R2017-162 2017-08-14 RESOLUTION NO. R2017-162
A Resolution of The City Council of the City of Pearland,Texas,authorizing
the City Manager or his designee to participate in an interlocal cooperative
pricing arrangement through the Texas Association of School Boards
(TASB) Buy Board for the purchase of a shade structure for the Sports
Complex at Shadow Creek Ranch, in the amount of$158,598.00.
BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF PEARLAND, TEXAS:
Section 1. That contract pricing has been obtained through interlocal cooperative partner
Texas Association of School Boards(TASB) Buy Board for the purchase of a shade structure for the
Sports Complex at Shadow Creek Ranch, in the amount of$158,598.00.
Section 2. That the City Manager or his designee is hereby authorized to participate in an
interlocal cooperative pricing arrangement with the Texas Association of School Boards(TASB) Buy
Board for the purchase of a shade structure for the Sports Complex at Shadow Creek Ranch, in the
amount of$158,598.00.
PASSED, APPROVED and ADOPTED this the 14th day of August, A.D., 2017.
/".? -t
TOM REID
MAYOR
ATTEST:
•, N 6 IN I .,
• TY :`CRETA-Y /\ .
APPROVED AS TO FORM:
Au__
DARRIN M. COKER
CITY ATTORNEY
USASHADE
& Fabric Structures®
Sports
Complex
Shade
Structures
July 14, 2017
Proposal Prepared For: City of
Pearland
AZ:289388 CA:989458 LA:61718 NV:78724
NM:383826 TN:68712 DIR: 1000003533
www.usa-shade.com I 800-966-500 5
USASHADE
& Fabric Structures.
Date:
BUYBOARD Proposal for USA SHADE & Fabric Structures #512-16
Project Information: Sales Information:
Purchaser: City of Pearland Contact: Chrystopher Bickham Sales Rep: Jared Angelica
Project Name: Sports Complex Shades Phone: 713.703.2631 Phone: 13-254-8861
JFA 108263 CBickham @pearlandtx.gov areda @usa-shade.com
Quote No: Email: Email:
PO No: N/A Fax: Fax: 14-905-9514
Billing Information: Shipping Information: lobsite Information:
City of Pearland Shadow Creek Sports Complex Shadow Creek Sports Complex
TBD 13050 Shadow Creek Pkwy 13050 Shadow Creek Pkwy
Pearland,TX 77584 Houston,TX 77584 Houston,TX 77584
Contact: Contact: Contact:
Phone Phone Phone
Fax: Fax: Fax:
Email: Email: Email:
CORPORATE ADDRESS: REMITTANCE ADDRESS:
8505 Chancellor Row P.O. Box 204691
Dallas,TX 75247-5519 Dallas, TX 75230-4691
SOUTHERN CALIFORNIA: NORTHERN CALIFORNIA: ARIZONA: LAS VEGAS:
1085 N.Main Street,Suite C 927 Enterprise Way,Suite A 2452 W.BirchwoodAve,Suite 112 6225 S.Valley View Blvd.,Suite
Orange,CA 92867 Napa,CA 94558 Mesa,AZ85202 Las Vegas,NV 89118
NOTE:This message is intended only for the use of the individual to whom it is addressed, and contains information that is
privileged,confidential,and exempt from disclosure under applicable law. If you are not the intended recipient,or the employee
or agent responsible for delivering this message to the intended recipient,you are hereby notified that any unauthorized
disclosure,distribution,or copying of this communication is strictly prohibited. If you have received this communication in error,
please notify us immediately by phone and return the original message to the applicable address above.
www.usa-shade.com 800-966-5005
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533
USASHADE
& Fabric Structures.
Structure Pricing
UNIT IMAGE UNIT DETAILS
Unit Quantity: 2 Base Attachment: N/A
:' Unit Type: Standard Octagon Footing Type: Recessed baseplate
, fr Structure Size: 65' Diameter Anchor Bolts: YES
Entry Height: 10 Concrete Cutting: NO
No of Columns: 8 Dirt Removal: YES
1.^. No of Fabric Tops: 1 NOTES
_{ ) I Fabric Type: Shadesure
I ', f :..;.V T i . ' Fabric Color: TBD
N.I j- Steel Finish: Powder coat
Steel Color: TBD
PRICE Electrical Provisions: N/A
Cable/HDW Finish: N/A
SEE BELOW
Concept No:
ADDITIONAL COSTS
QTY ITEM DETAILS COST
TOTAL FOR ACCESS/MISC ITEMS: $0.00
PRICINGTOTALS: PAYMENT TERMS:
Units Total INCLUDED (1) Upon execution of the Agreement(Deposit)
Accessories/Miscellaneous $0.00 (2) Upon delivery of Unit(s)
Shipping/Handling INCLUDED (3) Upon completion of assembly/installation Net 30
SUBTOTAL $0.00 (4) Other(specify):
Sales Tax(8.25%) Tax Exempt NOTES:
Installation INCLUDED .
TOTAL PRICE $158,598.00
USASHADE
& Fabric Structures.
ENGINEERING REQUIREMENTS NOTES
Building Code
Wind Load
Snow Load
Drawing Size
No.of Sealed Drawings Q
Calculations Required YES NO
INCLUSIONS/ EXCLUSIONS
INCLUDED EXCLUDED I ENGINEERING REQUIREMENTS INCLUDED I EXCLUDED INSTALLATION - MISCELLANEOUS
X Sealed Drawings&Calculations X Prevailing Wage/Certified Payroll
X Permit Submittal X Union Wages
X Permit Fee X Fencing
X DSASubmittal X Curb Repair
X DSA Fee X Landscape Repair
X Foundation Design&Engineering X Demolition(Existing Structures)
X Special Inspection Fees X Payment and Performance Bonds
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533
USASHADE
& Fabric Structures.
Construction Assumptions
1) The designated area for our structures will be accessible by drive-up for unloading of our trucks and equipment,including personnel man-
lifts,forklifts,etc. Should a crane be required and direct access not available,additional costs for such will be submitted by a Change Order.
2) Our pricing is based on the ability to perform all of our work with clear,sequential,and continuous access without interruption during
normal daytime working hours. We have assumed one mobilization for the installation of foundations,steel and fabric;if additional mobilizations
are required,there will be an additional charge. We will require exclusive access to the area for our work during the construction process.
3) Our pricing does not include daily site delays accessing the work areas. USA SHADE will submit a Change Order for any delays caused by other
trades which interfere or cause us to stop working.
4) Pricing assumes secure storage and adequate lay down area for our tools,equipment,and materials,within close proximity to the installation
site will be provided,free of charge.
5) Our price assumes others to provide 200-amp,110-volt electrical service and necessary potable water available within 100 feet of our work.
6) We will require site sanitary facilities and refuse containers by others within 200 feet of ourwork.
7) USA SHADE will leave its work and materials in a clean condition at the conclusion of our work.
8) Barricades and public security requirements are not included.
9) Unless specifically included in this proposal,this agreement does not include,and Company will not provide,services,labor,or materials for
any of the following work:(a)removal and disposal of any materials containing asbestos or any hazardous materials as defined by the EPA;(b)
moving Owner's property around the installation site;(c)repair or replacement of any Purchaser or Owner-supplied materials;or(d)repair of
damage to existing surfaces that may occur when construction equipment and vehicles are being used in the normal course of construction.
10) Pricing for foundation design is based on drilled pier footings. In the event the geotechnical report requires an alternate configuration,any
additional costs incurred will be submitted to the client by a Change Order.
11) Digging of our foundations will not be constrained by any existing concrete or utilities. USA SHADE will not be responsible for moving or
repairing any underground utility lines such as electrical,telephone,gas,water,or sprinkler lines that may be encountered during installation.
12) Any additional costs incurred as a result of hard rock conditions requiring extra equipment,utility removal or repair, resulting in delay,will
result in additional charges unless they are detailed on as-built site drawings provided to USA SHADE or marked on the ground and
communicated to USA SHADE in writing prior to installation.
GENERAL TERMS & CONDITIONS AND WARRANTY
1) Proposal:The above proposal is valid for 30 days from the date first set forth above. After 30 days,we reserve the right to increase prices due to the
rise in cost of raw materials,fuel,or other cost increases. When applicable,USA SHADE&Fabric Structures reserves the right to implement a surcharge
for significant increases in raw materials,including,but not limited to;fuel,steel,and concrete. Due to the duration of time between proposals,
contracts,and final installation,USA SHADE&Fabric Structures reserves the right to implement this surcharge,when applicable.
2) Purchase:By executing this proposal,or submitting a purchase order pursuant to this proposal(which shall incorporate the terms of this agreement
specifically by reference)which is accepted by USA SHADE&Fabric Structures(the"Company"),the purchaser identified above("you"or the
"Purchaser")agrees to purchase Shade Structures brand shade structures("Structures")and the services to be provided by the Company,as detailed in
the"Structure Pricing"and"General Scope of Work"sections of this agreement,above,or in the relevant purchase order accepted by the Company,for
use by Purchaser or for installation by Company or Purchaser on behalf of a third-party who will be the ultimate owner of the Structures(the ultimate
owner of a Structure,whether Purchaser or a third-party,being the"Owner").
3) Short Ship Claims:Purchaser has 15 days from receipt of the structures to file a short ship report in writing to its sales representative. Company will not
honor claims made after this time.
4) Standard Exclusions:Unless specifically included under the"General Scope of Work"section above,this agreement does not include,and Company will
not provide,services,labor,or materials for any of the following work:(a)removal and disposal of any materials containing asbestos or any hazardous
materials as defined by the EPA;(b)moving Owner's property around the installation site;(c)repair or replacement of any Purchaser or Owner-supplied
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533
USASHADE
& Fabric structures.
materials;(d)repair of concealed underground utilities not located on prints supplied to Company by Owner during the bidding process,or physically
staked out by Owner,and which are damaged during construction;or(e)repair of damage to existing surfaces that may occur when construction
equipment and vehicles are being used in the normal course of construction.
5) Bonding Guidelines:If Purchaser will use or provide the Structures and Services for an Owner other than Purchaser(including,without limitation,as a
subcontractor of Purchaser),Purchaser will include the following statement in Purchaser's contract with Owner:
"The manufacturer's warranty for the Shade Structures brand shade structures is a separate document between USA SHADE&
Fabric Structures and the ultimate owner of the Shade Structures brand shade structures,which will be provided to the ultimate
owner at the time of completion of the installation and other services to be provided by USA SHADE&Fabric Structures. Due to
surety requirements,any performance and/or payment bond will cover only the first year of the USA SHADE&Fabric Structures
warranty."
6) Insurance Requirements:Company is not required to provide any insurance coverage in excess of Company's standard insurance. A copy of the
Company's standard insurance is available for your review prior to acceptance of the Company's proposal.
7) Payment:Terms of payment are defined in the"Pricing Details"section and are specific to this contract. For purposes of this agreement,"Completion"
is defined as being the point at which the Structure is suitable for its intended use,the issue of occupancy consent,or a final building department
approval is issued,whichever occurs first. In any event where Completion cannot be effected due to delays or postponements caused by the Purchaser
or Owner,final payment(less 10%retainage)is due within 30 days of the date when Completion was scheduled,had the delay not occurred. All
payments must be made to Shade Structures,Inc., P.O.Box 204691,Dallas,TX 75320-4691. If the Purchaser or Owner fails or delays in making any
scheduled milestone payments,the Company may suspend the fulfillment of its obligations hereunder until such payments are made,or Company may
be relieved of its obligations hereunder if payment is more than 60 days past due. Company may use all remedies available to it under current laws
including,but not limited to,filing of liens against the property and using a collection agency or the courts to secure the collection of the outstanding
debt.
8) Lien Releases:Upon request by Owner,Company will issue appropriate partial lien releases as corresponding payments are received from Purchaser,
but prior to receiving final payment from Purchaser or Owner. Company will provide a full release of liens upon receipt of final payment. In accordance
with state laws,Company reserves the right to place a lien on the property if final payment has not been received 10 days prior to the filing deadline for
liens.
• 9) Site Plan Approval,Permit/s,Permit Fees,Plans,Engineering Drawings,and Surveying:Site plan approval,permits,permit fees,plans,engineering
drawings,and surveying are specifically excluded from this agreement and the Services unless specified under the"General Scope of Work". The
Company does not in any way warrant or represent that a permit or site plan approval for construction will be obtained. Sealed engineered drawings
that are required but not included in the"General Scope of Work"will result in an additional cost to Purchaser.
10) Manufacturing&Delivery: Manufacturing lead-time from Company's receipt of the"Notice To Proceed"is approximately 6 to 8 weeks for standard
structures,and 8 to 12 weeks for custom structures. Delivery is approximately 1 week thereafter. Delivery of structures may be prior to or at start of
assembly. Please note that these timelines do not include approval or permitting timeframes.
11) Returned Product,Deposits,and/or Cancelled Order: Within the first 45 days after shipment from our facility,all returned product(s)and cancelled
orders are subject to a 50%restocking fee. No returns are available following this 45 day period. All deposits are non-refundable. All expenses incurred
(engineering,site surveys,shipping,handling,etc.)are the responsibility of the Purchaser,up to notice of cancellation.
12) Concealed Conditions:"Concealed conditions"include,without limitation,water,gas,sprinkler,electrical and sewage lines,post tension cables,and
steel rebar. This agreement is based solely on observations the Company was able to make either by visual inspection or by drawings and/or plans
submitted by Owner at the time this agreement was bid. If additional Concealed Conditions are discovered once work has commenced,which were not
visible at the time this proposal was bid,Company will stop work and indicate these unforeseen Concealed Conditions to Purchaser or Owner so that
Purchaser and Company can execute a Change Order for any additional work. In any event,any damage caused by or to unforeseen Concealed
Conditions is the sole responsibility of the Purchaser and Company shall not be held liable for any such damage. Soil conditions are assumed to be soil
that does not contain any water,hard rock(such as limestone,caliche,etc.),rocks larger than 4 inches in diameter,or any other condition that will
require additional labor,equipment and/or materials not specified by the Purchaser or Owner in the bidding process. Any condition requiring additional
labor,equipment,and/or materials to complete the drilling or concrete operations will require a Change Order before Company will complete the
process. Price quotes are based on a drilled pier footing. Any variation will incur additional charges(i.e.spread footings,concrete mat,sand,water,
landfill,etc.). Costs for footing and installation do not include any allowance for extending below frost lines(the additional costs for which vary by
geographical region).
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 D IR:1000003533
USASHADE
a Fabric structures.
13) Changes in the Work:During the course of this project,Purchaser may order changes in the work(both additions and deletions). The cost of these
changes will be determined by the Company,and a Change Order form must be completed and signed by both the Purchaser and the Company,which
will detail the"General Scope of the Change Order". Should any Change Order be essential to the completion of the project,and the Purchaser refuses
to authorize such Change Order,then Company will be deemed to have performed its part of the project,and the project and services will be
terminated. Upon such termination,Company will submit a final billing to Purchaser for payment,less a labor allowance for work not performed but
including additional charges incurred due to the stoppage. No credit will be allowed for materials sold and supplied,which will remain the property of
the Purchaser.
14) Indemnification: To the fullest extent permitted by law,Purchaser shall indemnify,defend,and hold harmless the Company and its consultants,agents,
and employees or any of them from and against claims,damages,losses and expenses,including,but not limited to,attorneys'fees related to the
installation of the Structure or performance of the services,provided that such claim,damage,loss,or expense is attributable to bodily injury to,
sickness,disease,or death of a person,or to injury to or destruction of tangible property,but only to the extent caused by the negligent acts or
omissions of the Purchaser or its agents,employees,or subcontractors,or anyone directly or indirectly employed by them or anyone for whose acts
they may be liable,regardless of whether or not such claim,damage,loss,or expense is caused in part by a party indemnified hereunder. Such
obligation shall not be construed to negate,abridge,or reduce other rights or obligations of indemnity that would otherwise exist as to a party or
person described in Section 15.
15) Statement of Limited Warranty:
• The structural integrity of all supplied steel is warranted for ten years.
• If assembly is provided by the Company,workmanship of the structure is covered for one year,including labor for the removal of any failed part,
disassembly(if necessary),cost of shipping,and reassembly.
• All steel surface finishes are warranted for one year.
• Shadesure'",Colourshade®FR, eXtreme 32'"",Commercial 95"",SaFRshade',and Monotec 370'"fabrics all carry a ten year limited manufacturer's
warranty against failure from significant fading,deterioration,breakdown,outdoor heat,cold,or discoloration. Should the fabric need to be replaced
under the warranty,the Company will manufacture and ship a new replacement fabric at no charge for the first six years,thereafter pro-rated at 20%
per year over the remaining four years. The following are exceptions to the preceding warranty terms:
o Shadesure'"fabrics in Red,Yellow,Atomic Orange,Electric Purple,Zesty Lime,Cinnamon,Olive,and Mulberry carry a five year pro-rated
warranty;
o Fabric tops attached to Coolbrellae'structures carry a three year warranty;
o Individual fabric tops measuring greater than 40'in length are covered by a non-prorated five year warranty;
o Precontraint 502'"waterproof membrane is subject to an eight year pro-rated warranty.
• Sewing thread is warranted for ten years.
General Limited Warranty Terms and Conditions
• These limited warranties are effective from the date of sale,or,if assembly is provided by the Company,upon receipt by Company from Purchaser of a
completed and signed"Customer Checklist and Sign-off"form.
• In its sole discretion,the Company will repair and or/replace defective structures,products or workmanship,or refund that portion of the price related
to the defective product,labor,or service rendered.
• The Company reserves the right,in cases where certain fabric colors have been discontinued,to offer the Purchaser or Owner a choice of available
alternative colors to replace the warranted fabric. The Company does not guarantee that any particular color will be available for any period of time,and
reserves the right to discontinue any color for any reason,without recourse by the Purchaser or Owner of the discontinued fabric color.
• Should the Purchaser or Owner sell the structures to another party,the warranty cannot be transferred to the new owner without a complete and
thorough on-site inspection performed by a Company representative. Please contact the Company at warranty @usa-shade.com for more details.
• All warranty claims covering Company supplied structures,products,and services must be submitted by Purchaser or Owner in writing to the Company
within thirty days from the date of discovery of the alleged defect and must include a detailed description and applicable photographs of the alleged defect
or problem. Warranty claims should be submitted by email to warranty @usa-shade.com.
• Purchaser or Owner agrees that venue for any court action to enforce these limited warranties shall be in the City or County of Dallas in the State of
Texas,USA.
• These limited warranties are void if:
o the supplied structures,products,services and/or labor are not paid for in full;
o the structures are not assembled in strict compliance with USA SHADE specifications;
o any changes,modifications,additions,or attachments are made to the structures in any way,without prior written approval from the
Company. Specifically,no signs,objects,fans,light fixtures,etc.may be hung from the structures,unless specifically engineered by the Company.
• These limited warranties do not cover defects and/or damages caused by:
o normal wear and tear;
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533
USASHADE
& Fabric Structures.
o misuse,willful or intentional damage,vandalism,contact with chemicals,cuts and Acts of God(i.e.tornado,hurricane,micro/macros burst,
earthquake,wildfires,etc.);
o ice,snow or wind loads in excess of the designed load parameters engineered for the supplied structures;
o use,maintenance,neglect,repair,and/or service inconsistent with the Company's written care and maintenance instructions,provided with
the order.
• The limited warranties explicitly exclude:
o workmanship related to assembly not provided by the Company or its agents;
o fabric curtains,valances,and flat vertical panels;
o fabric tops installed on structures that were not engineered and originally supplied by the Company.
• THE COMPANY SHALL NOT BE LIABLE FOR ANY INCIDENTAL,CONSEQUENTIAL,SPECIAL,LIQUIDATED,EXEMPLARY,OR PUNITIVE DAMAGES,OR ANY
LOSS OF REVENUE,PROFIT,USE OR GOODWILL,WHETHER BASED UPON CONTRACT,TORT(INCLUDING NEGLIGENCE),OR ANY OTHER LEGAL THEORY,
ARISING OUT OF A BREACH OF THIS WARRANTY OR IN CONNECTION WITH THE SALE,INSTALLATION,MAINTENANCE,USE,OPERATION OR REPAIR OF ANY
PRODUCT OR SERVICE. IN NO EVENT WILL THE COMPANY BE LIABLE FOR ANY AMOUNT GREATER THAN THE PURCHASE PRICE FOR ANY PRODUCT OR
SERVICE PROVIDED BY THE COMPANY.
• THE FOREGOING LIMITED WARRANTY IS THE SOLE AND EXCLUSIVE WARRANTY FOR THE COMPANY'S PRODUCTS AND SERVICES,AND IS IN LIEU OF ALL
OTHER WARRANTIES,EXPRESS OR IMPLIED,IN LAW OR IN FACT. SELLER SPECIFICALLY DISCLAIMS ALL OTHER WARRANTIES,EXPRESS OR IMPLIED,
INCLUDING,WITHOUT LIMITATION,ALL IMPLIED WARRANTIES OF MERCHANTABILITY AND FITNESS FOR A PARTICULAR USE OR PURPOSE,AND ANY IMPLIED
WARRANTIES ARISING OUT OF COURSE OF DEALING OR PERFORMANCE OR TRADE USAGE. PURCHASER,BY ACCEPTANCE AND USE OF THIS LIMITED
WARRANTY,WAIVES ANY RIGHTS IT WOULD OTHERWISE HAVE TO CLAIM OR ASSERT THAT THIS LIMITED WARRANTY FAILS OF ITS ESSENTIAL PURPOSE.
Colourshade•and eXtreme 32`"are registered trademarks of Multiknit Pty.Ltd.
Commercial 95`"and SaFRshade`"are registered trademarks of Gale Pacific USA Inc.
Monotec 370`"is a registered trademark of PRO-KNIT Industries Pty.Ltd.
Precontraint 502`"is a registered trademark of Serge Ferrari North America,Inc.
16) Assembly/Installation:
• Company will notify Purchaser of the scheduled assembly date. Owner agrees to have an owner representative meet the assembly crew at the job site on the
scheduled assembly date to verify the exact location where the structure(s)is to be placed.
• Labor for the removal,assembly,and/or freight charges will only be covered by Company in instances where the structures supplied and installed by
Company are determined by the Company to be defective. In all cases where structures are not installed by Company,all labor for the removal,assembly,
and/or freight of the structures will be the Purchaser's responsibility.
• Installation prices are based on a single mobilization charge. If additional mobilizations are required,there will be additional charges.
• If the requested services require Company access to Owner's premises,Company will be provided access to the Owner's premises free and clear of debris,
automobiles,or other interference Monday^ Friday during the hours of 8:00am to 6:00pm,and Company will have access to water and electrical facilities
during installation. Additional charges will apply if utilities are not easily accessible. Where applicable,all vehicles will be moved prior to Company's crew
beginning any installation.
• Company will not be responsible for moving or repairing any underground utility lines such as electrical,telephone,gas,water,or sprinkler lines that may be
encountered during installation.
• Any additional costs incurred as a result of hard rock conditions requiring extra equipment,utility removal or repair resulting in delay will result in additional
charges unless they are detailed on as-built site drawings provided to Company or marked on the ground and communicated to Company in writing prior to
fabrication and installation.
17) Installation/Assembly on-site: Where installation/assembly is part of the services,Purchaser must provide the Company with a detailed drawing
prepared by or for the Owner showing exactly where the structures are to be assembled as well as detailing any obstacles or other impediments that
may cause the assembly process to be more difficult. Any fixture(s),e.g.,playground,pools,etc.,that the structures are to be assembled over must also
be detailed,along with their peak heights(if applicable).
18) Site/Use Review by Purchaser:Company relies on the Purchaser to determine that the structures ordered are appropriate and safe for the Owner's installation
site and/or intended use. Company is not responsible for damages or injuries resulting from collisions by moving objects or persons with the structure post(s).
Company can recommend,or supply at additional cost,padding for posts from a third party manufacturer.
19) Preparatory Work: Where installation/assembly is part of the services and in the event that the foundation or job site is not suitable or ready for
assembly to begin on the scheduled day,a Delay of Order notification must be sent to Company at least 4 working days prior,in order to allow Company
to reschedule the project. In the event that Company is not notified and incurs an expense in attempting to execute the assembly,a re-mobilization
charge may be charged to Purchaser before Company will reschedule the assembly.
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533
'.,,, USASHADE
& Fabric Structures.
20) Delegation:Subcontractors: The services and the manufacturing and assembly of the structures may be performed by subcontractors under
appropriate agreements with the Company.
21) Force Maieure:Impracticability: The Company shall not be charged with any loss or damage for failure or delay in delivering or assembling of the
structures when such failure or delay is due to any cause beyond the control of the Company,due to compliance with governmental regulations or
orders,or due to any Acts of God,strikes,lockouts,slowdowns,wars,or shortages in transportation,materials or labor.
22) Dispute Resolution: Any controversy or claim arising out of or related to this agreement must be settled by binding arbitration administered in Dallas,
TX by a single arbitrator selected by the parties or by the American Arbitration Association,and conducted in accordance with the construction industry
arbitration rules. Judgment upon the award may be entered in any court having jurisdiction thereof.
23) Entire Agreement;No Reliance: This agreement represents and contains the entire agreement between the parties. Prior discussion or verbal
representations by the parties that are not contained in this agreement are not part of this agreement. Purchaser hereby acknowledges that it has not
received or relied upon any statements or representations by Company or its agents which are not expressly stipulated herein,including without
limitation any statements as to the structures,warranties,or services provided hereunder.
24) No Third-Party Beneficiaries: This agreement creates no third-party rights or obligations between Company and any other person,including any Owner
who is not also a Purchaser. It is understood and agreed that the parties do not intend that any third party should be a beneficiary of this agreement.
25) Governing Law: The agreement will be construed and enforced in accordance with the laws of the State of Texas.
26) Assignment: Purchaser may not assign this agreement,by operation of law or otherwise,without the prior written consent of Company. The
agreement shall be binding upon and insure to the benefit of the Company and the Purchaser,and their successors and permitted assigns.
Executed to be effective as of the date executed by the Company:
NOTE: FOR ANY PURCHASE EQUAL TO OR EXCEEDING$100,000.00 USD,NO WORK,OTHER THAN PRE-WORK,SHALL BE UNDERTAKEN WITHOUT
A MUTUALLY ACCEPTABLE AND SIGNED CONSTRUCTION CONTRACT.
PURCHASER: SELLER:
City of Pearland USA SHADE& Fabric Structures
Signature: Signature:
By: (Print) By: (Print)
Title: Title:
Date: Date:
NOTE: All purchase orders and contracts should be drafted in the
name of Shade Structures, Inc.
•
www.usa-shade.com 800-966-500 5
AZ:289388 CA:989458 LA:61718 NV:78724 NV:78724 NM:383826 TN:68712 DIR: 1000003533