Floor Chicago, IL 60611 AISI American Iron and Steel Institute 1000 16th Street, N.W. Washington, DC 20036 ASME American Society of Mechanical Engineers 345 East 47th Street New York, NY 10017 ANSI American National Standards Institute 1430 Broadway New York,NY 10018 APA American Plywood Association Box 11700 Tacoma, WA 98411 API American Petroleum Institute 1220 L Street, N.W. Washington, DC 20005 AREA American Railway Engineering Association 50 F Street, N.W. Washington, DC 20001 ASTM American Society for Testing and Materials 1916 Race Street Philadelphia, PA 19103 AWPA American Wood-Preservers' Association 7735 Old Georgetown Road Bethesda, MD 20014 AWS American Welding Society P.O. Box 35104 Miami, FL 33135 AWWA American Water Works Association 6666 West Quincy Avenue Denver, CO 80235 02/2008 01420-2 of 5 CITY OF PEARLAND REFERENCED STANDARDS CLFMI Chain Link Fence Manufacturers Institute 1101 Connecticut Avenue, N.W. Washington, DC 20036 CRD U.S.A. Corps of Engineers Code of Ordinances City of Pearland 3519 Liberty Drive Pearland, TX 77581 CRSI Concrete Reinforcing Steel Institute 933 Plum Grove Road Schaumburg, IL 60173-4758 EJMA Expansion Joint Manufacturers Association 707 Westchester Avenue White Plains, NY 10604 FDA U.S. Food and Drug Administration 5600 Fisher Lane Rockville, MD 20857-0001 FS Federal Standardization Documents General Services Administration, Specifications Unit(WFSIS) 7th and D Street S.W. Washington, DC 20406 ICEA Insulated Cable Engineer Association P.O. Box 440 S. Yarmouth, MA 02664 IEEE Institute of Electrical and Electronics Engineers 445 Hoes Lane P.O. Box 1331 Piscataway, NJ 0855-1331 MIL Military Specifications General Services Administration, Specifications Unit (WFSIS) 7th and D Street S.W. Washington, DC 20406 NACE National Association of Corrosion Engineers P. O. Box 986 Katy, TX 77450 02/2008 01420-3 of 5 CITY OF PEARLAND REFERENCED STANDARDS NEMA National Electrical Manufacturers'Association 2101 L Street, N.W., Suite 300 Washington, DC 20037 NFPA National Fire Protection Association Batterymarch Park, P.O. Box 9101 Quincy, MA 02269-9101 OSHA Occupational Safety Health Administration U.S. Department of Labor, Government Printing Office Washington, DC 20402 PCA Portland Cement Association 5420 Old Orchard Road Skokie,IL 60077-1083 PCI Prestressed Concrete Institute 201 North Wacker Drive Chicago, IL 60606 SDI Steel Deck Institute Box 9506 Canton, OH 44711 SSPC Steel Structures Painting Council 4400 Fifth Avenue Pittsburgh, PA 15213 TAC Texas Administrative Code TCEQ Texas Commission on Environmental Quality P. O. Box 13087 Austin, TX 78711-3087 TxDOT Texas Department of Transportation 125 East 11th Street Austin, TX 78701-2483 Texas MUTCD Texas Manual on Uniform Traffic Control Devices (2003 Adoption) (published by Texas Department of Transportation) UL Underwriters'Laboratories, Inc. 333 Pfingston Road Northbrook, IL 60062 UNI-BELL UNI-BELL Pipe Association 2655 Villa Creek Drive, Suite 155 02/2008 01420-4 of 5 CITY OF PEARLAND REFERENCED STANDARDS Dallas, TX 75234 WRI Wire Reinforcement Institute 942 Main Street— Suite 300 Hartford, CT 06103 WWD/PI Water Well Drillers and Pump Installers Advisory Council Texas Department of Licensing and Regulation P.O. Box 12157 Austin, TX 78711 2.0 PRODUCTS - NotUsed 3.0 EXECUTION - NotUsed END OF SECTION 02/2008 01420-5 of 5 CITY OF PEARLAND CONTRACTOR'S QUALITY CONTROL Section 01430 CONTRACTOR'S QUALITY CONTROL 1.0 GENERAL 1.01 SECTION INCLUDES A Quality assurance and control of installation and manufacturer's field services and reports. B References to Technical Specifications: 1. Section 01350—Submittals 1.02 SUBMITTALS A Make Submittals required by this Section under the provisions of Section 01350 — Submittals. 1.03 QUALITY ASSURANCE/CONTROL OF INSTALLATION A Monitor quality control over suppliers, manufacturers, products, services, site conditions, and workmanship, to produce the Work of specified quality at no additional cost to the Owner. B Comply fully with manufacturers' installation instructions, including each step in sequence. C Request clarification from Project Manager before proceeding should manufacturers' instructions conflict with Contract Documents. D Comply with specified Standards as minimum requirements for the Work except when more stringent tolerances,codes,or specified requirements indicate higher standards or more precise workmanship. E Perform work by persons qualified to produce the specified level of workmanship. F Obtain copies of Standards and maintain at Project Site when required by individual Technical Specifications. 1.04 MANUFACTURERS' FIELD SERVICES AND REPORTS A When specified in individual Technical Specifications, provide material or product suppliers' or manufacturers' technical representative to observe site conditions, conditions of surfaces and installation,quality of workmanship,start-up of equipment, operator training, test, adjust, and balance of equipment as applicable, and to initiate operation,as required. Conform to minimum time requirements for start-up operations and operator training if defined in Technical Specifications. 02/2008 01430- 1 of 2 CITY OF PEARLAND CONTRACTOR'S QUALITY CONTROL B At the Project Manager's request, submit qualifications of manufacturer's representative to Project Manager fifteen (15) days in advance of required representative's services. The representative shall be subject to approval of Project Manager. C Manufacturer's representative shall report observations and site decisions or instructions given to applicators or installers that are supplemental or contrary to manufacturers'written instructions. Submit report within one(1)day of observation to Project Manager for review. 2.0 PRODUCTS - Not Used 3.0 EXECUTION - NotUsed END OF SECTION 02/2008 01430-2 of 2 CITY OF PEARLAND WASTE MATERIAL DISPOSAL Section 01562 WASTE MATERIAL DISPOSAL 1.0 GENERAL 1.01 SECTION INCLUDES A Disposal of waste material and salvageable material. B References to Technical Specifications: 1. Section 01350—Submittals 2. Section 01566—Source Controls for Erosion & Sedimentation 3. Section 01600—Materials &Equipment 1.02 MEASUREMENT AND PAYMENT A Unless indicated as a Bid Item,no separate payment will be made for Work performed under this Section. Include cost in Bid Items for which this Work is a component. 1.03 SUBMITTALS A Make Submittals required by this Section under the provisions of Section 01350 — Submittals. B Obtain and submit applicable permits for proposed disposal sites. C Submit a Waste Material Disposal Plan. D Submit a copy of written permission from property owners,along with a description of the property,prior to disposal of excess material adjacent to the Project Site. Submit a written and signed release from property owner upon completion of disposal work. City of Pearland requires individual fill placement permits for all fill placed within the City limits. 1.04 WASTE MATERIAL DISPOSAL PLAN A Contractor shall formulate and implement a plan for the collection and disposal of waste materials on the Project Site which includes the following information: 1. Schedule for collection and inspection. 2. Location of trash and waste receptacles. 3. Provisions for liquid waste and potential water pollutants material. B The plan shall comply with applicable federal, state, and local health and safety regulations and Section 01566—Source Controls for Erosion & Sedimentation. 2.0 PRODUCTS - Not Used 07/2006 01562- 1 of 3 CITY OF PEARLAND WASTE MATERIAL DISPOSAL 3.0 EXECUTION 3.01 SALVAGEABLE MATERIAL A Excavated material: When indicated on Plans, load, haul, and deposit excavated material at a location or locations outside the limits of Project Site. B Base, surface, and bedding material: Deliver gravel, asphaltic, or other base and surfacing material designated for salvage to the location designated by the Engineer. C Pipe culvert: Deliver culverts designated for salvage to Owner's storage area. D Other salvageable materials: Conform to requirements of individual Technical Specifications. E Coordinate delivery of salvageable material with Engineer. F When temporary, on-site storage of salvaged materials is required, comply with applicable provisions of Section 01600—Materials &Equipment. 3.02 SEDIMENT DISPOSAL A Remove sediment deposits and dispose of them at the designated spoil site for the Project. If a spoil site is not designated on the Plans,dispose of sediment off site at a location not in or adjacent to a stream or floodplain. B Off-site disposal is the responsibility of the Contractor. C Sediment to be placed at the Project Site should be spread evenly throughout the designated area,compacted and stabilized. Sediment shall not be allowed to flush into a stream or drainage way. D If sediment has been contaminated,it shall be disposed of in accordance with existing federal, state, and local rules and regulations. 3.03 EXCESS MATERIAL, WASTE,AND EQUIPMENT A Vegetation,rubble,broken concrete,debris,asphaltic concrete pavement,excess soil, and other materials not designated for salvage,shall become the property of Contractor and shall be removed from the Project Site and legally disposed of. B Dispose of removed equipment,materials,waste and debris in a manner conforming to applicable laws and regulations C Excess soil may be deposited on private property adjacent to the Project Site when written permission is obtained from property owner under the provisions of this Section, 1.03D. 07/2006 01562-2 of 3 CITY OF PEARLAND WASTE MATERIAL DISPOSAL D Verify the flood plain status of any proposed disposal site. Do not dispose of excavated materials in an area designated as within the 100-year Flood Hazard Area. E Waste materials shall be removed from the site on a daily basis, such that the site is maintained in a neat and orderly condition. F No materials shall be disposed in a manner to damage the Owner in any way. END OF SECTION 07/2006 01562-3 of 3 CITY OF PEARLAND MATERIAL AND EQUIPMENT Section 01600 MATERIAL AND EQUIPMENT 1.0 GENERAL 1.01 SECTION INCLUDES A Requirements for transportation, delivery, handling, and storage of materials and equipment. B References to Technical Specifications: 1. Section 01566—Source Controls for Erosion & Sedimentation 1.02 MEASUREMENT AND PAYMENT A Unless indicated as a Bid Item,no separate payment will be made for Work performed under this Section. Include cost in Bid Items for which this work is a component. 1.03 PRODUCTS A Products: Means material,equipment,or systems forming the Work. Does not include machinery and equipment used for preparation,fabrication,conveying and erection of the Work. Products may also include existing materials or components designated for reuse. B Do not reuse materials and equipment,designated to be removed,except as specified by the Contract Documents. C Provide equipment and components from the fewest number of manufacturers as is practical, in order to simplify spare parts inventory and to allow for maximum interchangeability of components. For multiple components of the same size,type or application, use the same make and model of component throughout the Work. 1.04 TRANSPORTATION A Make arrangements for transportation, delivery, and handling of equipment and materials required for timely completion of the Work. B Transport and handle products in accordance with instructions. C Consign and address shipping documents to the proper party giving name of Project, street number, and City. Shipments shall be delivered to the Contractor. 1.05 DELIVERY A Arrange deliveries of products to accommodate the Construction Schedule and in ample time to facilitate inspection prior to installation. Avoid deliveries that cause lengthy storage or overburden of limited storage space. 07/2006 01600- 1 of 3 CITY OF PEARLAND MATERIAL AND EQUIPMENT B Coordinate deliveries to avoid conflict with Work and conditions at the Project Site and to accommodate the following: 1. Work of other contractors or the Owner. 2. Limitations of storage space. 3. Availability of equipment and personnel for handling products. 4. Owner's use of premises. C Have products delivered to the Project Site in manufacturer's original, unopened, labeled containers. D Immediately upon delivery, inspect shipment to assure: 1. Product complies with requirements of Contract Documents. 2. Quantities are correct. 3. Containers and packages are intact; labels are legible. 4. Products are properly protected and undamaged. 1.06 PRODUCT HANDLING A Coordinate the off-loading of materials and equipment delivered to the Project Site. If necessary to move stored materials and equipment during construction, Contractor shall relocate materials and equipment at no additional cost to the Owner. B Provide equipment and personnel necessary to handle products, including those provided by the Owner,by methods to prevent damage to products or packaging. C Provide additional protection during handling as necessary to prevent breaking scraping, marring, or otherwise damaging products or surrounding areas. D Handle products by methods to prevent over bending or overstressing. E Lift heavy components only at designated lifting points. F Handle materials and equipment in accordance with Manufacturer's recommendations. G Do not drop, roll, or skid products off delivery vehicles. Hand carry or use suitable materials handling equipment. 1.07 STORAGE OF MATERIAL A Store and protect materials in accordance with manufacturer's recommendations and requirements of these Technical Specifications. Control storage of potential water pollutants in conformance with Section 01566 — Source Controls for Erosion & Sedimentation. B Make necessary provisions for safe storage of materials and equipment. Place loose soil materials,and materials to be incorporated into the Work to prevent damage to any part of the Work or existing facilities and to maintain free access at all times to all parts of the Work and to utility service company installations in the vicinity of the Work. 07/2006 01600-2 of 3 CITY OF PEARLAND MATERIAL AND EQUIPMENT C Keep materials and equipment neatly and compactly stored in locations that will cause a minimum of inconvenience to other contractors, public travel, adjoining owners, tenants, and occupants. Arrange storage in a manner to provide easy access for inspection. D Provide adequately ventilated, watertight storage facilities with floor above ground level for materials and equipment susceptible to weather damage. E Restrict storage to areas available on the construction site for storage of material and equipment as shown on Plans or approved by the Project Manager. F Provide off-site storage and protection when on-site storage is not adequate. G Do not use lawns, grass plots, or other private property for storage purposes without written permission of the owner or other person in possession or control of such premises. Damage to lawns,sidewalks,streets or other improvements shall be repaired or replaced to the satisfaction of the Project Manager. H Protect stored materials and equipment against loss or damage. I Store materials in manufacturers'unopened containers. J Materials delivered and stored along the line of the Work shall be not closer than 3 feet to any fire hydrant. Public and private drives and street crossings shall be kept open. K The total length which materials may be distributed along the route of construction at any one time is 1000 lineal feet, unless otherwise approved in writing by the Project Manager. 2.0 P R O D U C TS - Not Used 3.0 EXECUTION - NotUsed END OF SECTION 07/2006 01600-3 of 3 CITY OF PEARLAND TECHNICAL SPECIFICATIONS DIVISION 2 r TECHNICAL SPECIFICATIONS r DIVISION 2 SITE WORK r 07/2006 CITY OF PEARLAND CONTRACT CLOSEOUT Section 01770 CONTRACT CLOSEOUT 1.0 GENERAL 1.01 SECTION INCLUDES A Closeout procedures including final submittals such as operation and maintenance data, warranties, and spare parts and maintenance materials. B References to Technical Specifications: 1. Section 01350—Submittals 2. Section 01760—Project Record Documents 1.02 MEASUREMENT AND PAYMENT A Unless indicated as a Bid Item,no separate payment will be made for Work performed under this Section. Include cost in Bid Items for which this Work is a component. 1.03 SUBMITTALS A Make Submittals required by this Section under the provisions of Section 013.50 — Submittals. 1.04 CLOSEOUT PROCEDURES A Comply with Section 00700 — General Conditions of Agreement regarding Final Completion and Final Payment when Work is complete and ready for Engineer's final inspection. B Provide Record Documents under provisions of Section 01760 — Project Record Documents. C Complete or correct items on punch list,with no new items added. Any new items will be addressed during warranty period. D The Owner will occupy portions of the Work as specified in Section 00700—General Conditions of Agreement. E Contractor shall request Final Inspection at least two weeks prior to Final Acceptance. 1.05 FINAL CLEANING A Execute final cleaning prior to final inspection. B Clean debris from drainage systems. C Clean Project Site; sweep paved areas, rake clean landscaped surfaces. 09/2009 01770- 1 of 2 CITY OF PEARLAND CONTRACT CLOSEOUT D Remove waste and surplus materials, rubbish, and temporary construction facilities from the Project Site following the final test of utilities and completion of the Work. 1.06 OPERATION AND MAINTENANCE DATA A Submit Operations and Maintenance data under provisions of Section 01350 — Submittals. 1.07 WARRANTIES A Provide one original of each warranty from Subcontractors, Suppliers, and Manufacturers. B Provide Table of Contents and assemble warranties in 3-ring/D binder with durable plastic cover. C Submit warranties prior to Final Application for Payment. 1. Warranties shall commence in accordance with the requirements of Section 00700—General Conditions of Agreement, 1.09 "Substantially Completed". 2.0 PRODUCTS - Not Used 3.0 EXECUTION Contractor shall diligently pursue completion of the items and activities contained in the Contract Close Out and Project Record Document sections of the project manual. Notwithstanding any performance of warranty work, the work of Contract Closeout shall be complete within thirty (30) days of the date of Final Completion and Acceptance of the work. END OF SECTION 09/2009 01770-2 of 2 CLEANING AND SEALING PAVEMENT Special Specification JOINTS AND CRACKS SECTION 02781 CLEANING AND SEALING PAVEMENT JOINTS AND CRACKS PART1 GENERAL 1.01 SECTION INCLUDES A. Cleaning and sealing of joints and cracks in portland cement concrete pavement and asphaltic concrete pavement. 1.02 MEASUREMENT AND PAYMENT A. Measurement for cleaning and sealing of pavement joints and cracks is on linear foot basis. Separate measurement will be made for each different joint type as noted in the bid proposal. B. Payment includes all labor and materials required to perform the joint and crack sealing, including routing, cleaning, furnishing and placing materials, and all necessary tools and equipment. Mobilization and traffic control as needed to facilitate the joint and crack sealing operations will not be paid for separately, but the cost thereof shall be included in the unit price bid for related items. C. Refer to Section 01200—Measurement and Payment Procedures. 1.03 SUBMITTALS A. Make Submittals required by this Section under the provisions of Section 01350 — Submittals. B. Submit product data for joint sealing compound and proposed sealing equipment for approval. PART2 PRODUCTS 2.01 MATERIALS A. Hot poured rubber-asphalt compound meeting the requirements of ASTM D6690. B. When indicated on Plans or if directed by the Engineer,provide self-leveling low-modulus silicone sealant, single component, meeting the requirements of TxDOT DMS-6310 Joint Sealants and Fillers, Class 5. C. Backer rod shall be closed cell type suitable for hot applied sealants and shall comply with requirements of ASTM D5249. D. The sealant material shall be delivered in the manufacturer's original sealed container with labels clearly identifying the product name and manufacturer. 08/2018 02781-1 CLEANING AND SEALING PAVEMENT Special Specification JOINTS AND CRACKS 2.02 EQUIPMENT A. Heat in a double jacketed heater using a heat transfer oil so no direct flame comes in contact with the shell of the vessel containing the sealing compound. Provide a heater capable of circulating and agitating the sealant during the heating process to achieve a uniform temperature rise and maintain the desired temperature. Provide gauges to monitor the temperature of the vessel contents and avoid overheating the material. Provide a heater equipped with a gear-driven asphalt pump with adequate pressure to dispense the sealant. PART3 EXECUTION 3.01 PREPERATION A. Immediately before applying sealant, the joints and cracks shall be cleaned of loose and foreign material to a depth approximately twice the joint or crack width. Clean joints and cracks with air blasting equipment or other acceptable method. B. Joints and cracks must be free of moisture before sealing. C. Do not place sealant when the pavement temperature is below 40°F. D. Apply primer when required by the sealant manufacturer. 3.02 APPLICATION A. After cleaning and preparation, apply sealant material with a pressure nozzle in accordance with the manufacturer's recommended procedure. B. Completely fill joints and cracks flush with the pavement surface. Excess sealant shall be leveled off at the wearing surface by squeegee. The squeegeed material shall be centered on the joint or crack and shall not exceed 3 inches in width. END OF SECTION 08/2018 02781-2 City of Pearland 2018 Joint and Crack Sealing Project APPENDIX ARKK Job No. 18-038 List of Concrete Streets Priority No. Street No. Street Name 1 Cunningham Dr. 2 Romayor Ct. 3 Anthony Dr. 4 Goodrich Dr. 5 Rose St. 6 Francis Dr. 7 Halbert Dr. 8 Lynn Dr. 9 W. Plum St. 10 Willow Blvd. 11 Cedar St. 12 W. Jasmine St. 13 Bunkerhill Ct. 14 Corrigan Dr. 15 Camden Ln. 1 16 Carmona Ln. 17 Apple Springs Dr. 18 Leggett Ln. 19 Rockland Dr. 20 Trinity Dr. 21 Groveton Ln. 22 Woodville In. 23 Colmesneil Dr. 24 Livinsgston Dr. 25 Leggett Ln. 26 Neches River Dr. 27 Chester Dr. 28 Silsbee Dr. 29 Village Mills Dr. 30 Holly Springs Dr. 31 Julie Ann Dr. 32 Walnut Bend Blvd. 33 Country Club Dr. 34 Green Tee Dr. 35 Price Cir. 2 36 Champion Dr. 37 Fairway Cir. 38 Cork Cir. 39 Golfcrest Dr. 40 EaglesWay List of Concrete Streets Priority No. Street No. Street Name 41 Limrick Dr. 42 Kildare Dr. 43 Birdie Ct. 44 Tipperary Dr. 45 Wicklow Dr. 2 46 Londonderry Dr. 47 Kilkenny Dr. 48 Caloway Cir. 49 Sleepy Hollow Dr. 50 Rip Van Winkle Dr. 51 Washington Irving Dr. 52 N. Peach Hollow Cir. 53 Laurel Grove Ln. 54 Poplar Creek Ln. 55 S. Peach Hollow Cir. 56 W. Country Grove Cir. 57 E. Country Grove Cir. 58 W. Primrose Meadows Cir. 59 S. Primrose Meadows Or. 60 E. Primrose Meadows Cir. 61 Andover Dr. 3 62 E. Belgravia Dr. 63 E. Brompton Dr. 64 Woodridge Ave. 65 Helmsley Dr. 66 Windemere Dr. 67 Sherborne St. 68 Margate Dr. 69 Southdown Dr. 70 Wentworth Dr. 71 Canterbury Dr. 72 Sheldon Dr. 73 Portsmouth Dr. 74 Spring Forest Dr. 75 Springfield Ave. 76 Spring Crest Ct. 4 77 Spring Grove Ct. 78 Cedarwood Dr. 79 Beechwood Dr. 80 Ashwood Dr. List of Concrete Streets Priority No. Street No. Street Name 81 Heritage Green Dr. 82 Eton Dr. 83 Tower Bridge Ct. 84 Waterloo Rd. 85 E. Walnut St. 5 86 Stratford St. 87 Churchill St. 88 Nottingham Rd. 89 Creeks Edge Dr. 90 Clay Creek Ct. 91 Marble Creek Dr. 92 Helen Ln. 93 Dorothy Ln. 94 Shadybend Dr. 95 Laura Ln. 6 96 Misty Ln. 97 Colleen Dr. 98 Parkview Dr. 99 Marys Creek Ct. 100 Heather Ln. 101 Yost Blvd 102 Hamm Rd. 103 Woodcreek Dr. 104 Cripple Creek Ln. 7 105 Lazy Creek Ln. 106 Live Oak hollow St. 107 Pecan hollow St. 108 Dixie hollow Dt. 109 Sleepy Hollow Dr. 110 Cypress Hollow St. 111 Pine Ridge Ln. 112 Pine Tree Dr. 113 Pine Forest Dr. 114 Pine Lake Dr. 8 115 Shauntel St. 116 Hazel St. 117 Riverside Dr. 118 Merribr000k Ln. 119 Lochmoore Ln. 120 Chelsea Ln. List of Concrete Streets Priority No. Street No. Street Name 8 121 Linkwood Dr. 122 Chesterwood Dr. 123 Hickory Creek Dr. 9 124 Glastonbury Dr. 125 Barkly Ct. List of Asphalt Streets Segment No. Street Name From Street To Street 1 LEE LN COLONIAL DR NORTH END 2 WAGON TRAIL RD OCHOA RD CANTU RD 3 BROOKSIDE RD STONE RD N SUNBROOK DR 4 WAGON TRAIL RD SOUTH END FIGLAND ST 5 FITE RD CR 298 CR 389 6 HERBERT DR WILLIAMS ST EAST END 7 E WALNUT ST OLD ALVIN RD BARRY ROSE RD 8 GARDENIA ST LAZY BEND ST THELMA DR 9 CONFEDERATE DR WEST END LEE LN 10 GARDENIA ST GARDEN RD LAZY BEND ST 11 MAX RD BROADWAY ST REID BLVD 12 PECOS ST SCOTT LN COMAL ST 13 ODAY RD RICE RD HICKORY HOLLOW DR 14 MEADOWLARK WAY MOCKINGBIRD LN WEST LEA LN 15 KEIS RD WELLS DR EAST END 16 SKYLARK WAY WEST LEA LN MEADOW LN 17 CUNNINGHAM DR PEAR ST CHERRY ST 18 CAMELOTS CT MILLER RANCH RD AVILION CT 19 MCLEAN RD BAILEY RD VILLAGE CREEK DR 20 HERON LN WINGTAIL WAY MEADOWLARK WAY 21 LEE LN CONFEDERATE DR COLONIAL DR 22 CAMELOTS CT AVILION CT EAST END 23 SHADYBEND DR W CIRCLE DR E CIRCLE DR 24 W JASMINE ST N SAN ANTONIO AVE N WASHINGTON AVE 25 MEADOWLARK WAY WEST LEA LN MEADOW LN 26 WARREN RD WILLIAMS ST EAST END 27 FITE RD HARKEY RD WAGON TRAIL RD 28 BLUEBIRD WAY WEST LEA LN MEADOW LN 29 MOCKINGBIRD LN WINGTAIL WAY MEADOWLARK WAY 30 MOCKINGBIRD LN MEADOWLARK WAY BLUEBIRD WAY 31 ROY RD SHARON DR GREEN HILL RD 32 SCOTT LN WILKE RD WOODY RD 33 VETERANS DR STONEBRIDGE DR MAGNOLIA RD 34 VETERANS DR ELAINE WAY STONEBRIDGE DR 35 WOODY RD SCOTT LN COMAL ST 36 HARKEY RD FIGLAND ST FITE RD 37 HARKEY RD OLD OAKS BLVD FIGLAND ST 38 WAGON TRAIL RD BARDET ST OCHOA RD 39 N AUSTIN AVE W PLUM ST W ORANGE ST 40 LEE LN SOUTH END CONFEDERATE DR 41 STERLING DR WEST END BROOKNEY ST 42 FITE RD CULLEN PKWY MEADOWHURST DR 43 HAMM RD BROADWAY ST LAZY CREEK LN 44 W PEAR ST S PEARLAND AVE S SAN ANTONIO AVE 45 LYNN DR BROADWAY ST PEAR ST 46 W WALNUT ST BROADWAY ST MCLEAN RD 47 BECKY LN HARKEY RD WAGON TRAIL RD 48 ROY RD W CLIFF STONE RD ROY RD 49 MEADOW LN SKYLARK WAY WINGTAIL WAY List of Asphalt Streets Segment No. Street Name From Street To Street 50 ROY RD ROY RD ROBIN SOUND ST 51 E WALNUT ST S HOUSTON AVE S GRAND BLVD 52 LIBERTY DR LAURA LN SHADYBEND DR 53 ROY RD ROBIN SOUND ST SHARON DR 54 WINGTAIL WAY WEST LEA LN MEADOW LN 55 LIBERTY DR COLEEN DR LAURA LN 56 UNION VALLEY DR TRELAWNEY DR MEADOWVILLE DR 57 WAGON TRAIL RD LARRYCREST DR JERRYCREST DR 58 CHERRY ST PEACH CT N AUSTIN AVE 59 E MARYS CREEK LN LONGHERRIDGE DR SE END 60 WAGON TRAIL RD PATRIDGE DR LARRYCREST DR 61 SHADYBEND DR E CIRCLE DR SHADYCREST DR 62 WOODY RD RICE RD SCOTT LN 63 GARDENIA ST THELMA DR ODAY RD 64 W WALNUT ST S PEARLAND AVE S SAN ANTONIO AVE 65 S GRAND BLVD E PEAR ST N GRAND BLVD 66 MCLEAN RD SILSBEE DR W WALNUT ST 67 WELLS DR HERBERT DR WARREN RD 68 MCLEAN RD W WALNUT ST HALBERT DR 69 AUBRELL RD COTTONWOOD ST PATRIDGE DR 70 JERRYCREST DR HARKEY RD WAGON TRAIL RD 71 VETERANS DR SPRINGFIELD AVE BARRINGTON WAY 72 WESTCHESTER CIR BROADWAY ST MANVEL RD 73 E PEAR ST S HOUSTON AVE S GRAND BLVD 74 SONGBIRD PL SONGBIRD DR NORTH END 75 E PLUM ST BRIAR CIR BRIAR CIR 76 OLD ALVIN RD SHADY GATE LN OLD ALVIN RD 77 S PEARLAND AVE W WALNUT ST W PEAR ST 78 PATRIDGE DR HARKEY RD WAGON TRAIL RD 79 WEST LEA LN MEADOWLARK WAY BLUEBIRD WAY 80 STONE RD N LONGLEAF DR BROOKSIDE RD 81 BECKY LN WAGON TRAIL RD SONGBIRD PL 82 THELMA DR BROADWAY ST GARDENIA ST 83 E PEAR ST MAIN ST WEST END 84 COTTONWOOD ST AUBRELL RD EAST END 85 MILLER RANCH RD KING AUTHORS CT W HAMPTON DR 86 W JASMINE ST N WASHINGTON AVE N TEXAS AVE 87 ETHEL ST WEST END HELEN LN 88 WOODY RD BROADWAY ST PEAR ST 89 CHECKERBERRY LN SHADYCREST DR LONGHERRIDGE DR 90 E PLUM ST OLD ALVIN RD BRIAR CIR 91 MEADOW LN BLUEBIRD WAY EAST END 92 N GRAND BLVD S GRAND BLVD E JASMINE ST 93 LONGHERRIDGE DR W MARYS CREEK LN E MARYS CREEK LN 94 WEST LEA LN WINGTAIL WAY MEADOWLARK WAY 95 MILLER RANCH RD EXCALIBURS CT KING AUTHORS CT 96 E CIRCLE DR SHADYBEND DR BROADWAY ST 97 WINGTAIL WAY MOCKINGBIRD LN WEST LEA LN I 98 N PEARLAND AVE CHERRY ST W JASMINE ST List of Asphalt Streets Segment No. Street Name From Street To Street 99 N AUSTIN AVE S AUSTIN AVE CHERRY ST 100 W PEAR ST S SAN ANTONIO AVE S WASHINGTON AVE 101 LEE RD HUGHES RANCH RD NORTH END 102 MOCKINGBIRD LN BLUEBIRD WAY EAST END 103 W MARYS CREEK LN SHADYCREST DR LONGHERRIDGE DR 104 MCLEAN RD MAGNOLIA RD RYAN ACRES DR 105 WOODY RD COMAL ST CITY LIMIT 106 W PEAR ST S TEXAS AVE S SACRAMENTO ST 107 MILLER RANCH RD W HAMPTON DR HUGHES RANCH RD 108 S SACRAMENTO ST E WALNUT ST W PEAR ST 109 CHERRY ST N AUSTIN AVE N PEARLAND AVE 110 MOCKINGBIRD LN SKYLARK WAY WINGTAIL WAY 111 W JASMINE ST N AUSTIN AVE N PEARLAND AVE 112 CR 130 CR 430 CR 130 113 WOODY RD SOUTH END RICE RD 114 LAKE EDGE DR LONGHERRIDGE DR SE END 115 S PEARLAND AVE W PEAR ST BROADWAY ST 116 WAGON TRAIL RD CANTU RD JOSEPHINE ST 117 W MARYS CREEK LN NW END SHADYCREST DR 118 DEE RD ODAY RD EAST END 119 TERRELL DR WEST END HARKEY RD 120 ORANGE CIR S MYKAWA RD ORANGE CIR E 121 SKYLARK WAY MOCKINGBIRD LN W MOCKINGBIRD LN 122 WOOTEN RD BROADWAY ST LAMB BROOK 123 KNAPP RD BOBBY ST UNION VALLEY DR 124 S GRAND BLVD E WALNUT ST E PEAR ST 125 HERON LN BLUEBIRD WAY EAST END 126 CHERRY ST FRANCIS DR WILLOW BLVD 127 HATFIELD RD CARMONA LN BROADWAY ST 128 SKYLARK WAY HERON LN MOCKINGBIRD LN 129 S AUSTIN AVE RAY ST W PEAR ST 130 ROBIN SPUR ROBIN MEADOW ST ROBIN SOUND ST 131 CUNNINGHAM DR BROADWAY ST PEAR ST 132 HERON LN MEADOWLARK WAY BLUEBIRD WAY 133 WESTFIELD LN DIXIE FARM RD BUCKHOLT ST 134 5 AUSTIN AVE W PEAR ST N AUSTIN AVE 135 W JASMINE ST N PEARLAND AVE N SAN ANTONIO AVE 136 MCLEAN RD VILLAGE CREEK DR SPRINGFIELD AVE 137 MAX RD W CLIFF STONE RD CR 560 138 W PLUM ST N PEARLAND AVE N SAN ANTONIO AVE 139 COUNTRY CLUB DR PROVINCE VILLAGE DR GREEN TEE DR 140 WEST LEA LN BLUEBIRD WAY EAST END